Source document: https://docs-lawep.s3.us-east-2.amazonaws.com/1697632155035.pdf (Antigua and Barbuda)
BILLS OF QUANTITIES ST. MARYS SECONDARY SCHOOL – Phase 2 VOLUME 1 FOR MINISTRY OF EDUCATION GOVERNMENT OF ANTIGUA & BARBUDA ARCHITECT MECHANICAL/ELECTRICAL MOULTON MAYERS ARCHITECTS MCKIES HILL KINGSTON ST. VINCENT SYLVESTER ENGINEERING LIMITED #30A VIERRA DRIVE CHAMPS FLEUR KINGSTON ST. VINCENT & THE GRENADINES TEL: (784) 457-2072 FAX: (784) 457-2290 TEL: (868) 662-7935 FAX: (784) 456-1207 STRUCTURAL ENGINEERS QUANTITY SURVEYORS ADDISON WORKMAN ENGINEERING WEATHERRILLS ROAD ST. JOHN’S ANTIGUA & BARBUDA TEL: (268) 462-3700 FAX: (268) 461-1459 DESIGN COLLABORATIVE “LAURISTON” COLLYMORE ROCK ST. MICHAEL BARBADOS TEL: (246) 426-1741 FAX: (246) 429-4595 NOVEMBER 2018 P R O C U R E M E N T D O C U M E N T S vii Bidding Document for Procurement of Small Works Procurement of: ALTERATIONS AND EXTENSIONS TO ST. MARY'S SECONDARY SCHOOL – PHASE 2 Issued on: 24th November, 2018 Employer: MINISTRY OF EDUCATION GOVERNMENT OF ANTIGUA & BARBUDA Country: Antigua & Barbuda ix Preface This Bidding Document for Procurement of Small Works has been prepared by [Executing Agency] and is based on the Standard Bidding Document for Procurement of Small Works issued by the Caribbean Development Bank, dated April 2008.
This document reflects the structure and the provisions of the Master Document for the Procurement of Small Works, prepared by Multilateral Development Banks and International Financing Institutions, except where specific considerations within the respective institutions have required a change.
GOVERNMENT OF ANTIGUA AND BARBUDA MINISTRY OF EDUCATION ANTIGUA AND BARBUDA BASIC EDUCATION PROJECT II (BEPII) ST. MARY’S SECONDARY SCHOOL PHASE 2 INVITATION TO BID - WORKS The Government of Antigua and Barbuda (GOAB) has received financing from the Caribbean Development Bank (CDB) towards the cost of the Basic Education Project II (BEPII) and intends to apply a portion of the proceeds of this financing to eligible payments under this contract.
Payment by CDB will be made only at the request of GOAB and upon approval by CDB, and will be subject, in all respects, to the terms and conditions of the Financing Agreement.

The Financing Agreement prohibits withdrawal from the financing account for the purpose of any payment to persons or entities, or for any import of goods, if such payment or import, to the knowledge of CDB, is prohibited by a decision of the United Nations Security Council taken under Chapter VII of the Charter of the United Nations.
No party other than GOAB shall derive any rights from the Financing Agreement or have any claim to the proceeds of the Financing.

BEPII is being implemented by the Ministry of Education through its Planning Unit.

The overall objective of the contract is the enhancement of the learning environment at the St. Mary’s Secondary School in Antigua through expansion and upgrades.

The Ministry of Education has contracted Consultants who will assist the Ministry with delivering the contract.
The Consultants have prepared designs and bid documentation for this contract and will assist in bid administration and evaluation and construction supervision.

The Ministry of Education, Planning Unit, now invites sealed bids from eligible bidders for the Antigua and Barbuda Basic Education Project II (BEPII): St. Mary’s Secondary School Phase 2.

The works include, but are not limited to the following: a.
Construction of two new building blocks featuring classrooms, administration spaces, restrooms, circulation systems, underwater storage cistern and other specialized spaces.

b.

The upgrade and rehabilitation of existing spaces within the school.

c. Civil works to the site to include drainage, sanitation and parking.
Consideration will be limited to firms or joint ventures of firms, which are legally incorporated or otherwise organised in, and have their principal place of business in an eligible country and are either: (a) more than 50% beneficially owned by a citizen or citizens and/or a bona fide resident or residents of an eligible country, or by a body corporate or bodies corporate meeting these requirements; or (b) owned or controlled by the government of an eligible country provided that it is legally and financially autonomous and operated under the commercial law of an eligible country and otherwise meets the eligibility requirements of the CDB Guidelines for Procurement (2006).
Eligible countries are member countries of CDB.

Eligible bidders will be required to submit full qualification information with their bids establishing their eligibility to bid and qualification to perform the contract if the bid is accepted.

Bid and qualification information are to be submitted in the English language on the prescribed forms inserted in the Bidding Documents.
Submissions that do not provide the information required, or do not demonstrate the prospective contractor’s ability to perform satisfactorily, will not qualify and will not be considered for further evaluation.
Qualification requirements include, inter alia: (a) an average annual turnover (defined as certified payments received for works in progress or completed) within the last five (5) years of USD1,260,000 (b) a demonstrable cash flow (including access to credit) of USD222,000 per month; and - 2 - (c) experience as prime contractor in the construction of at least one (1) assignments of a nature, scope and complexity comparable to the proposed project activity within the last six (6) years valuing USD1,220,000 or greater.
(To comply with this requirement, works quoted should be at least 80 percent complete).

Bidding Documents (electronic copies in pdf.

format) may be obtained by eligible bidders from the first address below at no cost.

Alternatively, the Bidding Documents can be downloaded from the website listed below.
Hard copy submissions in sealed envelopes clearly marked “Bid for the Antigua and Barbuda BEPII: St. Mary’s Secondary School Phase 2”, must be received at the first address below not later than 2:00pm on Friday 7th June, 2019.

Bid opening will take place immediately after the deadline for submission at the first address below in the presence of bidders’ representatives who choose to attend.

Qualification information only must be simultaneously submitted to the second address below.
All bids must be accompanied by a signed Bid Declaration Document.

Late bids will be rejected.

GOAB reserves the right to accept or reject any bid, and to annul the process and reject all bids, at any time prior to award of contract, without thereby incurring any liability to the affected prospective bidder(s) or any obligation to inform the affected prospective bidder(s) of the grounds for GOAB action.

GOAB will not defray any costs incurred by any bidder in the preparation of bids.

1.
1.

Address for Bid Submission and Bid Opening Antigua and Barbuda Tender’s Board Ministry of Finance and Corporate Governance Parliament Drive Government Office Complex St. John’s ANTIGUA & BARBUDA Tel.

+268-562-5825/26 Fax.

+268-562-1717 Email: tenders.board@ab.gov.ag 2.

Address for Completed Qualification Information Only Procurement Officer Procurement Policy Unit Caribbean Development Bank P.O.

Box 408, Wildey St. Michael BARBADOS.

W.I.

Tel.

+246-431-1600 Fax.


+246-426-7269 Email: procurement@caribank.org.
WEBSITE TO OBTAIN BID DOCUMENTS: www.moest-antigua.org xi Standard Bidding Document Table of Contents PART 1 – Bidding Procedures………………………………………………………………1 Section I – Instructions to Bidders…………………………………………………………….3 Section II – Bid Data Sheet (BDS)…………………………………………………......……27 Section III – Evaluation and Qualification Criteria………………………………………….33 Section IV – Bidding Forms…………………………………………………………………43 Section V – Eligible Countries………………………………………………………………69 PART 2 – Employer’s Requirements………………………………………………………1 Section VI – Employer’s Requirements………………………………………………………3 PART 3 – Conditions of Contract and Contract Forms…………………………………..1 Section VII – General Conditions of Contract……………………………………………..…3 Section VIII – Particular Conditions of Contract……………………………………………29 Section IX – Contract Forms………………………………………………………………...35 .
1-1 PART 1 – Bidding Procedures 1-3 Section 1 - Instructions to Bidders Table of Clauses A. General……………………………………………………………………………..5 1.

Scope of Bid……………………………………………………………………….5 2.

Source of Funds…………………………………………………………………...5 3.

Fraud and Corruption……………………………………………………………...5 4.

Eligible Bidders…………………………………………………………………...7 5.

Eligible Goods and Services………………………………………………………8 B.

Contents of Bidding Document…………………………………………...………9 6.

Sections of Bidding Document…………………………………………………...9 7.
Clarification of Bidding Document, Site Visit, Pre-Bid Meeting……………….10 8.

Amendment of Bidding Document………………………………………………11 C. Preparation of Bids……………………………………………………………….11 9.

Cost of Bidding………………………………………………………………..…11 10.

Language of Bid…………………………………………………………………11 11.

Documents Comprising the Bid…………………………………………………12 12.

Letter of Bid and Schedules……………………………………………………..12 13.

Alternative Proposals…………………………………………………………….12 14.

Bid Prices and Discounts………………………………………………………...13 15.
Currencies of Bid and Payment………………………………………………….14 16.

Documents Establishing the Qualifications of the Bidder………………………14 17.

Documents Establishing the Eligibility of the Goods and Services……………..15 18.

Period of Validity of Bids……………………………………………………….15 19.

Bid Security……………………………………………………………………...15 20.

Format and Signing of Bid………………………………………………………17 D. Submission and Opening of Bids………………………………….……………..18 21.

Sealing and Marking of Bids…………………………………………………….18 22.
Deadline for Submission of Bids……………………………………………...…18 23.

Late Bids…………………………………………………………………………19 24.

Withdrawal, Substitution, and Modification of Bids…………………………….19 25.

Bid Opening……………………………………………………………………...19 1-4 Section I - Instructions to Bidders E. Examination of Bids……………………………………………………….…....20 26.

Confidentiality…………………………………………………………………20 27.

Clarification of Bids……………………………………………………………21 28.


Determination of Responsiveness………………………………………………21 F. Bid Evaluation and Comparison……………………………………………….23 29.

Correction of Arithmetical Errors…………………………………………...….23 30.

Conversion of Single Currency…………………………………………………23 31.

Bid Adjustment…………………………………………………………………23 32.

Qualification of Bidder…………………………………………………………24 33.

Employer’s Right to Accept Any Bid, and to Reject Any or All Bids…………24 G. Award of Contract……………………………………………………………….24 34.
Award Criteria…………………………………………………………………..24 35.

Notification of Award…………………………………………………………..25 36.

Signing of Contract……………………………………………………………..25 37.

Performance Security…………………………………………………………...26 Section I - Instructions to Bidders 1-5 Section I - Instructions to Bidders 1.

Scope of Bid 2.

Source of Funds 3.

