U.S. Coating Specialties & Supplies, LLC
Docket: ASBCA 58245
Decision date: 2015-04-09

ARMED SERVICES BOARD OF CONTRACT APPEALS 
Appeal of -- ) 
) 
U.S. Coating Specialties & Supplies, LLC ) 
) 
Under Contract No. W912EE-10-C-0019 ) 
APPEARANCE FOR THE APPELLANT: 
APPEARANCES FOR THE GOVERNMENT: 
ASBCA No. 58245 
Louis H. Watson, Jr., Esq. 
Watson & Norris, PLLC 
Jackson, MS 
Thomas H. Gourlay, Jr., Esq. 
Engineer Chief Trial Attorney 
John M. Breland, Esq. 
Daniel L. Egger, Esq. 
Engineer Trial Attorneys 
U.S. Army Engineer District, Vicksburg 
OPINION BY ADMINISTRATIVE JUDGE DICKINSON 
ON THE GOVERNMENT'S AMENDED MOTION TO DISMISS OR, IN THE 
ALTERNATIVE, FOR SUMMARY JUDGMENT 
Appellant, U.S. Coating Specialties & Supplies, LLC (U.S. Coating), appeals 
pursuant to the Contract Disputes Act of 1978 (CDA), 41 U.S.C. §§ 7101-7109, from the 
government's termination of the captioned contract for default. The government moves 
to dismiss the appeal on various grounds and, alternatively, moves for summary 
judgment. Appellant opposes the motion. 
STATEMENT OF FACTS (SOF) FOR PURPOSES OF THE MOTION 
1. On 21 June 2010, the Vicksburg Contracting Office of the United States Army 
Corps of Engineers (Corps) awarded Contract No. W912EE-10-C-0019 to U.S. Coating 
in the amount of$1 l,383,000 for the construction of a U.S. Army Engineer Research and 
Development Center Information Technology Laboratory office building 
and computer 
facility (R4, tab 3 at 5-6). 
, 2. The contract included the standard Federal Acquisition Regulation (FAR) 
default clause, FAR 52.249-10, DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984), 
which provided, in pertinent part: 
(a) If the Contractor refuses or fails to prosecute the work or 
any separable part, with the diligence that will insure its 
completion within the time specified in this contract including 

any extension, or fails to complete the work within this time, 
the Government may, by written notice to the Contractor, 
terminate the right to proceed with the work (or the separable 
part of the work) that has been delayed .... 
(c) If, after termination of the Contractor's right to proceed, it 
is determined that the Contractor was not in default, or that 
the delay was excusable, the rights and obligations of the 
parties will be the same as if the termination had been issued 
for the convenience of the Government. 
(R4, tab 3 at 133-34) 
3. On 13 January 2012, during performance of the contract, U.S. Coating filed a 
voluntary petition for relief under Chapter 11 of the Bankruptcy Code in the United 
States Bankruptcy Court for the Southern District of Mississippi (Bankruptcy Court) (R4, 
tab 4). 
4. Travelers Casualty and Surety Company of America (Travelers), U.S. Coating's 
surety for the contract, filed two motions in the Bankruptcy Court on 24 February 2012. 
Travelers filed a motion to lift the automatic stay, imposed by 11 U.S.C. § 362, to allow 
Travelers to enforce its rights under a General Agreement of Indemnity between Travelers 
and U.S. Coating (R4, tab 5). Travelers also filed a motion to compel 
rejection of the 
contract or, alternatively, to compel U.S. Coating to assume or reject the contract pursuant 
to 11 U.S.C. § 365 within ten days (supp. R4, tab 1). 
5. On 13 March 2012, the United States filed a response joining Travelers' motion 
seeking relief from the automatic stay to allow the government to terminate the contract 
and to arrange for completion of the project pursuant to FAR Part 49 (R4, tab 6). The 
United States also filed a response in support of Travelers' motion to compel rejection of 
the contract on 13 March 2012 (supp. R4, tab 2). 
6. The Bankruptcy Court issued an order on 30 March 2012, directing 
U.S. Coating to file a motion to assume or reject the contract by 4:30 p.m. on 13 April 
2012, and setting a trial on any such motion for 26 April 2012 (supp. R4, tab 4). 
