US Pan American Solutions, LLC
Docket: ASBCA 63743
Decision date: 2024-05-13

ARMED SERVICES BOARD OF CONTRACT APPEALS 
 
OPINION BY ADMINISTRATIVE JUDGE WILSON  
ON JURISDICTION 
 
This appeal arises out of the termination for cause of a contract between 
appellant US Pan American Solutions, LLC (USPAS) and the Naval Supply Systems 
Command Fleet Command Center Jacksonville (Navy).  Shortly after USPAS filed its 
notice of appeal, the Board sua sponte directed the parties to brief the question of the 
Board’s jurisdiction.  The Navy submitted a brief requesting that the appeal be 
dismissed for lack of jurisdiction, contending that it was untimely filed because 
USPAS did not submit its notice of appeal within 90 days as required by the Contract 
Disputes Act (CDA), 41 U.S.C. §§ 7101-7109.  USPAS did not respond to the Navy’s 
brief.  We dismiss the appeal as untimely filed. 
 
STATEMENT OF FACTS (SOF) 
1.  On August 17, 2022, the Navy awarded Contract No. N6883622P0257 
(contract) to USPAS for the delivery of three glacial pool coolers for use at the Naval 
Diving and Salvage Training Center in Panama City, Florida (R4, tab B at 21, 24). *  
The contract specified November 30, 2022 as the delivery date (id. at 23).    
 
2.  USPAS did not deliver the pool coolers on November 30, 2022, the contract’s 
delivery date, so by email dated December 9, 2022, the Navy requested that USPAS 
provide a status update.  USPAS responded that shipment was scheduled for 
 
* The government numbered the pages of its Rule 4 submission with leading zeros, 
which we omit here. 
Appeal of - )  
 )  
US Pan American Solutions, LLC ) ASBCA No. 63743 
 )  
Under Contract No. N68836-22-P-0257 )  
   
APPEARANCE FOR THE APPELLANT: Mr. Jorge Delpino 
    President 
 
APPEARANCES FOR THE GOVERNMENT: Craig D. Jensen, Esq. 
    Navy Chief Trial Attorney 
 Sharon H. Sachs, Esq. 
Lance P. Fortney, Esq. 
    Trial Attorneys 

2 
 
December 22, 2022.  (R4, tab B at 37-38)  USPAS failed to meet that shipment date as 
well.  For the next four months – between January and April 2023 – the Navy 
repeatedly requested that USPAS provide it with status updates concerning when it 
could expect the pool coolers to be delivered.  USPAS either ignored those requests, 
was noncommittal in its response, or provided delivery or shipment dates that it then 
failed to meet.  (R4, tab B at 39-41, 51-54, 58-60, 67)  
 
3.  On April 3, 2023, the Navy directed USPAS to contact it by the close of 
business the following day to avoid “any possible actions in regards to this contract” 
(R4, tab B at 66-67).  On April 13, 2023, USPAS and the Navy participated in a 
conference call, at which time the Navy rejected USPAS’s proposed delivery date 90 
days hence.  Instead, the parties agreed that by the following day, USPAS would 
provide the Navy with an updated delivery date that was within 60 days.  USPAS 
failed to provide that information.  (R4, tab C at 107)   
 
4.  On April 18, 2023, the Navy informed USPAS that it intended to issue a 
contract modification to extend the delivery date for 60 days but would seek guidance 
from its attorneys if USPAS missed that delivery date as well.  The Navy again 
requested that, by the following day, USPAS provide it with an updated delivery date.  
USPAS never provided that information.  (R4, tab B at 74-77, tab C at 107) 
 
5.  At some point the Navy decided that rather than formally extend the delivery 
date it would terminate USPAS’s contract.  By email dated May 3, 2023, the Navy 
forwarded to USPAS a copy of contract Modification No. P00001 (Mod 1) terminating 
USPAS’s contract for cause for failure to timely deliver the pool coolers.  Neither the 
cover email nor Mod 1 included the standard recitation of a contractor’s appeal rights 
required under Federal Acquisition Regulation (FAR) 33.211(a)(4)(v).  (R4, tab B 
at 90, tab C at 92-96)  
 