Fraud and Corruption A.


General 1.1 The Employer, as indicated in Section II, Bid Data Sheet (BDS), issues this Bidding Document for the procurement of the Works as specified in Section VI Requirements.

The name, identification, and number of lots provided in the BDS.

1.2 Unless otherwise stated, throughout this Bidding Document, definitions and interpretations shall be as prescribed in Section VII, General Conditions.
2.1 The Recipient of CDB Financing (hereinafter called “Recipient”) indicated in the BDS has applied for or received financing (hereinafter called “funds”) from the Caribbean Development Bank (hereinafter called “the Bank”) toward the cost of the project named in the BDS.

The Recipient intends to apply a portion of the funds to eligible payments under the contract(s) for which this Bidding Document is issued.
2.2 Payments by the Bank will be made only at the request of the Recipient and upon approval by the Bank in accordance with the terms and conditions of the financing agreement between the Recipient and the Bank (hereinafter called the Loan Agreement), and will be subject in all respects to the terms and conditions of that Loan Agreement.

No party other than the Recipient shall derive any rights from the Loan Agreement or have any claim to the funds.
3.1 The Bank requires that Recipients (including beneficiaries of Bank loans), as well as Bidders, Suppliers, Contractors, and Consultants under Bank-financed contracts, observe the highest standard of ethics during the procurement and execution of such contracts.
In pursuance of this policy, the Bank: (a) defines, for the purposes of this provision, the terms set forth below as follows: (i) “corrupt practice” means the offering, giving, receiving, or soliciting, directly or indirectly, of anything of value to influence the action of a public official in the procurement process or in contract execution; (ii) “fraudulent practice” means a misrepresentation or omission of facts in order to influence a procurement 1-6 Section I - Instructions to Bidders process or the execution of a contract; (iii) (iv) “collusive practice” means a scheme or arrangement between two or more bidders, with or without the knowledge of the Recipient, designed to establish bid prices at artificial, non-competitive levels; and “coercive practices” means harming or threatening to harm, directly or indirectly, persons or their property to influence their participation in a procurement process or affect the execution of a contract; (b) will reject a proposal for award if it determines that the Bidder recommended for award has, directly or through an agent, engaged in corrupt, fraudulent, collusive or coercive practices in competing for the Contract in question; (c) will cancel the portion of the loan allocated to a contract if it determines at any time that representatives of the Recipient or of a beneficiary of the loan engaged in corrupt, fraudulent, collusive or coercive practices during the procurement or the execution of that contract, without the Recipient having taken timely and appropriate action satisfactory to the Bank to remedy the situation; (d) will sanction a firm or individual, including declaring them ineligible, either indefinitely or for a stated period of time, to be awarded a Bank-financed contract if it at any time determines that they have, directly or through an agent, engaged in corrupt, fraudulent, collusive or coercive practices in competing for, or in executing, a Bank-financed contract; and (e) will have the right to require that a provision be included in Bidding Documents and in contracts financed by CDB, requiring bidders, suppliers, contractors and consultants to permit the Bank to inspect their accounts and records and other documents relating to the Bid submission and contract performance and to have them audited by auditors appointed by the Bank.
3.2 Furthermore, Bidders shall be aware of the provisions of GCC Sub-Clauses 22.2 and 56.2(h).

4.

Eligible Bidders 4.1 A Bidder may be a natural person, private entity, or government- owned entity — subject to ITB 4.5 — or any combination of such entities supported by a letter of intent to enter into an agreement or under an existing agreement in the form of a joint venture, consortium, or association (JVCA).
In the case of a JVCA: (a) unless otherwise specified in the BDS, all partners shall be Section I - Instructions to Bidders 1-7 jointly and severally liable, and (b) the JVCA shall nominate a Representative who shall have the authority to conduct all business for and on behalf of any and all the partners of the JVCA during the bidding process and, in the event the JVCA is awarded the Contract, during contract execution.
4.2 A Bidder, and all parties constituting the Bidder, shall have the nationality of an eligible country, in accordance with Section 5 (Eligible Countries).

A Bidder shall be deemed to have the nationality of a country if the Bidder is a citizen or is constituted, incorporated, or registered and operates in conformity with the provisions of the laws of that country.
This criterion shall also apply to the determination of the nationality of proposed subcontractors or suppliers for any part of the Contract including Related Services.

4.3 A Bidder shall not have a conflict of interest.

All Bidders found to have a conflict of interest shall be disqualified.
A Bidder may be considered to have a conflict of interest with one or more parties in this bidding process, if: (a) they have a controlling partner in common; or (b) they receive or have received any direct or indirect subsidy from any of them; or (c) they have the same legal representative for purposes of this bid; or (d) they have a relationship with each other, directly or through common third parties, that puts them in a position to have access to information about or influence on the Bid of another Bidder, or influence the decisions of the Employer regarding this bidding process; or (e) a Bidder participates in more than one bid in this bidding process.
Participation by a Bidder in more than one Bid will result in the disqualification of all Bids in which it is involved.
However, this does not limit the inclusion of the same subcontractor not otherwise participating as a Bidder, in more than one bid; or (f) a Bidder participated as a consultant in the preparation of the Section VI, Requirements that are the subject of the Bid; or (g) a Bidder, or any of its affiliates has been hired or is proposed to be hired by the Employer or Recipient for the supervision 1-8 Section I - Instructions to Bidders of the contract.
4.4 A firm that is under a declaration of ineligibility by the Bank at the date of the deadline for bid submission or thereafter, shall be disqualified.

4.5 Government-owned entities in the Recipient’s country shall be eligible only if they can establish that they (i) are legally and financially autonomous, (ii) operate under the principles of commercial law, and (iii) are not dependent agencies of the Employer.
4.6 Bidders shall provide such evidence of their continued eligibility satisfactory to the Employer, as the Employer shall reasonably request.
Firms shall be excluded if: (a) as a matter of law or official regulation, the Recipient’s country prohibits commercial relations with that country, provided that the Bank is satisfied that such exclusion does not preclude effective competition for the supply of goods or related services required; or (b) by an act of compliance with a decision of the United Nations Security Council taken under Chapter VII of the Charter of the United Nations, the Recipient’s country prohibits any import of goods or contracting of works or services from that country or any payments to persons or entities in that country.
5.

Eligible Goods and Services 5.1 All goods and services to be supplied under the Contract and financed by the Bank, shall have as their country of origin an eligible country of the Bank as listed in Section V, Eligible Countries.

5.2 For purposes of this Clause, includes commodities, raw material, machinery, equipment, and industrial plants; and services includes services such as insurance, transportation, installation, commissioning, training, and initial maintenance.
term goods the 5.3 The term “country of origin” means the country where the goods through have been mined, grown or produced when manufacturing, processing or substantial and major assembling of components, a commercially recognized new product results that is substantially different in basic characteristics or in purpose or utility from its components.
5.4 The nationality of the firm that produces, assembles, distributes or Section I - Instructions to Bidders 1-9 sells the goods shall not determine the origin of the goods.

Goods shall be considered to originate in a country if they meet the criterion of at least 50% by value derived from within that country.

B.

Contents of Bidding Document 6.


Sections of Bidding Document 6.1 The Bidding Document consist of Parts 1, 2, and 3, which include all the Sections indicated below, and should be read in conjunction with any Addenda issued in accordance with ITB 8.
PART 1 Bidding Procedures Section I - Instructions to Bidders (ITB) Section II - Bid Data Sheet (BDS) Section III - Evaluation and Qualification Criteria Section IV - Bidding Forms Section V - Eligible Countries PART 2 Requirements Section VI - Requirements PART 3 Conditions of Contract and Contract Forms Section VII - General Conditions (GCC) Section VIII - Particular Conditions (PCC) Section IX - Contract Forms 6.2 The Invitation for Bids issued by the Employer is not part of the Bidding Document.
6.3 The Bidder shall obtain the Bidding Document from the source stated by the Employer in the Invitation for Bids; otherwise the Employer is not responsible for the completeness of the Bidding Document.

6.4 The Bidder is expected to examine all instructions, forms, terms, and specifications in the Bidding Document.

Failure to furnish all information or documentation required by the Bidding Document may result in the rejection of the bid.

7.
7.

Clarification of Bidding Document, Site Visit, Pre-Bid Meeting the Employer in writing at 7.1 A prospective Bidder requiring any clarification of the Bidding Document shall contact the Employer’s address indicated in the BDS or raise his inquiries during the pre-bid meeting if provided for in accordance with ITB 7.4.
The Employer will respond in writing to any request for clarification, provided that such request is received prior to the deadline for submission of bids, within number of days specified in the BDS.

The Employer’s response shall be in writing with copies to all Bidders who have acquired the Bidding Document in accordance with ITB 6.3, including a description of the inquiry 1-10 Section I - Instructions to Bidders but without identifying its source.
Should the Employer deem it necessary to amend the Bidding Document as a result of a request for clarification, it shall do so following the procedure under ITB 8 and ITB 22.2.

7.2 Where applicable, the Bidder is advised to visit and examine the project site and obtain for itself, on its own responsibility, all information that may be necessary for preparing the bid and entering into a contract for provision of the Requirements.

The costs of visiting the Site shall be at the Bidder’s own expense.
7.3 Pursuant to ITB 7.2, where the Bidder and any of its personnel or agents have been granted permission by the Employer to enter upon its premises and lands for the purpose of such visit, the Bidder, its personnel, and agents will release and indemnify the Employer and its personnel and agents from and against all liability in respect thereof, and will be responsible for death or personal injury, loss of or damage to property, and any other loss, damage, costs, and expenses incurred as a result of the visit 7.4 The Bidder’s designated representative is invited to attend a pre- bid meeting, if provided for in the BDS.
The purpose of the meeting will be to clarify issues and to answer questions on any matter that may be raised at that stage.

If so provided in the BDS, the Employer will organize a site visit.

7.5 The Bidder is requested, as far as possible, to submit any questions in writing, to reach the Employer not later than one week before the meeting.
7.6 Minutes of the pre-bid meeting, including the text of the questions raised, without identifying the source, and the responses given, together with any responses prepared after the meeting, will be transmitted promptly to all Bidders who have acquired the Any Bidding Document modification that may become necessary as a result of the pre-bid meeting shall be made by the Employer exclusively through the issue of an Addendum pursuant to ITB 8 and not through the minutes of the pre-bid meeting.
in accordance with ITB 6.3. the Bidding Document to 8.

Amendment of Bidding Document 7.7 Non-attendance at the pre-bid meeting will not be a cause for disqualification of a Bidder.

