Sungjee Construction Co., Ltd.
Docket: ASBCA 62002, ASBCA 62170
Decision date: 2021-03-23

ARMED SERVICES BOARD OF CONTRACT APPEALS 
 
OPINION BY ADMINISTRATIVE JUDGE O’SULLIVAN ON APPELLANT’S 
MOTION FOR SANCTIONS FOR SPOLIATION OF EVIDENCE 
 
 Appellant Sungjee Construction Co., Ltd appeals a contracting officer’s 
termination of its contract for default.  In challenging the default termination, Sungjee 
alleges that the government refused to issue passes that it needed to perform the 
contract work on Osan Air Base, Republic of Korea, for a total of 352 days during the 
contract performance period.  In the course of discovery, it became apparent that the 
government could not produce certain documents related to its issuance or non-issuance 
of passes for Sungjee employees due to their routine destruction by the 51st Security 
Forces Pass Office.  Sungjee filed its Motion for Sanctions for Spoliation of Evidence 
on December 15, 2020.  We deny the motion for the reasons stated below. 
 
STATEMENT OF FACTS FOR PURPOSES OF THE MOTION 
 
On August 4, 2020, Appellant Sungjee Construction Co., Ltd., filed a motion to 
compel discovery.  Sungjee sought an order compelling the government to produce 
“documents evidencing that the government had issued proper passes and decals to 
Sungjee which would have allowed Sungjee personnel to access the job site” at Osan Air 
Base, Republic of Korea.  Appellant’s task order for repair of officer dormitory building 
No. 929 was terminated for default on December 20, 2018, and appellant’s defense relies 
at least in part on being able to prove that the government hindered its access to the work 
site. 
 
 On August 21, 2020, the Board conducted a conference call to discuss the 
appellant’s motion and the government’s response.  Appellant explained that it sought 
Appeals of - )  
 )  
Sungjee Construction Co., Ltd. ) ASBCA Nos. 62002, 62170 
 )  
Under Contract No. W91QVN-14-D-0050 )  
   
APPEARANCE FOR THE APPELLANT: Song Yong Eui, Esq. 
  Central IP & Law 
  Seoul, Korea 
     
APPEARANCES FOR THE GOVERNMENT: Scott N. Flesch, Esq. 
    Army Chief Trial Attorney 
 MAJ Mark T. Robinson, JA 
    Trial Attorney 

2 
 
production of copies of pass requests and passes issued in response to those requests for 
the period of performance, roughly from August 2016 to August 2018.  The government 
explained that the biometric data listing personnel who had access to the facility during 
the relevant period, which it had already supplied to appellant, was the only 
documentation that still exists.  The parties agreed that if the government produced a 
letter confirming that the exact documentation sought by appellant no longer exists, the 
matter would be resolved. 
 
 On November 5, 2020, the government issued its response to detailed questions 
posed by appellant in a letter dated August 24, 2020.  The information supplied included 
the following facts relevant to this motion:  During the relevant period, the office 
responsible for issuing passes on Osan Air Base was the 51st Fighter Wing Security 
Forces (SF) located on the base.  The contracting office, 411th Contracting Support 
Brigade (CSB), is not involved in the issuance of passes and does not maintain records 
related to the issuance of passes.  Requests for passes are submitted by the sponsoring 
agency, in this case the 51st Civil Engineering Squadron (CES), which maintains a 
running log of all requests received and gives the hard copy of the pass request to the 
51st SF to process.  The 51st SF keeps hard copies until a final decision to grant or deny 
the request is made, at which point that decision is entered into the Defense Biometric 
Identification System (DBIDS).  Hard copies of disposed pass requests and issued passes 
are destroyed by 51st SF on an annual basis, no later than one year from disposition and 
entry into DBIDS.   
 
 On November 26, 2020, appellant filed its second motion to compel discovery.  
The second motion is identical to the first in most respects, except it includes an 
acknowledgement of the government’s November response affirming that it cannot 
produce the requested documents because they have been destroyed.  Notwithstanding 
the written confirmation that the government cannot produce the documents, appellant 
asked the Board to order the government either to produce the documents or “declare in 
writing that the Government cannot produce the pass-related documents the Appellant 
has been seeking.”   
 