6.  By email dated May 8, 2023, USPAS wrote to the Navy requesting assistance 
“to address a pressing issue that arose during our recent call” with Navy 
representatives: 
 
During the call, it was mentioned that [a Navy 
representative] was open to extending our current timeline 
by more than 90 days.  However, it appears that there has 
been a miscommunication or misunderstanding, as we 
have now been notified that we are required to proceed 
with the appeal process.  This situation not only creates an 
unnecessary burden on the appeal board’s valuable time 

3 
 
but also imposes significant financial implications on our 
group due to this termination. 
 
(R4, tab C at 109) 
 
7.  The Navy responded on May 12, 2023, advising USPAS that it was within its 
rights to terminate the contract (R4, tab C at 110-11).  The Navy’s response also 
included the following sentence:  “The contractor may appeal this decision under ‘The 
Contract Disputes Act of 1978 (CDA)’” (id. at 111).  USPAS replied on May 17, 
2023, informing the Navy that it had “contacted Absca Appeal Board and we are 
really confused on why this [isn’t] being supported and allowed to proceed with 
delivery . . . .”  (id. at 106).  
 
8.  USPAS’s May 17, 2023 email apparently prompted a conference call between 
the parties.  By email dated May 22, 2023, the Navy provided a “recap” of the call, 
stating “[w]e will expect an email of the updated confirmed delivery date no later than 
Tuesday, 23 May 2023 12:00pm EST.  This email will serve as the next action by the 
Government in reference to the subject terminated contract for failure of delivery of 3 
Pool Coolers . . . .”  (R4, tab C at 113)  The following afternoon, USPAS informed the 
Navy that the approximate delivery date would be July 7, 2023 (id. at 215).   
 
9.  By email dated June 2, 2023, the Navy forwarded to USPAS a contract 
modification extending the delivery date until July 7, 2023, which USPAS was to sign 
and return to the Navy.  The email stated that if the pool coolers were not received on 
that date the Navy would “initiate actions to terminate this contract for cause on 
10 July 2023.”  (R4, tab C at 212)  On June 6, 2023, the Navy executed Modification 
No. P00002 (Mod 2) rescinding Mod 1, reinstating the contract, and extending the 
delivery date to July 7, 2023 (R4, tab D at 231-32). 
 
10.  During June 2023, the Navy repeatedly requested confirmation from USPAS 
that the pool coolers would be delivered by July 7, 2023.  In these communications the 
Navy frequently reminded USPAS that the contract would be terminated for cause if 
the delivery date was not met.  USPAS provided the requested assurances throughout 
the month.  (R4, tab D at 238, 242-43, 250-52, 263-64)  However, on July 3, 2023 
USPAS responded much more equivocally, this time stating “[w]e will work today to 
have this info supported regarding our delivery.  I will follow up with tracking as soon 
as possible” (id. at 273).  
 
11.  On July 5, 2023, a Navy representative emailed USPAS, stating that several 
attempts had been made via text, email and voicemail to obtain a status on the 
anticipated delivery.  The representative directed USPAS to provide a “detailed status 
by 3:00 PM” that day.  (R4, tab D at 288-89)  The Navy representative once again 

4 
 
reminded USPAS that failure to meet the July 7, 2023 delivery date would result in a 
termination for cause (id. at 289).   
 
12.  Early on the morning of July 6, 2023, USPAS advised the Navy via email that 
it had still not received the bill of lading or tracking for the pool coolers and that “the 
mid week 4th Holiday has un-expectedly caused this last delay” (R4, tab D at 306).  
An email from approximately 10 am that morning, originating from the Navy and sent 
to numerous representatives of both the Navy and USPAS, contains copies of text 
exchanges between representatives from USPAS and the Navy regarding the 
anticipated delivery, with USPAS providing evasive responses to the Navy’s demands 
for delivery information (R4, tab D at 303).  One hour later the Navy emailed USPAS 
stating “[y]ou have failed to respond with status.  The Government demands a phone 
conference today” (id. at 304). 
 