8.1 At any time prior to the deadline for submission of bids, the Employer may amend the Bidding Document by issuing addenda.
8.2 Any addendum issued shall be part of the Bidding Document and shall be communicated in writing to all who have obtained the Section I - Instructions to Bidders 1-11 Bidding Document from the Employer in accordance with ITB 6.3.
8.3 To give prospective Bidders reasonable time in which to take an addendum into account in preparing their bids, the Employer may, at its discretion, extend the deadline for the submission of bids, pursuant to ITB 22.2 C. Preparation of Bids 9.1 The Bidder shall bear all costs associated with the preparation and submission of its Bid, and the Employer shall not be responsible or liable for those costs, regardless of the conduct or outcome of the bidding process.
10.1 The Bid, as well as all correspondence and documents relating to the bid exchanged by the Bidder and the Employer, shall be written in the language specified in the BDS.

Supporting documents and printed literature that are part of the Bid may be in another language provided they are accompanied by an accurate translation of the relevant passages in the language specified in the BDS, in which case, for purposes of interpretation of the Bid, such translation shall govern.

9.

Cost of Bidding 10.


Language of Bid 11.
Documents 11.1 The Bid shall comprise the following: Comprising the Bid (a) Letter of Bid; (b) Completed Schedules, as provided in Section IV, Bidding Forms; (c) Bid Security or Bid Securing Declaration, in accordance with ITB 19; (d) at the Bidder’s option, alternative proposals if permissible, in accordance with ITB 13; (e) written confirmation authorizing the signatory of the Bid to commit the Bidder, in accordance with ITB 20.2; (f) documentary evidence establishing the Bidder’s qualifications in accordance with the requirements of Section III, Evaluation and Qualification Criteria, using the relevant forms furnished in Section IV, Bidding Forms; (g) documentary evidence as specified in the BDS, establishing the conformity of the Technical Proposal offered by the Bidder with the Bidding Document, using the relevant forms furnished 1-12 Section I - Instructions to Bidders in Section IV, Bidding Forms; (h) In the case of a bid submitted by a JVCA, JVCA agreement, or letter of intent to enter into a JVCA including a draft agreement, indicating at least the parts of the Requirements to be executed by the respective partners; and (i) Any other document required in the BDS.
12.

Letter of Bid and Schedules 12.1 The Letter of Bid and Schedules shall be prepared using the relevant forms in Section IV, Bidding Forms.

The forms must be completed as indicated in each form 13.

Alternative Proposals 13.1 Unless otherwise indicated in the BDS, alternative proposals shall not be considered.

If alternative proposals are permitted, their method of evaluation shall be as stipulated in Section III, Evaluation and Qualification Criteria.
13.2 When alternative times for completion are explicitly invited, a statement to that effect will be included in the BDS, as will the method of evaluating different times for completion.
13.3 Except as provided under ITB 13.4 below, Bidders wishing to offer technical alternatives to the requirements of the Bidding Document must first price the Employer’s requirements as described in the Bidding Document and shall further provide all information necessary for a complete evaluation of the alternative including drawings, design calculations, by technical specifications, breakdown of prices, and proposed construction methodology and other relevant details.
Only the technical alternatives, if any, of the lowest evaluated Bidder technical requirements shall be the basic to conforming considered by the Employer.

the Employer, 13.4 When specified in the BDS, Bidders are permitted to submit alternative the Requirements and such parts will be identified in the BDS as will the method for their evaluation and described in Section VI, Requirements.

technical solutions for specified parts of 14.


Bid Prices and Discounts 14.1 The prices and discounts quoted by the Bidder in the Letter of Bid and in the Schedules shall conform to the requirements specified in ITB 14.2.

14.2 Unless otherwise provided in the BDS and the GCC, the prices quoted by the Bidder shall be fixed.
14.3 The Bidder shall submit a bid for the whole of the works described in ITB 1.1 by filling in prices for all items of the Section I - Instructions to Bidders 1-13 Works, as identified in Section IV, Bidding Forms.

In case of admeasurement contracts, the Bidder shall fill in rates and prices for all items of the Works described in the Bill of Quantities.
Items against which no rate or price is entered by the Bidder will not be paid for by the Employer when executed and shall be deemed covered by the rates for other items and prices in the Bill of Quantities.

14.4 The price to be quoted in the Letter of Bid shall be the total price of the Bid, excluding any discounts offered.
14.5 Unconditional discounts, if any, and the methodology for their application shall be quoted in the Letter of Bid, in accordance with ITB 12.1 14.6 If so indicated in ITB 1.1, bids are invited for individual contracts or for any combination of contracts (packages).

Bidders wishing to offer any price reduction for the award of more than one Contract shall specify in their bid the price reductions applicable to each package, or alternatively, to individual Contracts within the package.
Price reductions or discounts shall be submitted in accordance with ITB 14.4, provided the bids for all contracts are submitted and opened at the same time.

14.7 Unless otherwise provided in the BDS and the Conditions of Contract, the prices quoted by the Bidder shall be fixed.
If the prices quoted by the Bidder are not fixed in accordance with ITB 14.2 but are subject to adjustment during the performance of the Contract in accordance with the provisions of the Conditions of Contract, the Bidder shall furnish the indices and weightings for the price adjustment formulae in the Schedule of Adjustment Data in Section IV (Bidding Forms) and the Employer may require the Bidder to justify its proposed indices and weightings.
14.8 All duties, taxes, and other levies payable by the Contractor under the Contract, or for any other cause, as of the date 28 days prior to the deadline for submission of bids, shall be included in the rates and prices and the total bid price submitted by the Bidder.

15.1 The currency(ies) of the bid and the currency(ies) of payment shall be as specified in the BDS.
16.1 To establish its qualifications to perform the Contract, the Bidder shall provide the information requested in Section III (Evaluation and Qualification Criteria).

15.

Currencies of Bid and Payment 16.

Documents Establishing the Qualifications of the Bidder 1-14 Section I - Instructions to Bidders 17.

Documents Establishing the Eligibility of the Goods and Services 18.
Period of Validity of Bids 16.2 If so required in the BDS, a Bidder shall submit the Manufacturers Authorisation using the form included in Section IV, Bidding Forms, where the Bidder does not manufacture or produce the goods it offers to supply.
16.3 If so required in the BDS, a Bidder shall submit evidence that it will be represented by an agent in the country, equipped and able to carry out the supplier’s maintenance, repair and spare parts stocking obligations prescribed in the Conditions of Contract and requirements where a Bidder does not conduct business within the Employer’s country.
16.4 Regional Bidders, individually or in joint ventures, applying for eligibility for regional margin of preference shall supply all information required to satisfy the criteria for eligibility as described in ITB 33.

17.1 To establish the eligibility of the Good and Services in accordance with ITB 5, Bidders shall complete the forms included in Section IV, Bidding Forms.

18.1 Bids shall remain valid for the period specified in the BDS after the bid submission deadline date prescribed by the Employer.
A bid which is valid for a shorter period shall be rejected by the Employer as non-responsive.

18.2 In exceptional circumstances, prior to the expiration of the bid validity period, the Employer may request Bidders to extend the period of validity of their bids.

The request and the responses shall be made in writing.

If a bid security is requested in accordance with ITB 19, the bidder granting the request shall also extend the bid security for 28 days beyond the deadline of the extended validity period.
A Bidder may refuse the request without forfeiting its bid security.

A Bidder granting the request shall not be required or permitted to modify its bid except as provided in ITB 19.3.

18.3 In the case of fixed price contracts, if the award is delayed by a period exceeding fifty-six (56) days beyond the expiry of the initial bid validity, the Contract price shall be adjusted by a factor specified in the request for extension.
Bid evaluation shall be based on the Bid Price without taking into consideration the above correction.

19.

Bid Security 19.1 The Bidder shall furnish as part of its bid, the original of either a Bid-Securing Declaration or a bid security using the relevant form Section I - Instructions to Bidders 1-15 included in Section IV, Bidding Forms.

In the case of a bid security, the amount shall be as specified in the BDS.

19.2 A Bid Securing Declaration shall use the form included in Section IV Bidding Forms.
19.3 If a bid security is specified pursuant to ITB 19.1, the bid security shall be a demand guarantee, in any of the following forms at the Bidder’s option: (a) an unconditional guarantee, issued by a bank or surety; (b) an irrevocable letter of credit; or (c) a cashier’s or certified check.

from a reputable source from an eligible country.


If the unconditional guarantee is issued by an insurance company or bonding company located outside the Employer’s Country, the issuer shall have a correspondent financial institution located in the Employer’s Country to make it enforceable.
In the case of a bank guarantee, the bid security shall be submitted either using the Bid Security Form included in Section IV, Bidding Forms or in another substantially similar format approved by the Employer prior to bid submission.

In either case, the form must include the complete name of the Bidder.

The bid security shall be valid for twenty-eight days (28) beyond the original validity period of the bid, or beyond any period of extension if requested under ITB 18.2.
19.4 Any bid not accompanied by a substantially responsive bid security or Bid Securing Declaration , if required in accordance with ITB 19.1, shall be rejected by the Employer as non- responsive.

19.5 If a bid security is specified pursuant to ITB 19.1, the bid security of unsuccessful Bidders shall be returned as promptly as possible upon the successful Bidder’s furnishing of the performance security pursuant to ITB 41.
19.6 If a bid security is specified pursuant to ITB 19.1, the bid security of the successful Bidder shall be returned as promptly as possible once the successful Bidder has signed the Contract and furnished the required performance security.

19.7 The bid security may be forfeited or the Bid Securing Declaration executed: (a) if a Bidder withdraws its bid during the period of bid 1-16 Section I - Instructions to Bidders 20.
Format and Signing of Bid validity specified by the Bidder on the Letter of Bid or (b) if the successful Bidder fails to: (i) sign the Contract in accordance with ITB 40; or (ii) furnish a performance security in accordance with ITB 41.

19.8 The Bid Security or the Bid Securing Declaration of a JVCA shall be in the name of the JVCA that submits the bid.
If the JVCA has not been constituted into a legally-enforceable JVCA, at the time of bidding, the Bid Security or the Bid Securing Declaration shall be in the names of all future partners as named in the letter of intent mentioned in ITB 4.1.

20.1 The Bidder shall prepare one original of the documents comprising the bid as described in ITB 11 and clearly mark it “ORIGINAL”.

Alternative proposals, if permitted in accordance with ITB 13, shall be clearly marked “ALTERNATIVE”.
In addition, the Bidder shall submit copies of the bid in the number specified in the BDS, and clearly mark them “COPY.” In the event of any discrepancy between the original and the copies, the original shall prevail.