This second motion to compel was followed on December 15, 2020, by 
appellant’s motion for sanctions for spoliation of evidence, in which the appellant asked 
the Board to draw adverse evidential inferences from the government’s inability to 
produce the requested documents, namely that the Board find that the documents that no 
longer exist would have supported appellant’s position that the government did not issue 
the passes that were needed by appellant to timely complete the work on the project. 
 
In a conference call on December 17, 2020, the Board discussed the second 
motion to compel and the motion for sanctions with the parties.  The Board asked 
appellant why it filed the second motion to compel and was told that appellant wanted 

3 
 
the government to “admit” that it has no evidence of issuance of passes.  The Board 
indicated that it would rule on the motions to compel, and requested that the government 
file an opposition to the motion for sanctions.  An Order denying the motions to compel 
was issued on March 9, 2021. 
 
The government filed its opposition to appellant’s motion for sanctions on 
January 14, 2021.  The appellant filed a reply on January 20, 2021, and the 
government, with leave of the Board (due to the new arguments raised in appellant’s 
reply), filed a sur-reply on February 17, 2021.  On February 22, 2021, the appellant 
moved for leave to respond to the government’s sur-reply.  This motion was denied by 
the Board on March 8, 2021. 
 
DISCUSSION 
 
Contentions of the Parties 
 
 Sungjee asks that the Board find that the government has failed to preserve and 
has destroyed documents which it had a duty to preserve, and that Sungjee has been 
prejudiced by this failure which adversely affects its ability to prove that the government 
improperly prevented proper access to the job site for a total of 352 days.  Sungjee 
further requests that the Board assess sanctions by drawing the adverse inference that the 
documents, had they been produced, would have demonstrated that the government’s 
delays and failures to timely renew passes denied appellant proper access to the worksite 
for 352 days out of the original 450 day performance period under the task order.   
 
  Sungjee asserted in its initial motion for sanctions that the duty to preserve 
records can arise one of two ways.  First, an applicable regulation or statute may require 
that the records be maintained for a specific period of time.  Second, a duty to preserve 
also arises when a party knows or should have known that the records may be relevant to 
future litigation.  However, despite acknowledging that the party moving for sanctions 
for spoliation has the burden of proof, Sungjee did not in its initial motion identify, let 
alone establish, how the government’s destruction of pass-related documents was in 
violation of either kind of duty.   
 
 In its opposition to Sungjee’s motion, the government contends that the earliest 
time litigation could reasonably have been foreseen was March of 2019 when 
appellant filed its Notice of Appeal with the Board.  By that time, it notes, two months 
had already passed since the 51st SF destroyed the documents as part of its regular 
course of business.  In support, the government proffers the Declaration of 
Technical Sergeant Cody Hutchison.  TSgt Hutchison currently serves as the 
non-commissioned officer in charge of the 51st SF Pass and Registration Office at 
Osan Air Base.  He states that pass request records are filed until they are no longer 

4 
 
needed to support the process for which they are created or received.  Thus, if passes 
for Sungjee personnel were no longer required, expired, or the business relationship 
had been terminated, pass-related documents would have been destroyed during the 
annual review in January 2019.  In September of 2020, the Army Legal Services 
Agency asked his office to conduct a search for pass requests and documents 
pertaining to installation access for Sungjee from August 2016 to December 2018.  
However, due to the annual process he described, his office no longer had the 
requested records.   
 
 The government further notes that the adverse inference sought by appellant, that 
the government was responsible for Sungjee’s inability to properly access the work site 
for 352 days, would be a dispositive inference since it would entitle Sungjee to an 
excusable delay in the contract completion date.  The government states that a 
dispositive adverse inference requires a finding of bad faith, citing Garco Constr., Inc., 
ASBCA Nos. 57796, 57888, 13-1 BCA ¶ 35,456 at 173,881.   
 