7. On 17 April 2012, with permission from the Bankruptcy Court (see R4, tab 20 
at 45), U.S. Coating filed a motion to assume the contract pursuant to 11 U.S.C. § 365 
(R4, tab 9). Travelers filed its objection to U.S. Coating's motion to assume the contract 
on 16 April 2012 (R4, tab 10). The United States filed a response on 20 April 2012 
demanding proof at trial of U.S. Coating's ability to assume the contract (R4, tab 12). 
2 

8. Prior to the scheduled 26 April 2012 trial, the parties advised the Bankruptcy 
Court that the issues had been settled and submitted a proposed order to that effect 
(R4, tab 20 at 45). The Bankruptcy Court issued an order on 25 April 2012 
finding that 
cause existed to grant Travelers and the Corps relief from the automatic stay, that the 
motion to assume should be denied, and that the contract should be deemed rejected. 
Accordingly, the Bankruptcy Court ordered that "the Contract is hereby rejected as a 
matter oflaw," and that ''the automatic stay is hereby terminated in favor of the Corps 
and Travelers." The order did not expressly address termination of the contract by the 
Corps. (R4, tab 13) 
9. Following the issuance of the Bankruptcy Court's order, the Corps' contracting 
officer issued a final decision, dated 25 April 2012, terminating the contract for default 
on the basis that U.S. Coating's consent to the rejection of the contract constituted 
anticipatory repudiation of the contract (R4, tab 2). 
10. On 30 April 2012, U.S. Coating filed a motion in the Bankruptcy Court to 
vacate the 25 April 2012 order. In its motion, U.S. Coating asserted that its consent to 
the proposed order was based on representations by the Assistant United States Attorney 
that the Corps would terminate the contract for "reasons other than default." (R4, tab 15) 
Both the United States and Travelers filed responses in opposition to U.S. Coating's 
motion to vacate the 25 April 2012 order (R4, tabs 16, 17). 
11. The Bankruptcy Court held a hearing on U.S. Coating's motion to vacate, in 
which the United States participated, on 17 May 2012. The sole witness at the hearing, 
~Mr. Earl J. Washington, U.S. Coating's president and CEO, testified that he had 
attempted to meet with the contracting officer to discuss bringing on a new subcontractor 
to assist with completion of the contract, but that the contracting officer stated that she 
could not discuss the issue while the automatic stay remained in place. Mr. Washington 
further testified that his agreement to the proposed order was based on his understanding 
that such an order was necessary to proceed with negotiations with the Corps to allow the 
addition of the subcontractor to assist U.S. Coating in completing the contract. (R4, 
tab 20 at 23-30) Mr. Washington also testified that "I have not consented to any 
termination, and I will not consent to any termination" (id. at 33). Prior to 
Mr. Washington's testimony, the Bankruptcy Court noted that the 25 April 2012 order 
was silent on how the contract would be terminated and inquired of Mr. Jeff Regner, 
counsel appearing on behalf of the United States and the Corps, what recourse is 
available to a party that disagrees with a termination. Mr. Regner responded that a 
contractor that is unsatisfied with a termination for default can maintain an action before 
the Court of Federal Claims or the Board of Contract Appeals, and that "if the contracting 
officer has done the wrong thing here[,] there is an opportunity for this debtor to obtain 
relief from -- from that decision." (R4, tab 20 at 18-20) 
12. Ruling from the bench, the Bankruptcy Court denied U.S. Coating's motion to 
vacate the 25 April 2012 order. The Bankruptcy Court found that U.S. Coating, through 
3 

counsel, "sign[ ed] off' on the simple and unambiguous order. Although the Bankruptcy 
Court did not doubt Mr. Washington's testimony, the Bankruptcy Court determined that 
it was about the "aftermath of the rejection" and was insufficient to meet the standard to 
set aside an order under FED. R. C1v. P. 60(b)(l) or 60(b)(6). The Bankruptcy Court did 
not address the propriety of the termination of the contract for default. The Bankruptcy 
Court noted that U.S. Coating retained its rights under the contract, but questioned the 
court's authority to adjudicate such matters in light of Stern v. Marshall, 131 S. Ct. 2594 
(2011), and suggested that U.S. Coating would need to pursue its rights in other fora. 