20.2 The original and all copies of the bid shall be typed or written in indelible ink and shall be signed by a person duly authorized to sign on behalf of the Bidder.

This authorization shall consist of a written confirmation as specified in the BDS and shall be attached to the bid.
The name and position held by each person signing the authorization must be typed or printed below the signature.

All pages of the bid where entries have been made shall be signed or initialled by the person signing the bid.
20.3 A bid submitted by a JVCA shall comply with the following requirements: (a) unless not required in accordance with ITB 4.1 (a), be signed so as to be legally binding on all partners; and (b) include the representatives authorization referred to in ITB 4.1 (b) consisting of a Power of Attorney signed by those legally authorised to sign on behalf of the JVCA.

20.4 Any amendments, interlineations, erasures, or overwriting shall be valid only if they are signed or initialled by the person signing the bid.
Section I - Instructions to Bidders 1-17 D. Submission and Opening of Bids 21.

Sealing and Marking of Bids 21.1 Bidders may always submit their bids by mail or by hand.

If so specified in the BDS, bidders shall have the option of submitting their bids electronically.
Procedures for submission, sealing and marking are as follows: (a) Bidders submitting bids by mail or by hand shall enclose the original and each copy of the Bid, including alternative bids, if permitted in accordance with ITB 13, in separate sealed envelopes, duly marking the envelopes as “ORIGINAL”, “ALTERNATIVE” and “COPY.” These envelopes containing the original and the copies shall then be enclosed in one single envelope.
The rest of the procedure shall be in accordance with ITB sub-Clauses 21.2 and 21.3.

(b) Bidders submitting bids electronically shall follow the electronic bid submission procedures specified in the BDS.
21.2 The inner and outer envelopes shall: (a) bear the name and address of the Bidder; (b) be addressed to the Employer in accordance with ITB 22.1; (c) bear the specific identification of this bidding process indicated in accordance with ITB 1.1; and (d) bear a warning not to open before the time and date for bid opening.

21.3 If envelopes and packages are not sealed and marked as required, the Employer will assume no responsibility for the misplacement or premature opening of the bid.

22.
22.

Deadline for 22.1 Bids must be received by the Employer at the address and no later Submission of Bids than the date and time indicated in the BDS.

23.

Late Bids 22.2 The Employer may, at its discretion, extend the deadline for the submission of bids by amending the Bidding Document in accordance with ITB 8, in which case all rights and obligations of the Employer and Bidders previously subject to the deadline shall thereafter be subject to the deadline as extended.
23.1 The Employer shall not consider any bid that arrives after the deadline for submission of bids, in accordance with ITB 22.

Any bid received by the Employer after the deadline for submission of bids shall be declared late, rejected, and returned unopened to the 1-18 Section I - Instructions to Bidders Bidder.

24.
24.

Withdrawal, Substitution, and Modification of Bids 24.1 A Bidder may withdraw, substitute, or modify its bid after it has been submitted by sending a written notice, duly signed by an authorized representative, and shall include a copy of the authorization that withdrawal notices do not require copies).

The corresponding substitution or modification of the bid must accompany the respective written notice.

All notices must be: in accordance with ITB 20.2, (except 25.
Bid Opening (a) prepared and submitted in accordance with ITB 20 and ITB 21 (except that withdrawal notices do not require copies), and in addition, the respective envelopes shall be clearly marked “Withdrawal,” “Substitution,” “Modification;” and (b) received by the Employer prior to the deadline prescribed for submission of bids, in accordance with ITB 22.

24.2 Bids requested to be withdrawn in accordance with ITB 24.1 shall be returned unopened to the Bidders.
24.3 No bid may be withdrawn, substituted, or modified in the interval between the deadline for submission of bids and the expiration of the period of bid validity specified by the Bidder on the Letter of Bid or any extension thereof.

25.1 The Employer shall conduct the bid opening in public in the presence of Bidders` designated representatives and anyone who choose to attend at the address, date and time specified in the BDS.
Any specific electronic bid opening procedures required if electronic bidding is permitted in accordance with ITB 21.1, shall be as specified in the BDS.

25.2 First, envelopes marked “WITHDRAWAL” shall be opened and read out and the envelope with the corresponding bid shall not be opened, but returned to the Bidder.

No bid withdrawal shall be permitted unless the corresponding withdrawal notice contains a valid authorization to request the withdrawal and is read out at bid opening.
Next, envelopes marked “SUBSTITUTION” shall be opened and read out and exchanged with the corresponding bid being substituted, and the substituted bid shall not be opened, but returned to the Bidder.

No bid substitution shall be permitted unless the corresponding substitution notice contains a valid authorization to request the substitution and is read out at bid opening.

Envelopes marked “MODIFICATION” shall be opened and read out with the corresponding bid.
No bid modification shall be permitted unless the corresponding modification notice contains a valid authorization to request the modification and is Section I - Instructions to Bidders 1-19 read out at bid opening.

Only envelopes that are opened and read out at bid opening shall be considered further.
25.3 The Employer shall open all other envelopes one at a time and read out: the name of the Bidder and the Bid Price(s), any discounts and their application methodology, alternative bids; the presence of a bid security or Bid-Securing Declaration; and any other details as the Employer may consider appropriate.

Only discounts and alternative offers read out at bid opening shall be considered for evaluation.
No bid shall be rejected at bid opening except for late bids, in accordance with ITB 23.1. if applicable, 25.4 The Employer shall prepare a record of the bid opening that shall include, as a minimum: the name of the Bidder and whether there is a withdrawal, substitution, or modification; the Bid Price, per including any discounts and alternative lot proposals; and the presence or absence of a bid security or a Bid- Securing Declaration.
The Bidders’ representatives who are present shall be requested to sign the record.

The omission of a Bidder’s signature on the record shall not invalidate the contents and effect of the record.

A copy of the record shall be distributed to all Bidders who submitted bids in time, and posted online when electronic bidding is permitted.
E. Examination of Bids 26.1 Information relating to the evaluation of bids shall not be disclosed to Bidders or any other persons not officially concerned with such process until information on Contract award is communicated to all Bidders.

26.2 Any attempt by a Bidder to influence improperly the Employer in the evaluation of the bids or Contract award decisions may result in the rejection of its bid.
26.3 Notwithstanding ITB 26.1, from the time of bid opening to the time of Contract award, if any Bidder wishes to contact the Employer on any matter related to the bidding process, it may do so in writing.

27.1 To assist in the examination, evaluation, and comparison of the bids, and qualification of the Bidders, the Employer may, at its discretion, ask any Bidder for a clarification of its bid allowing a reasonable time for response.
Any clarification submitted by a Bidder that is not in response to a request by the Employer shall not be considered.

The Employer’s request for clarification and the response shall be in writing.

No change in the prices or substance of the bid shall be sought, offered, or permitted, except 26.

Confidentiality 27.

Clarification of Bids 1-20 Section I - Instructions to Bidders 28.
Determination of Responsiveness to confirm the correction of arithmetic errors discovered by the Employer in the evaluation of the bids, in accordance with ITB 29.

27.2 If a Bidder does not provide clarifications of its bid by the date and time set in the Employer’s request for clarification, its bid may be rejected.

28.1 The Employer’s determination of a bid’s responsiveness is to be based on the contents of the bid itself, as defined in ITB 11.
28.2 A substantially responsive bid is one that meets the requirements of the Bidding Document without material deviation, reservation, or omission.
(a) “Deviation” is a departure from the requirements specified in the Bidding Document; (b) “Reservation” is the setting of limiting conditions or withholding from complete acceptance of the requirements specified in the Bidding Document; and “Omission” is the failure to submit part or all of the (c) information or documentation required in the Bidding Document.
28.3 A material deviation, reservation, or omission is one that, (a) if accepted, would: (i) (ii) affect in any substantial way the scope, quality, or performance of the Requirements as specified in Section VI; or limit in any substantial way, inconsistent with the Bidding Document, the Employer’s rights or the Bidder’s obligations under the proposed Contract; or (b) if rectified, would unfairly affect the competitive position of other Bidders presenting substantially responsive bids.
28.4 The Employer shall examine the technical aspects of the bid in particular, to confirm that all requirements of Section VI have been met without any material deviation, reservation or omission.

28.5 If a bid is not substantially responsive to the requirements of the Bidding Document, it shall be rejected by the Employer and may not subsequently be made responsive by correction of the material deviation, reservation, or omission.
Section I - Instructions to Bidders 1-21 28.6 Provided that a bid is substantially responsive, the Employer may waive any quantifiable non-conformities in the bid that do not constitute a material deviation, reservation or omission.

28.7 Provided that a bid is substantially responsive, the Employer may request that the Bidder submit the necessary information or documentation, within a reasonable period of time, to rectify non- material non-conformities in the bid related to documentation requirements.
Requesting information or documentation on such nonconformities shall not be related to any aspect of the price of the bid.

Failure of the Bidder to comply with the request may result in the rejection of its bid.

28.8 Provided that a bid is substantially responsive, the Employer shall rectify quantifiable non-material non-conformities related to the Bid Price.

To this effect, the Bid Price shall be adjusted, for comparison purposes only, to reflect the price of the non- conforming item or component.
The adjustment shall be made using the methodology indicated in Section III, Evaluation and Qualification Criteria.

F. Bid Evaluation and Comparison 29.

Correction of Arithmetical Errors 29.1 Provided that the bid is substantially responsive, the Employer shall correct arithmetical errors as indicated in Section III, Evaluation and Qualification Criteria.
29.2 If the Bidder does not accept the correction of errors, its bid shall be declared non-responsive and its Bid Security shall be forfeited or the Bid Securing Declaration executed.

30.

Conversion to Single Currency 30.1 For evaluation and comparison purposes, the currency(ies) of the bid shall be converted into a single currency as specified in Section III, Evaluation and Qualification Criteria.

31.
31.

Bid Adjustments 31.1 For the evaluation and comparison purposes the Employer shall adjust the bid prices using the criteria and methodology specified in Section III, Evaluation and Qualification Criteria.

31.2 Unless otherwise specified in the BDS, no regional margin of preference shall apply.

If a margin of preference applies, the application methodology shall be as specified in Section III, Evaluation and Qualification Criteria.
31.3 If in the opinion of the Employer the bid which results in the lowest Evaluated Bid Price, is seriously unbalanced or front loaded or substantially below th e Employer’s estimates , the Employer may require the Bidder to produce detailed price analyses for any or all items of the Bill of Quantities, to 1-22 Section I - Instructions to Bidders demonstrate the internal consistency of those prices with the methods and schedule proposed.
After evaluation of the price analyses, taking into consideration the schedule of estimated Contract payments, the Employer may require that the amount of the performance security be increased at the expense of the Bidder to a level sufficient to protect the Employer against financial loss in the event of default of the successful Bidder under the Contract.