 In appellant’s reply to the government’s opposition, appellant stated for the first 
time that the 51st SF should have retained the pass-related documents for six years 
pursuant to Federal Acquisition Regulation (FAR) 4.805, Storage, Handling, and 
Contract Files.  FAR 4.805 contains a table with varying retention periods for contract 
files, depending on the type of file and the dollar value of the contract in question.  The 
retention period for construction contracts above $2000 and related documents, 
including successful proposals, is 6 years and three months after final payment.  
However, appellant does not convincingly argue that base pass-related documents, no 
matter how important they may be to a contractor’s ability to perform, constitute contract 
files.  
 
Appellant also argues in its reply that a duty to preserve arose because litigation 
was reasonably foreseeable at the time the government issued its Notice of Termination 
on December 20, 2018.  However, beyond this bare assertion, we are not given a factual 
basis for concluding that litigation was reasonably foreseeable at this time.   
 
 In its sur-reply, the government argues that no duty to preserve the documents 
existed at the time of their routine destruction in January of 2019, either under 
FAR 4.805’s record retention requirements, or because litigation was reasonably 
foreseeable at that time.  As to the first point, the government states that FAR 4.805 sets 
forth requirements for contracting offices, contract administration offices, and payment 
offices to retain their contract files, and does not apply to an office such as the 51st SF, 
which did not have a contracting function and therefore would not have contract files.  
As to the second point, the government points out that there would have been no reason 
to anticipate litigation at the time the notice of termination was issued or the next month 
when the pass-related records were destroyed, because Sungjee had never alleged any 
excusable or government delay and, in fact, admitted fault for its delays on numerous 

5 
 
occasions in writing, citing the record at Rule 4, tabs 55 and 92, and an email attached 
to its sur-reply as Ex. A.  Therefore, the first time the government could have 
reasonably foreseen litigation was in March of 2019 when Sungjee filed its Notice of 
Appeal. 
 
A party moving for sanctions for spoliation of evidence has the burden of proving 
three elements:  (1) the party having control over the evidence had an obligation to 
preserve it when it was destroyed or altered; (2) the destruction or loss was accompanied 
by a “culpable state of mind;” and (3) the evidence that was destroyed or altered was 
relevant to the claims or defenses of the party that sought the discovery of the evidence, 
to the extent that a reasonable factfinder could conclude that the evidence would have 
supported the claims or defenses of the party that sought it.  Garco Constr., Inc., 
ASBCA Nos. 57796, 57888, 13 BCA ¶ 35,456 at 173,879; Ensign-Bickford Aerospace 
& Defense Co., ASBCA No. 57929, 13 BCA ¶ 35,322 at 173,385.  The third element “is 
often cast in terms of prejudice,” in that “it must be shown that the requesting party was 
prejudiced by the loss of evidence.”  ADT Constr. Grp., Inc., ASBCA No. 55358, 13 
BCA ¶ 35,307 at 173,325. 
 
Further, if the sanctions sought for spoliation are dispositive, before imposing 
such sanctions the trier of fact must make a determination of bad faith.  Micron Tech., 
Inc. v. Rambus, Inc., 645 F.3d 1311, 1327 (Fed. Cir. 2011).  To make a determination of 
bad faith, the court must find that the spoliating party intentionally destroyed documents 
that it knew would be important or useful to its opponent, and the fundamental element 
of bad faith spoliation is “advantage-seeking behavior by the party with superior access 
to information necessary for the proper administration of justice.”  Id. at 1326.  
Moreover, to impose dispositive sanctions, it is not enough to find both bad faith and 
prejudice.  In gauging the propriety of such a sanction, the court must take into account 
(1) the degree of fault of the party who destroyed the evidence, (2) the degree of 
prejudice suffered by the opposing party, and (3) whether there is a lesser sanction that 
will avoid prejudice to the opposing party but also, where the offending party is 
seriously at fault, will serve to deter such conduct by others in the future.  Id. at 1329. 
 
The Duty to Preserve 
 
 For purposes of this motion, we find that the pass-related documents appellant 
seeks were destroyed in accordance with the then-current document retention policy of 
the 51st Security Forces office in January 2019.  In addition, we find the longer retention 
periods cited by appellant to be inapplicable inasmuch as they do not apply to base pass 
offices, and records pertaining to base access such as those sought by appellant are not 
contract files.  Thus, appellant has not established the existence of any regulatory or 
contractual duty to retain the records beyond the time when they were destroyed. 
 