(R4, tab 20 at 47-49) The same day, following the hearing, the Bankruptcy Court issued 
a written Final Judgment denying U.S. Coating's motion to vacate for the reasons stated 
in open court (R4, tab 19). 
13. On 20 July 2012, U.S. Coating filed a timely notice of appeal from the· 
termination of the contract for default, which the Board docketed as ASBCA No. 58245. 
14. On 15 February 2013, the government filed its initial motion to dismiss or, in 
the alternative, for summary judgment. 
15. On 31July2013, with leave ofthe Board, U.S. Coating filed an amended 
complaint. Appellant's amended complaint alleges 
racial animus on behalf of the 
contracting officer, and that the termination of the contract for default was contrary to the 
parties' agreement that the Corps would terminate the contract for convenience and 
which led to the 25 April 2012 Bankruptcy Court order (am. compl. iii! 7-9, 16-20). 
Appellant therefore seeks to convert the default termination to a termination for the 
convenience of the government (am. compl. iJ 22). In addition, appellant's amended 
complaint asserts numerous affirmative claims seeking unspecified monetary damages, 
including, but not limited to: breach of contract, tortious interference with business 
and/or contractual relations, violations of the Fourteenth Amendment and the civil rights 
statutes ( 42 U .S.C. §§ 1981, 1983, 1985, 1986), negatively impacting the project 
schedule, and adding unnecessary costs to the project (am. compl. iii! 23-48). 
16. In light of the amended complaint, the government filed an amended motion 
to dismiss or, in the alternative, for summary judgment. Appellant opposed the amended 
motion, and the government filed a reply. 
17. Appellant submitted the affidavits, under penalty of perjury, of 
Mr. Washington, Ms. Velma Day, and Mr. Alden Brooks with its opposition to the 
government's motion. Mr. Washington and Mr. Brooks stated that discussions 
concerning terminating the contract for convenience took place on 24 April 2012 between 
themselves and counsel for the parties. (App. opp'n, exs. A, B, D) Mr. Brooks stated 
that he understood the parties to have agreed to terminate the contract for convenience 
(app. opp'n, ex. D). Mr. Washington stated that his consent to the subsequent order was 
based upon the Corps' termination of U.S. Coating's contract for convenience 
(app. opp'n, ex. A). 
4 

DECISION 
Jurisdiction 
The government argues that the appeal should be dismissed because the 
"Amended Complaint has failed to appeal or even mention a contracting officer's 
Decision" (gov't am. mot. at 5). The Board's jurisdiction under the CDA is predicated 
upon either a contracting officer's decision on, or deemed denial of, a written claim by 
the contractor or a contracting officer's decision asserting a government claim against the 
contractor. 41 U.S.C. § 7103; Connectec Co., ASBCA No. 57546, 11-2 BCA, 34,797 at 
171,258. Accordingly, we have held that it is the claim, not the complaint, that 
determines the Board's jurisdiction. Puget Sound Environmental Corp., ASBCA 
Nos. 58827, 58828, 14-1BCA,35,585 at 174,371; Alderman Building Co., ASBCA 
No. 58082, 13 BCA, 35,381at173,619; see also Lockheed Martin Aircraft Center, 
ASBCA No. 55164, 07-1 BCA, 33,472 at 165,933 ("The scope of the appeal, and our 
jurisdiction, are determined 'by the parameters of the claim, the [contracting officer's] 
decision thereon, and the contractor's appeal therefrom."') (citations omitted). It is well 
settled that a termination for default is a government claim. Malone v. United States, 849 
F.2d 1441, 1443 (Fed. Cir. 1988); Amina Enterprise Group, LTD, ASBCA Nos. 58547, 
58548, 13 BCA, 35,376 at 173,580. U.S. Coating timely appealed the contracting 
officer's final decision terminating the contract for default (SOF, 13). The Board 
therefore has jurisdiction to consider the propriety of the government claim for default 
termination. 