32.
32.

Qualification of the Bidder 32.1 The Employer shall determine to its satisfaction whether the Bidder that is selected as having submitted the lowest evaluated and substantially responsive bid meets the qualifying criteria specified in Section III, Evaluation and Qualification Criteria.

32.2 The determination shall be based upon an examination of the documentary evidence of the Bidder’s qualifications submitted by the Bidder, pursuant to ITB 16.1.
32.3 An affirmative determination of qualification shall be a prerequisite for award of the Contract to the Bidder.

A negative determination shall result in disqualification of the bid, in which event the Employer shall proceed to the next lowest evaluated bid to make a similar determination of that Bidder’s qualifications to perform satisfactorily.
32.4 The capabilities of the manufacturers and subcontractors proposed in its Bid to be used by the lowest evaluated Bidder for identified major items of the Requirements will also be evaluated for acceptability in accordance with the criteria and methodologies defined in Section III, Evaluation and Qualification Criteria.

Their participation should be confirmed with a letter of intent between the parties, as needed.
Should a manufacturer or subcontractor be determined to be unacceptable, the Bid will not be rejected, but the Bidder will be required to substitute an acceptable manufacturer or subcontractor without any change to the bid price.

33.

Employer’s Right to Accept Any Bid, and to Reject Any or All Bids 33.1 The Employer reserves the right to accept or reject any bid, and to annul the bidding process and reject all bids at any time prior to contract award, without thereby incurring any liability to Bidders.
In case of annulment, all bids submitted and specifically, bid securities, shall be promptly returned to the Bidders.

G. Award of Contract 34.

Award Criteria 34.1 The Employer shall award the Contract to the Bidder whose offer has been determined to be the lowest evaluated bid and is substantially responsive to the Bidding Document, provided further that the Bidder is determined to be qualified to perform the Section I - Instructions to Bidders 1-23 Contract satisfactorily.

35.
35.

Notification of Award 35.1 Prior to the expiration of the period of bid validity, the Employer shall notify the successful Bidder, in writing, that its bid has been accepted.

35.2 Until a formal contract is prepared and executed, the notification of award shall constitute a binding Contract.
35.3 At the same time, the Employer shall also notify all other Bidders of the results of the bidding, and shall publish in UNDB online and in the Bank’s website the results identifying the bid and lot numbers and the following information: (i) name of each Bidder who submitted a Bid; (ii) bid prices as read out at bid opening; (iii) name and evaluated prices of each Bid that was evaluated; (iv) name of bidders whose bids were rejected and the reasons for their rejection; and (v) name of the winning Bidder, and the price it offered, as well as the duration and summary scope of the contract awarded.
After publication of the award, unsuccessful bidders may request in writing to the Employer for a debriefing seeking explanations on the grounds on which their bids were not selected.

The Employer shall promptly respond in writing to any unsuccessful Bidder who, after Publication of contract award, requests a debriefing.

36.

Signing of Contract 36.1 Promptly after notification, the Employer shall send the successful Bidder the Contract Agreement.
36.2 Within twenty-eight (28) days of receipt of the Contract Agreement, the successful Bidder shall sign, date, and return it to the Employer.

36.3 Upon the successful Bidder’s furnishing of the signed Contract Agreement and Performance Security pursuant to ITB 38, the [Employer or Purchaser] will discharge its Bid Security, pursuant to ITB 19.
36.4 Notwithstanding ITB 36.2 above, in case signing of the Contract Agreement is prevented by any expo rt restrictions attributable to the Employer, to the country of the E mployer, or to the use of the products/goods, systems or services to be supplied, where such export restrictions arise from tr ade regulations from a country supplying those products/goods, syst ems or services, the Bidder shall not be bound by its bid, always provided, however, that the Bidder can demonstrate to the sati sfaction of the Employer and of the Bank that signing of the Contract Agreem ent has not been prevented by any lack of diligenc e on the part of the Bidd er in completing any formalities, including applying for permits, 1-24 Section I - Instructions to Bidders 37.
Performance Security authorizations and licenses necessary for th products/goods, systems or serv ices under the terms of the Contract Agreement.
e export of the 37.1 Within twenty-eight (28) days of the receipt of notification of award from the Employer, the successful Bidder shall furnish the performance security in accordance with the conditions of contract, subject to ITB 31.3, using for that purpose the Performance Security Form included in Section IX (Contract Forms), or another form acceptable to the Employer.
If the performance security furnished by the successful Bidder is in the form of a bond, it shall be issued by a bonding or insurance company that has been determined by the successful Bidder to be acceptable to the Employer.

A foreign institution providing a bond shall have a correspondent financial institution located in the Employer’s Country.
37.2 Failure of the successful Bidder to submit the above-mentioned Performance Security or to sign the Contract shall constitute sufficient grounds for the annulment of the award and forfeiture of the bid security, or execution of the Bid Security Declaration.

In that event the Employer may award the Contract to the next lowest evaluated Bidder whose offer is substantially responsive and is determined by the Employer to be qualified to perform the Contract satisfactorily.
1-25 Section II - Bid Data Sheet (BDS) A.

Introduction The Employer is: Ministry of Education, Government of Antigua and Barbuda.

The name of the bidding process is: BEP II - St. Mary's Secondary School – Phase 2.

The identification number of the bidding process is: to be assigned by the CDB.

The number and identification of lots comprising this bidding process is: 1 Lot.

The Recipient is: Ministry of Education, Government of Antigua and Barbuda.
The name of the Project is: BEP II - St. Mary's Secondary School – Phase 2.

ITB 1.1 ITB 1.1 ITB 2.1 ITB 2.1 ITB 4.1(a) The individuals or firms in a JVCA, “shall be” be jointly and severally liable.

ITB 7.1 For clarification purposes only, the Employer’s address is: B.
Bidding Documents Antigua and Barbuda Tenders Board Ministry of Finance and Corporate Governance Parliament Drive Government Office Complex St. John's Antigua and Barbuda Tel: (268) 462-2953 Fax: (268) 462-4622 Email: tenders.board@ab.gov.ag Requests for clarification should be received by the Employer no later than: 14 days.

1-26 Section II - Bid Data Sheet ITB 7.4 There will be NO pre-bid meeting.

ITB 10.1 The language of the bid is: English.


C. Preparation of Bids ITB 11.1 (b) The following schedules shall be submitted with the bid: Bill of Quantities, draft progr amme of w orks and methodology, breakdown of Preliminaries costs.

ITB 11.1 (i) The Bidder shall submit with its bid the following additional documents: N/A.

ITB 13.1 Alternative bids shall not be permitted.

ITB 13.2 Alternative times for completion shall not be permitted.
If alternative times for completion are permitted, the evaluation method will be as specified in Section III (Evaluation and Qualification Criteria).

ITB 13.4 Alternative technical solutions shall be permitted for the following parts of the Works: None If alternative technical solutions are permitted, the evaluation method will be as specified in Section III (Evaluation and Qualification Criteria).
ITB 14.7 The prices quoted by the Bidder shall not be subject to adjustment during the performance of the Contract.

ITB 14.8 All goods imported by the Contractor into the country shall be exempt from customs and other import duties, subject to final approval of the Ministry of Finance.

The Employer shall endorse the necessary exemption document prepared by the Contractor for presentation in order to clear the Goods through Customs.
If exemption is not granted by the Ministry of Finance, the customs duties payable and paid shall be reimbursed by the Employer.

All imported goods, which are not incorporated in or expended in connection with the Works, shall be exported on completion of the Contract.

If not exported, the Goods will be assessed for duties as applicable to the Goods involved in accordance with the laws of the Country.

Section II - Bid Data Sheet 1-27 However, exemption may not be available for: a. b.
Goods which are similar to those locally produced, unless they are not available in sufficient quantities or are of a different standard to that which is necessary for the Works; and Any element of duty or tax inherent in the price of goods or services procured in the Country, which shall be deemed to be included in the Accepted Contract Amount.
Port duties, quay dues and except as setout above, any element of tax or duty inherent in the price of goods or services shall be deemed to be included in the Accepted Contract Amount.
ITB 15.1 The currency(ies) of the bid and the payment currency(ies) shall be as described below: Alternative A Alternative A (Bidders to quote entirely in local currency): (a) (b) (c) The unit rates and the prices shall be quoted by the Bidder in the Bill of Quantities, entirely in Eastern Caribbean Currency, further referred to as “the local currency”.
A Bidder expecting to incur expenditures in other currencies for inputs to the Requirements supplied from outside the Employer’s country (referred to as “the foreign currency(ies) requirements”) shall indicate in the Section IV.

Summary of Payment Currencies – Table C, the percentage(s) of the Bid Price (excluding Provisional Sums), needed by him for the payment of such foreign currency requirements, limited to no more than three foreign currencies of any country.
The rates of exchange to be used by the Bidder in arriving at the local currency equivalent and the percentage(s) mentioned in (a) above shall be specified by the Bidder in the Section IV.

Summary of Payment Currencies – Table C, and shall apply for all payments under the Contract so that no exchange risk will be borne by the successful Bidder.
their Bidders may be required by the Employer to justify, to the foreign currency Employer’s satisfaction, requirements, and to substantiate that the amounts included in the unit rates and prices and shown in the Section IV.

Schedule of Adjustment Data are reasonable, in which case a detailed breakdown of the foreign currency requirements shall be provided by Bidders.
local and 1-28 Section II - Bid Data Sheet Alternative B (Bidders allowed to quote in local and foreign currencies): (a) The unit rates and prices shall be quoted by the Bidder in the Bill of Quantities separately in the following currencies: (i) (ii) for those inputs to the Requirements that the Bidder expects to supply from within the Employer’s country, in EC$, further referred to as “the local currency”; and for those inputs to the Requirements that the Bidder expects to supply from outside the Employer’s country (referred to as “the foreign currency requirements”), in up to any three currencies of any country.
(b) Bidders may be required by the Employer to justify, to the Employer’s satisfaction, their local and foreign currency requirements, and to substantiate that the amounts included in the unit rates and prices and shown in the Section IV.

Schedule of Adjustment Data are reasonable, in which case a detailed breakdown of the foreign currency requirements shall be provided by Bidders.
The currency of the bid and payment shall be: US$ ITB 16.2 ITB 16.3 The Bidder shall not submit with its bid, the Manufacturer’s Authorization for the following part: N/A.

The Bidder shall not submit with its bid, evidence that it will be represented by an Agent in the country.