6 
 
 When litigation is “reasonably foreseeable” is a flexible, fact-specific standard 
that allows a court to exercise the discretion necessary to confront the myriad factual 
situations inherent in the spoliation inquiry.  Micron, 645 F.3d at 1320.  It is an objective 
standard, asking not whether the party in fact reasonably foresaw litigation, but whether 
a reasonable person in the same factual circumstances would have reasonably foreseen 
litigation.  Id.  Sungjee carries the burden of proof on its motion, but points us to nothing 
more than its assertion that the government should have known that litigation was 
reasonably foreseeable when it issued the Notice of Termination for Default on 
December 20, 2018.  We do not think that the mere possibility of litigation that 
accompanies government actions such as notices of default termination or denials of 
claims can be held to trigger a duty of preservation that does not otherwise exist.  
Moreover, the government has supplied us with facts indicating that a reasonable person 
in the government’s position could not have reasonably foreseen litigation until after 
Sungjee filed its Notice of Appeal on March 18, 2019.  Appellant has failed to carry its 
burden of proof on this point.  We find that litigation was not reasonably foreseeable at 
the time the documents were destroyed. 
 
Culpable State of Mind and Prejudice 
 
 Even if we could find that litigation was reasonably foreseeable during the few 
weeks’ span between the issuance of the Notice of Termination and the routine 
destruction of the documents, Sungjee has not met its burden of proof on the other two 
elements of spoliation, a culpable state of mind and prejudice.  As to culpable state of 
mind, to us it is significant that the documents were destroyed as a matter of routine 
policy during the annual review in January of 2019.  Had the annual review been 
scheduled for, say, June, but the documents were destroyed in January, further inquiry 
into the reason for the early destruction might unearth evidence of culpable state of 
mind.  But Sungjee has not drawn our attention to any evidence that the documents were 
destroyed for any reason other than timely housekeeping.   
 
As for prejudice, while it is true that the evidence Sungjee seeks appears relevant 
to its asserted defense, Sungjee offers us nothing from which we can find that the 
destroyed evidence would have been favorable to its position.  We also have no 
explanation for why Sungjee does not have its own relevant evidence to offer to satisfy 
its burden of proof.  Typically, parties to a contract each keep their own files, and 
document any developments that may be relevant to their respective rights and 
responsibilities.  If the government’s failure to issue needed passes was indeed the 
reason Sungjee could not timely perform, it seems highly unlikely that Sungjee would 
not carefully document this fact, so that at trial it could support its defense against the 
eventual termination for default with its own contemporaneous records.  In short, we 
cannot find that the government’s routine document destruction, as opposed to Sungjee’s 
apparent failure to create and keep contemporaneous records, is the cause of any 
difficulty Sungjee may be experiencing in meeting its burden of proof.  

7 
 
 
 Given that Sungjee has not met its burden of proof to show that any spoliation 
occurred, we do not reach the issues of dispositive sanctions and bad faith. 
 
CONCLUSION 
 
Appellant’s motion for sanctions for spoliation of evidence is denied. 
  
 Dated:  March 23, 2021
 
 
 
 
 
 
 
 
 
 
 
LYNDA T. O’SULLIVAN 
Administrative Judge 
Armed Services Board 
of Contract Appeals 
I concur 
 
 
 
RICHARD SHACKLEFORD 
Administrative Judge 
Acting Chairman 
Armed Services Board 
of Contract Appeals 
 I concur 
 
 
 
 OWEN C WILSON 
Administrative Judge 
Vice Chairman 
Armed Services Board 
of Contract Appeals 
 
 I certify that the foregoing is a true copy of the Opinion and Decision of the 
Armed Services Board of Contract Appeals in ASBCA Nos. 62002, 62170, Appeals of 
Sungjee Construction Co., Ltd., rendered in conformance with the Board’s Charter. 
 
 Dated:  March 24, 2021  
 
 
 
 
 
 
 
 
PAULLA K. GATES-LEWIS 
Recorder, Armed Services 
Board of Contract Appeals