13.  On July 7, 2023, a USPAS representative emailed the Navy to confirm he 
would “send an invite for a Monday [July 10, 2023] 1:15 pm call” with USPAS’s 
suppliers (R4, tab D 323-24).  Within minutes the Navy declined the offer to 
participate in that call and instead requested that USPAS provide an accurate delivery 
time by 3:00 pm that day (R4, tab D at 322).  We were unable to locate in the record 
any evidence that USPAS responded to that email. 
 
14.  By email dated July 14, 2023, the Navy informed USPAS that it was 
forwarding a copy of contract Modification No. P00003 (Mod 3) terminating USPAS’s 
contract for cause for failure to deliver the pool coolers.  Neither the cover email nor 
Mod 3, also dated July 14, 2023, included the standard recitation of a contractor’s 
appeal rights required under FAR 33.211(a)(4)(v).  (R4, tabs D at 325, E at 328-30) 
 
15.  USPAS filed its notice of appeal with the Board on October 24, 2023 and 
included a copy of Mod 3 with its submission.  Because it appeared the appeal might 
be untimely under the CDA, by Order dated October 27, 2023, the Board directed 
USPAS to show by suitable evidence that it filed a timely appeal in accordance with 
41 U.S.C. § 7104(a).   
 
16.  Instead of providing the evidence requested by the Board, on November 28, 
2023, USPAS’s president, Mr. Jorge Delpino, submitted a request to the Board for 
alternative dispute resolution.  In that request, Mr. Delpino stated that USPAS 
“received the Termination on 7/14/23 and . . . without counsel misinterpreted the 
appeal period as 120 days.” (Bd. corr. email dtd. November 28, 2023
)  We find that 
admission by Mr. Delpino indicates USPAS received the Navy’s termination decision 
on July 14, 2023. 
 
17.  By Order dated December 4, 2023, the Board directed the Navy to brief the 
question of whether the Board possesses jurisdiction to hear this appeal.  In that same 

5 
 
Order, USPAS was advised that upon receipt of the government’s brief it would have 
30 days to respond.  The Navy submitted its brief on December 19, 2023, requesting 
that the Board dismiss the appeal for lack of jurisdiction because USPAS did not file 
its notice of appeal within 90 days after it received Mod 3, as required by the CDA 
(gov’t br. at 4-5).  A copy of that brief was provided to USPAS.   
 
18.  USPAS did not respond to the government’s December 19, 2023 brief on the 
question of the Board’s jurisdiction; nor did it respond to multiple subsequent orders 
from the Board directing it to submit a response to the government’s brief.   
 
DECISION 
 
Appellant bears the burden of establishing by a preponderance of the evidence 
that the Board possesses jurisdiction to hear its appeal.  See Reynolds v. Army & Air 
Force Exchange Serv., 846 F.2d 746, 748 (Fed. Cir. 1988); United Healthcare 
Partners, Inc., ASBCA No. 58123, 13 BCA ¶ 35,277 at 173,156.  We accept 
uncontroverted factual allegations as true for purposes of deciding motions to dismiss 
for lack of jurisdiction, and “other facts underlying the jurisdictional allegations are 
subject to fact-finding” based upon our review of the record.  See L-3 Commc’ns 
Integrated Sys., L.P., ASBCA Nos. 60713, 60716, 17-1 BCA ¶ 36,865 at 179,625 
(citations omitted).   
 
Under the CDA, contractors must file their notices of appeal with the Board 
within 90 days of receiving a contracting officer’s final decision.  41 U.S.C. § 7104(a); 
see Woolpert, Inc., ASBCA No. 63515, 24-1 BCA ¶ 38,542 at 187,349.  “In the case 
of a termination for cause, such as the one presented here, receipt of notification of the 
[contracting officer’s] decision to terminate for cause begins the 90-day clock.”  
Western Trading Co., ASBCA No. 61004, 18-1 BCA ¶ 37,030 at 180,304 (quoting 
Bushra Co., ASBCA No. 59918, 16-1 BCA ¶ 36,355 at 177,238).  The 90-day 
deadline is statutory, strictly construed and cannot be waived.  See Cosmic Constr. Co. 
v. United States, 697 F.2d 1389, 1390 (Fed. Cir. 1982). 
 