ITB 18.1 The bid validity period shall be: 120 days.

ITB 19.1 - The Bidder shall furnish a signed bid declaration document.

ITB 19.3 (d) None ITB 20.1 In addition to the original of the bid, the number of copies is: one.
ITB 20.2 The written confirmation of authorization to sign on behalf of the Bidder shall be: (a) a Power of Attorney witnessed and signed by a Notary Public.
(b) In the case of Bids sub mitted by an existing or intended JVCA an undertaking signed by all parties ( i) stating that all parties shall be jointly and severally lia ble, if so required in accordance with ITB 4.1(a), and (ii ) nominating a Representative who shall have the Section II - Bid Data Sheet 1-29 authority to conduct all business fo r and on behalf of any and all the parties of the JVCA during the b idding process and, in the event th e JV is awarded the Contract, during contract execution.
D. Submission and Opening of Bids ITB 21.1 Bidders shall not have the option of submitting their bids electronically.

ITB 21.1 (b) If bidders shall have the option of submitting their bids electronically, the electronic bidding submission procedures shall be: N/A.
ITB 22.1 For bid submission purposes only, the Employer’s address is: Antigua and Barbuda Tenders Board Ministry of Finance and Corporate Governance Parliament Drive Government Office Complex St. John's Antigua and Barbuda Tel: (268) 462-2953 Fax: (268) 462-4622 Email: tenders.board@ab.gov.ag The deadline for bid submission is: Date: Friday 7th June, 2019 Time: 14:00 hours ITB 25.1 The bid opening shall take place at: Street Address: Antigua and Barbuda Tenders Board Ministry of Finance and Corporate Governance Parliament Drive Government Office Complex St. John's Antigua and Barbuda Tel: (268) 462-2953 Fax: (268) 462-4622 Email: tenders.board@ab.gov.ag 1-30 Section II - Bid Data Sheet Date: Friday 7th June, 2019 Time: 14:30 hours ITB 25.1 If electronic bid submission is permitted in accordance with ITB 21.1, the specific bid opening procedures shall be: N/A.
E. Evaluation and Comparison of Bids ITB 30.1 The currency that shall be used for bid evaluation and comparison purposes to convert all bid prices expressed in various currencies into a single currency is: EC$ The source of exchange rate shall be: Eastern Caribbean Central Bank.

The date for the exchange rate shall be: 10 days prior to submission date.

ITB 31.2 A regional margin of preference shall not apply.
1-31 Section III - Evaluation and Qualification Criteria This section contains all the criteria that the Employer shall use to evaluate bids and qualify Bidders if the bidding was not preceded by a prequalification exercise and post-qualification is applied.

In accordance with ITB 34 and ITB 36, no other methods, criteria and factors shall be used.

The Bidder shall provide all the information requested in the forms included in Section IV (Bidding Forms).

Table of Criteria 1.


Evaluation…………………………………………………………………………34 1.1 Adequacy of Technical Proposal…………………………………………..34 1.2 Multiple Contracts…………………………………………………………34 1.3 Completion Time…………………………………………………………..34 1.4 Technical Alternatives……………………………………………………..34 1.5 Margin of Preference [Applicable for ICB only]……………………….....34 2.
Qualification………………………………………………………………………35 2.1 2.2 2.3 2.4 2.5 2.6 Eligibility…………………………………………………………………..35 Historical Contract Non-Performance……………………………………..36 Financial Situation…………………………………………………………37 Experience………………………………………………………………….39 Personnel…………………………………………………………………...41 Equipment………………………………………………………………….41 1-32 Section III - Evaluation and Qualification Criteria 1.
Evaluation In addition to the criteria listed in ITB 34.2 (a) – (e) the following criteria shall apply: 1.1 Adequacy of Technical Proposal Evaluation of the Bidder's Technical Proposal will include an assessment of the Bidder's technical capacity to mobilize key equipment and personnel for the contract consistent with its proposal regarding work methods, scheduling, and material sourcing in sufficient detail and fully in accordance with the requirements stipulated in Section 6 (Employer's Requirements).
1.2 Multiple Contracts Pursuant to Sub-Clause 34.4 of the Instructions to Bidders, if Works are grouped in multiple contracts, evaluation will be as follows: N/A 1.3 Completion Time An alternative Completion Time, if permitted under ITB 13.2, will be evaluated as follows: N/A 1.4 Technical Alternatives Technical alternatives, if permitted under ITB 13.4, will be evaluated as follows: N/A 1.5 Margin of Preference [Applicable for ICB only] If a margin of preference shall apply under ITB 33.1, the procedure will be as follows as: N/A Section III - Evaluation and Qualification Criteria 1-33 2.
Qualification Factor 2.1 Eligibility Criteria Bidder Sub-Factor Requirement Single Entity 2.1.1 Nationality Nationality in accordance with ITB 4.2.

Must meet requirement 2.1.2 Conflict of Interest No- conflicts of interests as described in ITB 4.3.

Must meet requirement 2.1.3 Bank Ineligibility Not having been declared ineligible by the Bank as described in ITB 4.4.
Must meet requirement All partners combined Existing or intended JVCA must meet requirement Existing or intended JVCA must meet requirement Existing JVCA must meet requirement Joint Venture, Consortium or Association Each partner Must meet requirement N / A At least one partner Documentation Required Form ELI –1.1 and 1.2, with attachments Must meet requirement N / A Letter of Bid Must meet requirement N / A Letter of Bid 2.1.4 Government Owned Entity Compliance with conditions of ITB 4.5 Must meet requirement Must meet requirement Must meet requirement N / A 2.1.5 Ineligibility based on a United Nations resolution or Recipient’s country law Not having been excluded as a result of the Recipient’s country laws or official regulations, or by an act of compliance with UN Security Council resolution, in accordance with ITB 4.8 Must meet requirement Existing JVCA must meet requirement Must meet requirement N / A Form ELI –1.1 and 1.2, with attachments Letter of Bid 1-34 Section III - Evaluation and Qualification Criteria Factor Sub-Factor 2.2.1 History of non- performing contracts 2.2.2 Pending Litigation 2.2 Historical Contract Non-Performance Criteria Bidder Requirement Single Entity Joint Venture, Consortium or Association At least one Each All partners partner partner combined Non-performance of a contract did not occur within the last five (5) years prior to the deadline for application submission, based on all information on fully settled disputes or litigation.
A fully settled dispute or litigation is one that has been resolved in accordance with the Dispute Resolution Mechanism under the respective contract, and where all appeal instances available to the bidder have been exhausted.

All pending litigation shall in total not represent more than ten percent (10%) of the Bidder’s net worth and shall be treated as resolved against the Bidder.
Must meet requirement by itself or as partner to past or existing JVCA Must meet requirement by itself or as partner to past or existing JVCA N / A N / A Must meet requirement by itself or as partner to past or existing JVCA Must meet requirement by itself or as partner to past or existing JVCA N / A N / A Documentation Required Form CON - 2 Form CON – 2 Section III - Evaluation and Qualification Criteria 1-35 Factor 2.3 Financial Situation Sub-Factor 2.3.1 Historical Financial Performance 2.3.2.
Average Annual Turnover Criteria Bidder Requirement Single Entity Joint Venture, Consortium or Association Documentation Required All partners combined Each partner At least one partner Submission of audited balance sheets or if not required by the law of the bidder’s country, other financial statements acceptable to the Employer, for the last three (3) years to demonstrate the current soundness of the bidders financial position and its prospective long term profitability.
(a) (criterion 1) (b) (criterion 2) Minimum average annual turnover of US$1,850,000.00 (EC$5,000,000.00), calculated as total certified payments received for contracts in progress or completed, within the last five (5) years Must meet requirement N / A Must meet requirement N / A Form FIN – 3.1 with attachments Must meet requirement Must meet requirement Must meet forty percent (40%) of the requirement Must meet fifty percent (50%) of the requirement Form FIN –3.2 1-36 Section III - Evaluation and Qualification Criteria Factor 2.3 Financial Situation Sub-Factor 2.3.3.
Financial Resources Criteria Bidder Requirement Single Entity Joint Venture, Consortium or Association Documentation Required All partners combined Each partner At least one partner The Bidder must demonstrate access to, or availability of, financial resources such as liquid assets, unencumbered real assets, lines of credit, and other financial means, other than any contractual advance payments to meet: (i) the following cash-flow requirement: US$220,000.00 (EC$600,000.00) and (ii) the overall cash flow requirements for this contract and its concurrent commitments.
Must meet requirement Must meet requirement Must meet forty percent (40%) of the requirement Must meet fifty percent (50%) of the requirement Form FIN –3.3 Section III - Evaluation and Qualification Criteria 1-37 Factor 2.4 Experience Criteria Bidder Sub-Factor 2.4.1 General Experience 2.4.2 Specific Experience Requirement Single Entity Joint Venture, Consortium or Association Each partner All partners combined At least one partner Documentation Required Experience under contracts in the role of contractor, subcontractor, or management contractor for at least the last five (5) years prior to the applications submission deadline, and with activity in at least nine (9) months in each year.
(a)Participation as contractor, management contractor, or subcontractor, in at least two (2) contracts within the last six (6) years , each with a value of at least US$2,000,000.00(two million), that have been successfully and substantially completed and that are similar to the proposed Works.
The similarity shall be based on the physical size, complexity, methods/technology or other characteristics as described in Must meet requirement N / A Must meet requirement N / A Form EXP-4.1 Must meet requirement Must meet requirements for all characteristics N / A Must meet requirement for one characteristic Form EXP 2.4.2(a) 1-38 Section III - Evaluation and Qualification Criteria Factor 2.4 Experience Criteria Bidder Sub-Factor Requirement Single Entity Joint Venture, Consortium or Association Each partner All partners combined At least one partner Documentation Required 2.4.2 Specific Experience Section VI, Employer’s Requirements.
b) For the above or other contracts executed during the period stipulated in 2.4.2(a) above, a minimum experience in the following key activities: institutional buildings Must meet requirements Must meet requirements N / A Must meet requirements Form EXP- 2.4.2(b) Section III - Evaluation and Qualification Criteria 1-39 2.5 Personnel The Bidder must demonstrate that it will have the personnel for the key positions that meet the following requirements: Position Site Agent Site Foreman No.
Total Work Similar Experience (years) 15 15 In Similar Works Experience (years) 10 10 The Bidder shall provide details of the proposed personnel and their experience records in the relevant Forms included in Section IV, Bidding Forms.