The affirmative claims asserted in U.S. Coating's amended complaint are another 
matter. The parties debate the Board's jurisdiction over the various types of claims 
asserted in appellant's amended complaint (SOF, 15; gov't am. mot. at 5; app. opp'n at 
5-8). We do not reach those issues. The linchpin of the Board's jurisdiction over a 
contractor claim is the contractor's submission of its claim to the contracting officer for 
decision. MACH II, ASBCA No. 56630, 10-1 BCA, 34,357 at 169,673. The Board 
lacks jurisdiction over claims raised for the first time on appeal. Optimum Services, Inc., 
ASBCA No. 57575, 13 BCA, 35,412 at 173,726; The Public Warehousing Co., ASBCA 
No. 56022, 11-2 BCA, 34,788 at 171,227. Appellant's amended complaint asserts 
various affirmative claims for which it seeks unspecified damages (SOF , 15). There is 
no evidence that U.S. Coating submitted any of its affirmative claims, stated in a sum 
certain or otherwise, to the contracting officer for decision. U.S. Coating's failure to do 
so deprives the Board of jurisdiction to consider these claims. Accordingly, we strike 
paragraphs 23 through 48 of appellant's amended complaint. 
The Bankruptcy Court's Rejection of the Contract 
The remainder of the government's amended motion to dismiss focuses on the 
Bankruptcy Court's rejection of the contract. The government's amended motion is 
5 

largely premised on its interpretation of appellant's amended complaint as contending 
that "Appellant did not reject the contract during bankruptcy proceedings" and that "the 
25 April 2012 Order and 17 May 2012 Final Judgment are invalid." (Gov't am. mot. at 
6, 8) The government argues that the Bankruptcy Court has exclusive jurisdiction to 
consider assumption or rejection of executory contracts (gov't am. mot. at 8-9). The 
government further argues appellant is precluded from relitigating the issue of rejection 
of the contract under the doctrines of collateral estoppel and res judicata (gov't 
am. mot. at 9-11 ). 
The government's arguments miss the mark.* Although the amended complaint is 
not a model of clarity, the government's premise that appellant is challenging the validity 
of the Bankruptcy Court's rejection of the contract finds no support in the language of the 
amended complaint. We do not read appellant's amended complaint as challenging the 
validity of the Bankruptcy Court's rejection of the contract. We read the allegations in 
the amended complaint regarding the circumstances leading to the Bankruptcy Court's 
order rejecting the contract to be in rebuttal to the contention in the default termination 
letter that appellant repudiated the contract. We therefore do not address the 
government's arguments that appellant may not challenge the validity of the Bankruptcy 
Court's Order rejecting the contract, because appellant does not make such a challenge. 
The Government's Summary Judgment Motion 
The government maintains that it is entitled to summary judgment on the basis of 
anticipatory repudiation (gov't am. mot. at 11-13). Appellant argues that summary 
judgment is inappropriate because no discovery has taken place (app. opp'n at 9). We 
evaluate the government's motion for summary judgment under the well-settled standard 
that summary judgment is properly granted only where the moving party has met its 
burden of establishing the absence of any genuine issue of material fact and the moving 
party is entitled to judgment as a matter of law. Mingus Constructors, Inc., 812 F.2d 
1387, 1390 (Fed. Cir. 1987). In the course of our evaluation, the Board's role is not '"to 
weigh the evidence and determine the truth of the matter,' but rather to ascertain whether 
material facts are disputed and whether there exists any genuine issue for trial." Holmes 
& Narver Constructors, Inc., ASBCA Nos. 52429, 52551, 02-1BCAif31,849 at 157,393 
(quoting Anderson v. Liberty Lobby, Inc., 477 U.S. 242, 249 (1986)), aff'd, 57 F. App'x 
870 (Fed. Cir. 2003). A material fact is one which may make a difference in the outcome 
of the case. Liberty Lobby, 477 U.S. at 248. A dispute is genuine only if, on the entirety 
* The government appears to conflate the rejection of a contract with the termination of a 
contract; however, rejection and termination are distinct concepts. See Thompkins 
v. Lil' Joe Records, Inc., 476 F.3d 1294, 1306 (11th Cir. 2007); Med. Malpractice 
Ins. Assoc. v. Hirsch (In re Lavigne), 114 F.3d 379, 386-87 (2nd Cir. 1997); 
Eastover Bank/or Savings v. Sowashee Venture (In re Austin Dev. Co.), 19 F.3d 
1077, 1082 (5th Cir. 1994). 