For purposes of starting the CDA’s 90-day window, it is typically the 
government’s burden to prove the date a contractor received a final decision.  See, e.g., 
MVP Network Consulting, LLC, ASBCA No. 63466, 23-1 BCA ¶ 38,427 at 186,766 
(government must provide “objective indicia” of actual receipt; without more, 
evidence that a final decision was emailed to appellant “introduces uncertainty” to the 
analysis).  The Navy provided a July 14, 2023 email purporting to forward a copy of 
Mod 3, and Mod 3 itself is dated July 14, 2023 (SOF ¶ 14).  While the Rule 4 file does 
not include evidence establishing the date that USPAS received notice of the Navy’s 
second termination for cause, we have previously found that an appellant’s failure to 
assert a different receipt date can be used to establish that it received the final decision 
on the email transmission date.  See Alnawars Co., ASBCA No. 58678, 13-1 BCA 

6 
 
¶ 35,463 at 173,908 (“Since appellant has not asserted, in response to the 
government’s motion, that it received the COFD on a different date, we find that 
appellant received the COFD on 14 January 2013.”); see also Zahra Rose Constr. & 
Logistics Servs. Co., ASBCA No. 63221, 22-1 BCA ¶ 38,134 at 185,234, recon. 
denied 22-1 BCA ¶ 38,148 (noting appellant did not assert that it received the final 
decision on a date other than the date it was emailed).   
 
In addition, USPAS’s president, Mr. Delpino, has admitted in correspondence 
with the Board that USPAS received the notice of termination on the same date the 
email indicates it was sent – July 14, 2023 (SOF ¶¶ 14, 16; see gov’t br. at 3).  We 
deem this admission sufficient to prove that USPAS received notice of the termination 
on July 14, 2023 (SOF ¶ 16). 
 
 We also do not find fatal to the jurisdictional question the Navy’s failure to 
include in Mod 3 language regarding USPAS’s appeal rights.  FAR 33.211 requires 
that a contracting officer’s written decision include language substantially the same as 
the following: 
 
This is the final decision of the Contracting Officer.  
You may appeal this decision to the agency board of 
contract appeals.  
If you decide to appeal, you must, within 90 days from the 
date you receive this decision, mail or otherwise furnish 
written notice to the agency board of contract appeals and 
provide a copy to the Contracting Officer from whose 
decision this appeal is taken.  
The notice shall indicate that an appeal is intended, 
reference this decision, and identify the contract by 
number. 
 
FAR 33.211(a)(4)(v).  The omission of that notice, however, does not nullify an 
otherwise valid final decision.  See Parsons Gov’t Servs., Inc., ASBCA No. 62113, 
20-1 BCA ¶ 37,586 at 182,509 (citing Alenia North America, Inc., ASBCA No. 57935, 
13 BCA ¶ 35,296 at 173,271).  Nor will it stop the 90-day deadline from commencing 
unless the contractor can show detrimental reliance or prejudice.  Decker & Co. v. 
West, 76 F.3d 1573, 1579 (Fed. Cir. 1996); see Mansoor Int’l Dev. Servs., ASBCA 
No. 58423, 14-1 BCA ¶ 35,742 at 174,926 (citing Decker for the proposition that it is 
the contractor’s burden to show prejudice).  If the contractor can show detrimental 
reliance or prejudice, the 90-day deadline will be tolled.  Access Personnel Servs., Inc., 
ASBCA No. 59900, 16-1 BCA ¶ 36,407 at 177,517. 
 