2.6 Equipment The Bidder must demonstrate that it will have access to the key Contractor’s equipment listed hereafter: No.
Equipment Type and Characteristics Minimum Number required Hoist Cement Mixer The Bidder shall provide further details of proposed items of equipment using the relevant Form in Section IV.
1-41 Section IV - Bidding Forms Table of Forms Letter of Bid…………………………………………………………………………………44 Schedules…………………………………………………………………………………….46 Bill of Quantities/Schedules of Prices…………………………………………………….....46 Table(s) of Adjustment Data………………………………………………………………...47 Form of Bid Security (Bank Guarantee)………………………………………………….48 Form of Bid Security (Bid Bond)……..…………………………………………………...49 Form of Bid Security Declaration……..…………………………………………...……...50 Technical Proposal……………………...……………………………………….…………51 Technical Proposal Forms……………………………………………………………….…..51 Forms for Personnel…………………………………………………………………………52 Forms for Equipment………………………………………..………………………………54 Bidder’s Qualification……………………………………………………………………...55 Bidder Information Sheet……………………………………………………………………56 Party to JVCA Information Sheet……………………………………………………………57 Historical Contract Non-Performance……………………………………………………….58 Current Contract Commitments/Works in Progress…………………………………..……..59 Financial Situation………………………………………………………………………...…60 Average Annual Turnover……………………………………………………………...……62 Financial Resources………………………………………………………………………….63 General Experience………………………………………………………………………….64 Specific Experience………………………………………………………………………….65 Specific Experience in Key Activities……………………………………………………....67 1-42 Section IV - Bidding Forms Letter of Bid The Bidder must prepare the Letter of Bid on stationery with its letterhead clearly showing the Bidder’s complete name and address.
Date: _______________ Bidding No.

: _______________ Invitation for Bid No.
: _______________ To: We, the undersigned, declare that: (a) We have examined and have no reservations to the Bidding Documents, including Addenda issued in accordance with Instructions to Bidders (ITB) Clause 8; (b) We offer to execute in conformity with the Bidding Documents the following Works: ____________________________________________________________________; (c) (d) (e) (f) (g) (h) The total price of our Bid, excluding any discounts offered in item (d) below is: ___________________________; The discounts offered and the methodology for their application are: _____________; Our bid shall be valid for a period of ________ [insert validity period as specified in ITB 18.1.]
days from the date fixed for the bid submission deadline in accordance with the Bidding Documents, and it shall remain binding upon us and may be accepted at any time before the expiration of that period; If price adjustment provisions apply, the Table(s) of Adjustment Data shall be considered part of this Bid;1 If our bid is accepted, we commit to obtain a performance security in accordance with the Bidding Document; Our firm, including any employees, subcontractors or suppliers for any part of the Contract, have nationalities from eligible countries; (i) We, including any subcontractors or suppliers for any part of the contract, do not have any conflict of interest in accordance with ITB 4.3; 1 Include if price adjustment provisions apply in the Contract in accordance with PCC Sub-Clause 44.1 Price Adjustment.
Section IV - Bidding Forms 1-43 (j) We are not participating, as a Bidder or as a subcontractor, in more than one bid in this bidding process in accordance with ITB 4.3, other than alternative offers submitted in accordance with ITB 13; (k) Our firm, its affiliates or subsidiaries, including any Subcontractors or Suppliers for any part of the contract, has not been declared ineligible by the Bank, under the Employer’s country laws or official regulations or by an act of compliance with a decision of the United Nations Security Council; (l) We are not a government owned entity / We are a government owned entity but meet the requirements of ITB 4.5;2 (m) We have paid, or will pay the following commissions, gratuities, or fees with respect to the bidding process or execution of the Contract: 3 Name of Recipient Address Reason Amount (n) We understand that this bid, together with your written acceptance thereof included in your notification of award, shall constitute a binding contract between us, until a formal contract is prepared and executed; (o) We understand that you are not bound to accept the lowest evaluated bid or any other bid that you may receive; and (p) If awarded the contract, the person named below shall act as Contractor’s Representative: ________________________________________________________ Name: In the capacity of: Signed: Duly authorized to sign the Bid for and on behalf of: Date: Schedules 2 Use one of the two options as appropriate.
3 If none has been paid or is to be paid, indicate “none”.

1-44 Section IV - Bidding Forms Bill of Quantities/ Schedules of Prices Schedule of Payment Currencies For ...........................insert name of Section of the Works Separate tables may be required if the various sections of the Works (or of the Bill of Quantities) will have substantially different foreign and local currency requirements.

The Employer should insert the names of each Section of the Works.
A Name of Payment Currency Amount of Currency Local currency Foreign Currency #1 Foreign Currency #2 Foreign Currency #3 Net Bid Price Provisional Sums Expressed in Local Currency BID PRICE C Local Currency Equivalent C = A x B D Percentage of Net Bid Price (NBP) 100xC NBP B Rate of Exchange to Local Currency 1.00 100.00 1.00 Section IV - Bidding Forms 1-45 Table(s) of Adjustment Data Table A - Local Currency Index Code Index Description Source of Index Base Value and Date Nonadjustable — — Bidder’s Local Currency Amount — Total Bidder’s Proposed Weighting A: B: C: D: E: 1.00 Table B - Foreign Currency Name of Currency: _______________ If the Bidder wishes to quote in more than one foreign currency, this table should be repeated for each foreign currency.
Index Code Index Description Source of Index Base Value and Date Nonadjustable — — Bidder’s Currency in Type/Amount — Equivalent in FC1 Total Bidder’s Proposed Weighting A: B: C: D: E: 1.00 1-46 Section IV - Bidding Forms Form of Bid Security (Bank Guarantee) __________________________ [Bank’s Name, and Address of Issuing Branch or Office] Beneficiary: __________________________ [Name and Address of Employer] Date: __________________________ BID GUARANTEE No.
: __________________________ We have been informed that __________________________ [name of the Bidder ] (hereinafter called "the Bidder") has submitted to you its bid dated ___________ (hereinafter called "the Bid") for the execution of ________________ [name of contract] under Invitation for Bids No.

___________ (“the IFB”).

Furthermore, we understand that, according to your conditions, bids must be supported by a bid guarantee.
At the request of the Bidder, we ____________________ [name of Bank] hereby irrevocably undertake to pay you any sum or sums not exceeding in total an amount of ___________ [amount in figures ] (____________) [amount in words] upon receipt by us of your first demand in writing accompanied by a written statement stating that the Bidder is in breach of its obligation(s) under the bid conditions, because the Bidder: (a) has withdrawn its Bid during the period of bid validity specified by the Bidder in the Form of Bid; or (b) having been notified of the acceptance of its Bid by the Beneficiary during the period of bid validity, (i) fails or refuses to execute the Contract Form, if required, or (ii) fails or refuses to furnish the performance security, in accordance with the ITB.
This guarantee will expire: (a) if the Bidder is the successful Bidder, upon our receipt of copies of the contract signed by the Bidder and the performance security issued to you upon the instruction of the Bidder; and (b) if the Bidder is not the successful Bidder, upon the earlier of (i) our receipt of a copy your notification to the Bidder of the name of the successful Bidder; or (ii) twenty-eight days after the expiration of the Bidder’s bid.
Consequently, any demand for payment under this guarantee must be received by us at the office on or before that date.

This guarantee is subject to the Uniform Rules for Demand Guarantees, ICC Publication No.

458.

_____________________________ [signature(s)] Section IV - Bidding Forms 1-47 Form of Bid Security (Bid Bond) BOND NO.
______________________ BY THIS BOND [name of Bidder] as Principal (hereinafter called “the Principal”), and [name, legal title, and address of surety], authorized to transact business in [name of country of Employer], as Surety (hereinafter called “the Surety”), are held and firmly bound unto [name of Employer] as Obligee (hereinafter called “the Employer”) in the sum of [amount of Bond]4 [amount in words], for the payment of which sum, well and truly to be made, we, the said Principal and Surety, bind ourselves, our successors and assigns, jointly and severally, firmly by these presents.
WHEREAS the Principal has submitted a written Bid to the Employer dated the ___ day of ______, 20__, for the construction of [name of Contract] (hereinafter called the “Bid”).
NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that if the Principal: (a) withdraws its Bid during the period of bid validity specified in the Form of Bid; or (b) having been notified of the acceptance of its Bid by the Employer during the period of Bid validity; (i) fails or refuses to execute the Contract Form, if required; or (ii) fails or refuses to furnish the Performance Security in accordance with the Instructions to Bidders; then the Surety undertakes to immediately pay to the Employer up to the above amount upon receipt of the Employer’s first written demand, without the Employer having to substantiate its demand, provided that in its demand the Employer shall state that the demand arises from the occurrence of any of the above events, specifying which event(s) has occurred.
The Surety hereby agrees that its obligation will remain in full force and effect up to and including the date 28 days after the date of expiration of the Bid validity as stated in the Invitation to Bid or extended by the Employer at any time prior to this date, notice of which extension(s) to the Surety being hereby waived.

IN TESTIMONY WHEREOF, the Principal and the Surety have caused these presents to be executed in their respective names this ____ day of ____________ 20__.
Principal: _______________________ Surety: _____________________________ Corporate Seal (where appropriate) _______________________________ (Signature) ____________________________________ (Signature) (Printed name and title) (Printed name and title) 4 The amount of the Bond shall be denominated in the currency of the Employer’s country or the equivalent amount in a freely convertible currency.
1-48 Section IV - Bidding Forms Form of Bid-Securing Declaration Date: [insert date (as day, month and year)] Bid No.

: [insert number of bidding process] Alternative No.

: [insert identification No if this is a Bid for an alternative] To: [insert complete name of Employer] We, the undersigned, declare that: We understand that, according to your conditions, bids must be supported by a Bid-Securing Declaration.
We accept that we will automatically be suspended from being eligible for bidding in any contract with the Recipient for the period of time of [insert number of months or years] starting on [insert date], if we are in breach of our obligation(s) under the bid conditions, because we: (a) have withdrawn our Bid during the period of bid validity specified in the Letter of Bid; or (b) having been notified of the acceptance of our Bid by the Employer during the period of bid validity, (i) fail or refuse to execute the Contract, if required, or (ii) fail or refuse to furnish the Performance Security, in accordance with the ITB.
We understand this Bid-Securing Declaration shall expire if we are not the successful Bidder, upon the earlier of (i) our receipt of your notification to us of the name of the successful Bidder; or (ii) twenty-eight days after the expiration of our Bid.
Signed: [insert signature of person whose name and capacity are shown] In the capacity of [insert legal capacity of person signing the Bid-Securing Declaration] Name: [insert complete name of person signing the Bid-Securing Declaration] Duly authorized to sign the bid for and on behalf of: [insert complete name of Bidder] Dated on ____________ day of __________________, _______ [insert date of signing] Corporate Seal (where appropriate) [Note: In case of a Joint Venture, the Bid-Securing Declaration must be in the name of all partners to the Joint Venture that submits the bid.]
Note: All italicized text is for use in preparing this form and shall be deleted from the final product.
Section IV - Bidding Forms 1-49 Technical Proposal Technical Proposal Forms Personnel Equipment Site Organization Method Statement Mobilization Schedule Construction Schedule Others 1-50 Section IV - Bidding Forms Forms for Personnel Form PER – 1: Proposed Personnel Bidders should provide the names of suitably qualified personnel to meet the specified requirements for each of the positions listed in Section III (Evaluation and Qualification Criteria).
The data on their experience should be supplied using the Form below for each candidate.