6 

of the record, a reasonable factfinder could resolve a factual matter in favor of the 
nonmovant. Sweats Fashions, Inc. v. Pannill Knitting Co., 833 F.2d 1560, 1562 
(Fed. Cir. 1987). All significant doubt over factual issues must be resolved in favor of 
the party opposing summary judgment. Mingus, 812 F.2d at 1390. "Under summary 
judgment procedures 'it is usually necessary for the nonmoving party to have an adequate 
opportunity for discovery, and summary judgment should not be granted where the 
nonmovant has been denied the chance to discover information essential to its 
opposition."' Coronet 
Machinery Corp., ASBCA Nos. 55645, 
56899, 09-2 BCA 
, 34,306 at 169,464 (quoting Environmental Chemical Corp., ASBCA No. 54141, 05-1 
BCA, 32,938 at 163,176). 
A termination for default is a type of forfeiture and is strictly construed. AEON 
Group, LLC, ASBCA Nos. 56142, 56251, 14-1BCA,35,692 at 174,752. The 
government bears the initial burden of proof that a default termination was justified. 
Lisbon Contractors, Inc. v. United States, 828 F.2d 759, 764-65 (Fed. Cir. 1987); 
Free & Ben, Inc., ASBCA No. 56129, 11-1BCA,34,719 at 170,952. If the government 
satisfies its burden of proving that the termination for default was justified, the burden 
shifts to the contractor to establish that its default was excusable or caused by the 
government's material breach, or that the contracting officer's termination decision was 
arbitrary, capricious, or an abuse of discretion. Lan-Cay, Inc., ASBCA No. 56140, 12-1 
BCA, 34,935 at 171,761; Dae Shin Enterprises, Inc., d/b/a Dayron, ASBCA No. 50533, 
03-1BCA,32,096 at 158,646. 
In the event of an anticipatory repudiation, the government has a summary right to 
terminate a contract for default. C.H. Hyperbarics, Inc., ASBCA No. 49375 et al., 
04-1 BCA, 32,568 at 161,140; Bison Trucking & Equip. Co., ASBCA No. 53390, 
01-2 BCA, 31,654 at 156,385. In order to demonstrate anticipatory repudiation, the 
government must show that the contractor "communicated an 'intent not to perform in a 
positive, definite, unconditional and unequivocal manner,' either by unequivocal 
statements of refusal to perform, or by actions amounting to actual abandonment of 
performance." Bulova Technologies Ordnance Systems LLC, ASBCA No. 57406, 14-1 
BCA, 3 5,521 at 174,100 (quoting Troy Eagle Group, ASBCA No. 5644 7, 13 BCA 
, 35,258 at 173,061). 
Under bankruptcy law, a debtor "may assume or reject any executory contract." 
11 U.S.C. § 365(a). "[T]he authority to reject an executory contract is vital to the basic 
purpose of a Chapter 11 reorganization." Century lndem. Co. v. Nat 'l Gypsum Co. 
Settlement Trust (In re Nat'l Gypsum Co.), 208 F.3d 498, 504 (5th Cir. 2000) (quoting 
NLRB v. Bi/disco & Bi/disco, 465 U.S. 513, 528 (1984)) (alteration in original). 
Rejection of an executory contract "relieves the debtor of burdensome future obligations 
while he is trying to recover financially." First Ave. W Bldg., LLC v. James (In re 
Onecast Media, Inc.), 439 F.3d 558, 563 (9th Cir. 2006) (citations omitted); see also 
Lewis Bros. Bakeries Inc. & Chi. Baking Co. v. Interstate Brands Co. (In re Interstate 
Bakeries Corp.), 751F.3d955, 961 (8th Cir. 2014) ("Rejection frees the estate from the 
7 

obligation to perform under the contract") (citation and internal quotation marks omitted). 
Thus, the authority to reject is a "power to breach" the executory contract. In re Austin 
Dev. Co., 19 F.3d at 1082. 
The government cites Thomas & Sons Building Contractors, Inc., ASBCA 
No. 53395, 05-2 BCA if 33,083, for the proposition that the rejection of the contract 
during the bankruptcy proceedings was anticipatory repudiation of the contract. In 
Thomas & Sons, the contractor had stopped work months prior to filing for bankruptcy. 