The Navy argues that USPAS was not prejudiced by the omission of its appeal 
rights in Mod 3 or the cover email (gov’t br. at 5-12).  We agree.  The Navy’s first 

7 
 
termination for cause in May 2023 (which was later rescinded) also did not include the 
language required by FAR 33.211(a)(4)(v) (SOF ¶ 5).  Nevertheless, in apparent 
response to that termination, USPAS emailed the Navy on May 8, 2023 stating that 
“we have now been notified that we are required to proceed with the appeals process” 
which would “create[] an unnecessary burden on the appeal board’s valuable time” 
(SOF ¶ 6).  Moreover, USPAS’s May 17, 2023 statement that it had “contacted Absca 
Appeal Board” after the Navy advised it could “appeal this decision under the Contract 
Disputes Act” shows USPAS was aware well before the second (and final) termination 
that it had the right to appeal, and further that it knew this Board was where its appeal 
could be filed (SOF ¶¶ 6-7). 
 
 USPAS has also not affirmatively claimed that it was prejudiced by the Navy’s 
failure to include its appeal rights in Mod 3 or the cover email.  See Zahra Rose 
Constr., ASBCA No. 63221, 22-1 BCA ¶ 38,134 at 185,234 (in finding no prejudice, 
noting that appellant “[did] not assert that the lack of written appeal rights prejudiced 
its ability to timely initiate its Board appeal”).  In fact, USPAS well knew how to 
properly initiate an appeal, having appeared before the Board in the recent past.  In 
U.S. Pan American Sols., LLC, ASBCA No. 62629, 21-1 BCA ¶ 37,911, the Board 
found USPAS’s notice of appeal was timely because it was filed within 90 days of a 
later-dated corrected version of the government’s original termination decision.  Id. 
at 184,120.  It is difficult to understand how USPAS could have been unaware of its 
appeal rights, including the 90 day deadline, given that prior litigation.  See also BCC-
UIProjects-ZAAZTC Team JV, ASBCA No. 62846, 22-1 BCA ¶ 38,119 at 185,176 (a 
party’s “demonstrated ability to bring an appeal to the Board is affirmative evidence” 
that no prejudice occurred).  We note that USPAS’s president, Mr. Jorge Delpino, 
served as USPAS’s named representative in that earlier appeal as well as this one.  See 
id. (finding no prejudice in part because the person who brought an earlier appeal on 
behalf of one of the parties to the joint venture was still associated with that party).  
Given that prior litigation and resulting Board decision on precisely this issue, it is 
unclear to us why Mr. Delpino or USPAS “misinterpreted the appeal period as 120 
days” (SOF ¶ 16; see gov’t br. at 3).   
 
The record establishes that the Navy notified USPAS via email of the 
termination on July 14, 2023, and USPAS admits it received notice of the termination 
on that date (SOF ¶¶ 14, 16).  Yet USPAS did not file its appeal with the Board until 
October 24, 2023, 12 days beyond the closing of the 90-day window (SOF ¶ 15).  
USPAS was given multiple opportunities to present relevant evidence or to otherwise 
challenge the Navy’s assertions in its brief, but failed to do so (SOF ¶¶ 16-18).  We 
therefore conclude that because it was untimely filed, we do not possess jurisdiction to 
hear USPAS’s appeal.  
  

8 
 
CONCLUSION 
 
The appeal is dismissed.  
 
 Dated:  May 13, 2024 
 
 
 
 
 
 
 
 
 
 
 
OWEN C. WILSON 
Administrative Judge 
Acting Chairman 
Armed Services Board 
of Contract Appeals 
I concur 
 
 
 
J. REID PROUTY 
Administrative Judge 
Vice Chairman 
Armed Services Board 
of Contract Appeals 
 I concur 
 
 
 
 LAURA EYESTER 
Administrative Judge 
Armed Services Board 
of Contract Appeals 
 
 
 I certify that the foregoing is a true copy of the Decision and Dismissal of the 
Armed Services Board of Contract Appeals in ASBCA No. 63743,
 Appeal of US Pan 
American Solutions, LLC, rendered in conformance with the Board’s Charter. 
 
 Dated:  May 13, 2024 
 
 
 
 
 
 
 
PAULLA K. GATES-LEWIS 
Recorder, Armed Services 
Board of Contract Appeals