05-2 BCA if 33,083 at 163,988-89. During the bankruptcy proceedings, the contractor 
denied that it had any executory contracts, did not assume its government contract, and 
expressly rejected, in its reorganization plan, any executory contract that had not been 
previously assumed. Id We held that through these actions, the contractor manifested a 
positive, definite, unconditional and unequivocal intent not to render performance 
justifying the government's termination for default. Id. at 163,989-90. 
In this appeal, the parties do not dispute that the Bankruptcy Court's 25 April 2012 
order rejected the contract (SOF if 8). Nor can U.S. Coating genuinely dispute, as the 
Bankruptcy Court found, that it consented to the order rejecting the contract (SOF if 12), and 
thus communicated that it was freeing itself from the obligation to perform under the 
contract. In re Interstate Bakeries Corp., 751 F.3d at 961. However, "the default clause 
does not require the Government to terminate on a finding of a bare default but merely gives 
the agency the discretion to do so." The Ryan Co., ASBCA No. 48151, 00-2 BCA if 31,094 
at 153,543, recon. denied, 01-1BCAif31,151; see also Radar Devices, Inc., ASBCA No. 
43912, 99-1BCAif30,223 at 149,528 ("The default clause does not mandate termination; it 
merely gives the contracting officer the discretion to terminate for default."). The 
contracting officer's discretion to terminate for default "is not unfettered," Radar Devices, 
99-1BCAif30,223 at 149,528 (citations omitted), and "the exercise of that discretion must 
be fair and reasonable, not arbitrary or capricious," Darwin Constr. Co. v United States, 
811 F.2d 593, 597 (Fed. Cir. 1987) (citations omitted). 
Here, unlike the contractor in Thomas & Sons, U.S. Coating had filed a motion to 
assume its contract (SOF if 7). The Bankruptcy Court's 25 April 2012 order rejecting the 
contract as a matter of law stemmed from the parties' settlement of Travelers' motion to 
compel rejection, the government's response in support thereof, and U.S. Coating's motion 
to assume (SOF if 8). Appellant maintains that the settlement was based upon an 
agreement that the government would terminate the contract for convenience (app. opp'n at 
4), and has offered the sworn affidavits of Mr. Washington and Mr. Brooks in support 
(app. opp'n, exs. A, D). The contracting officer terminated the contract for default due to 
appellant's consent to rejecting the contract in bankruptcy (SOF if 9); however, whether 
this was a proper exercise of her discretion is called into question if, as appellant alleges, 
its consent to the rejection of the contract was based upon an agreement with the 
government to terminate the contract, not for default, but for convenience. It remains to be 
seen whether appellant can prove the existence of such an agreement to terminate the 
contract for convenience. However, absent discovery and further development of the 
8 

record, summary judgment is premature. See GAP Instrument Corp., ASBCA No. 55041, 
06-2 BCA ~ 33,375 at 165,458 ("an adequate opportunity for discovery must usually 
precede summary judgment") (citing Burnside-Ott Aviation Training Ctr., Inc. v. United 
States, 985 F.2d 1574, 1582 (Fed. Cir. 1993)). 
CONCLUSION 
The Board lacks jurisdiction to consider the affirmative claims raised by appellant 
and we therefore strike paragraphs 23 through 48 of appellant's amended complaint. The 
remainder of the government's amended motion to dismiss or, in the alternative, for 
summary judgment is denied. 
Dated: 9 April 2015 
concur 
/~~/7£--:i_ 
/MARK N. STEMP~ 
Administrative Judge 
Acting Chairman 
Armed Services Board 
of Contract Appeals 
'/~ ~c ~KINSON. 
Administrative Judge 
Armed Services Board 
of Contract Appeals 
I concur 
RICHARD SHACKLEFORD 
Administrative Judge 
Vice Chairman 
Armed Services Board 
of Contract Appeals 
I certify that the foregoing is a true copy of the Opinion and Decision of the 
Armed Services Board of Contract Appeals in ASBCA No. 58245, Appeal of U.S. 
Coating Specialties & Supplies, LLC, rendered in conformance with the Board's Charter. 
Dated: 
9 
JEFFREY D. GARDIN 
Recorder, Armed Services 
Board of Contract Appeals