1.

Title of position Name 2.

Title of position Name 3.

Title of position Name 4.

Title of position Name 5.

Title of position Name 6.

Title of position Name etc.

Title of position Name Section IV - Bidding Forms 1-51 Form PER – 2: Resume of Proposed Personnel The Bidder shall provide all the information requested below.

Fields with asterix (*) shall be used for evaluation.
Position* Personnel information Name * Professional qualifications Present employment Name of Employer Address of Employer Date of birth Telephone Fax Job title Contact (manager / personnel officer) E-mail Years with present Employer Summarize professional experience in reverse chronological order.

Indicate particular technical and managerial experience relevant to the project.
From* To* Company, Project , Position, and Relevant Technical and Management Experience* 1-52 Section IV - Bidding Forms Forms for Equipment The Bidder shall provide adequate information to demonstrate clearly that it has the capability to meet the requirements for the key equipment listed in Section III (Evaluation and Qualification Criteria).

A separate Form shall be prepared for each item of equipment listed, or for alternative equipment proposed by the Bidder.
The Bidder shall provide all the information requested below, to the extent possible.

Fields with asterisk (*) shall be used for evaluation.

Type of Equipment* Equipment Information Name of manufacturer Model and power rating Capacity* Year of manufacture* Current Status Current location Details of current commitments Source Indicate source of the equipment  Owned  Rented  Leased  Specially manufactured The following information shall be provided only for equipment not owned by the Bidder.
Owner Name of owner Address of owner Telephone Fax Contact name and title Telex Agreements Details of rental / lease / manufacture agreements specific to the project Section IV - Bidding Forms 1-53 Bidder’s Qualification To establish its qualifications to perform the contract in accordance with Section III (Evaluation and Qualification Criteria) the Bidder shall provide the information requested in the corresponding Information Sheets included hereunder 1-54 Section IV - Bidding Forms Form ELI 1.1 Bidder Information Sheet Date: ______________________ Bidding No.
: ________________ Invitation for Bid No.

: ________ Page ________ of _______ pages 1.

Bidder’s Legal Name 2.

In case of JVCA, legal name of each party: 3.

Bidder’s actual or intended Country of Registration: 4.

Bidder’s Year of Registration: 5.

Bidder’s Legal Address in Country of Registration: 6.

Bidder’s Authorized Representative Information Name: Address: Telephone/Fax numbers: Email Address: Articles of Incorporation or Registration of firm named in 1, above, in accordance with 7.
Attached are copies of original documents of:  ITB Sub-Clauses 4.1 and 4.2.

 In case of JVCA, letter of intent to form JVCA including a draft agreement, or JVCA agreement, in accordance with ITB Sub-Clauses 4.1 In case of government owned entity from the Employer’s country, documents establishing legal and financial autonomy and compliance with the principles of commercial law, in accordance with ITB Sub-Clause 4.5.
Section IV - Bidding Forms 1-55 Form ELI 1.2 Party to JVCA Information Sheet Date: ______________________ Bidding No.

: ___________________ Invitation for Bid No.

:_________ Page ________ of_ ______ pages 1.

Bidder’s Legal Name: 2.

JVCA’s Party legal name: 3.

JVCA’s Party Country of Registration: 4.

JVCA’s Party Year of Registration: 5.

JVCA’s Party Legal Address in Country of Registration: 6.

JVCA’s Party Authorized Representative Information Name: Address: Telephone/Fax numbers: Email Address: 7.
Attached are copies of original documents of: Articles of Incorporation or Registration of firm named in 1, above, in accordance with ITB Sub-Clauses 4.1 and 4.2.

 In case of government owned entity from the Employer’s country, documents establishing legal and financial autonomy and compliance with the principles of commercial law, in accordance with ITB Sub-Clause 4.5.
1-56 Section IV - Bidding Forms Form CON – 2 Historical Contract Non-Performance Bidder’s Legal Name: _______________________ JVCA Partner Legal Name: _______________________ Date: _____________________ ___________________ Bidding No.
: __________________ Page _______ of _______ pages Non-Performing Contracts in accordance with (Evaluation and Qualification Criteria) Contract non-performance did not occur during the stipulated period, in accordance with Sub-Factor 2.2.1 of Section III (Evaluation and Qualification Criteria) Contract non-performance during the stipulated period, in accordance with Sub-Factor 2.2.1 of Section III(Evaluation and Qualification Criteria).
Year Outcome as Percent of Total Assets ______ ______ Contract Identification Contract Identification: Name of Employer: Address of Employer: Matter in dispute: Total Contract Amount (current value, US$ equivalent) ___________ Pending Litigation, in accordance with Section III (Evaluation and Qualification Criteria) No pending litigation in accordance with Sub-Factor 2.2.2 of Section III(Evaluation and Qualification Criteria) Pending litigation in accordance with Sub-Factor 2.2.2 of Section III(Evaluation and Qualification Criteria), as indicated below Year Outcome as Percent of Total Assets ______ ______ ______ ______ Contract Identification Contract Identification: Name of Employer: Address of Employer: Matter in dispute: Contract Identification: Name of Employer: Address of Employer: Matter in dispute: Total Contract Amount (current value, US$ equivalent) ___________ ___________ Section IV - Bidding Forms 1-57 Current Contract Commitments / Works in Progress Form CCC Bidders and each partner to a JVCA should provide information on their current commitments on all contracts that have been awarded, or for which a letter of intent or acceptance has been received, or for contracts approaching completion, but for which an unqualified, full completion certificate has yet to be issued.
Name of contract Employer, contact address/tel/fax Value of outstanding work (current US$ equivalent) Estimated completion date Average monthly invoicing over last six months (US$/month) 1.

2.

3.

4.

5. etc.

1-58 Section IV - Bidding Forms Financial Situation Historical Financial Performance Bidder’s Legal Name: _______________________ Date: _____________________ JVCA Partner Legal Name: _______________________ Bidding No.
: __________________ Page _______ of _______ pages To be completed by the Bidder and, if JVCA, by each partner Historic information for previous ______ (__) years (US$ equivalent in 000s) Financial information in US$ equivalent Year 1 Year 2 Year 3 Year … Year n Avg.

Avg.
Ratio Information from Balance Sheet Total Assets (TA) Total Liabilities (TL) Net Worth (NW) Current Assets (CA) Current Liabilities (CL) Information from Income Statement Total Revenue (TR) Profits Before Taxes (PBT) Section IV - Bidding Forms 1-59 Attached are copies of financial statements (balance sheets, including all related notes, and income statements) for the years required above complying with the following conditions:  Must reflect the financial situation of the Bidder or partner to a JVCA, and not sister or parent companies  Historic financial statements must be audited by a certified accountant  Historic financial statements must be complete, including all notes to the financial statements  Historic financial statements must correspond to accounting periods already completed and audited (no statements for partial periods shall be requested or accepted) 1-60 Section IV - Bidding Forms Form FIN – 3.2 Average Annual Turnover Bidder’s Legal Name: ___________________________ Date: _____________________ JVCA Partner Legal Name: ____________________________ Bidding No.
: ______________ Page _______ of _______ pages Year Amount and Currency US$ equivalent Annual turnover data (construction only) _________________________________________ ____________________ _________________________________________ ____________________ _________________________________________ ____________________ _________________________________________ ____________________ _________________________________________ ____________________ _________________________________________ ____________________ *Average Annual Construction Turnover *Average annual turnover calculated as total certified payments received for work in progress or completed over the number of years specified in Section III(Evaluation and Qualification Criteria), Sub-Factor 2.3.2, divided by that same number of years.
Section IV - Bidding Forms 1-61 Form FIN3.3 Financial Resources Specify proposed sources of financing, such as liquid assets, unencumbered real assets, lines of credit, and other financial means, net of current commitments, available to meet the total construction cash flow demands of the subject contract or contracts as indicated in Section III (Evaluation and Qualification Criteria) Source of financing Amount (US$ equivalent) 1.

2.

3.

4.
2.

3.

4.

1-62 Section IV - Bidding Forms Experience General Experience Bidder’s Legal Name: ____________________________ Date: _____________________ JVCA Partner Legal Name: ____________________________Bidding No.
: ________________ Page _______ of _______ pages Starting Month / Year Ending Month / Year Years* ______ ______ ______ ______ ______ ______ ______ ______ ______ ______ ______ ______ Contract Identification Contract name: Brief Description of the Works performed by the Bidder: Name of Employer: Address: Contract name: Brief Description of the Works performed by the Bidder: Name of Employer: Address: Contract name: Brief Description of the Works performed by the Bidder: Name of Employer: Address: Contract name: Brief Description of the Works performed by the Bidder: Name of Employer: Address: Contract name: Brief Description of the Works performed by the Bidder: Name of Employer: Address: Contract name: Brief Description of the Works performed by the Bidder: Name of Employer: Address: Role of Bidder _________ _________ _________ _________ _________ _________ *List calendar year for years with contracts with at least nine (9) months activity per year starting with the earliest year Section IV - Bidding Forms 1-63 Form EXP – 2.4.2(a) Specific Experience Bidder’s Legal Name: ___________________________ Date: _____________________ JVCA Partner Legal Name: _________________________Bidding No.
: __________________ Similar Contract Number: ___ [insert specific number] of ___[insert total number of contracts required.
Page _______ of _______ pages Information Contract Identification _______________________________________ Award date Completion date Role in Contract Total contract amount If partner in a JVCA or subcontractor, specify participation of total contract amount Employer’s Name: Address: Telephone/fax number: E-mail: _______________________________________ _______________________________________ Contractor Management Contractor Subcontractor __________________________ __ US$_______ ___ __________% _____________ US$_______ _______________________________________ _______________________________________ _______________________________________ _______________________________________ _______________________________________ 1-64 Section IV - Bidding Forms Form EXP – 2.4.2(a) (cont.)
Specific Experience (cont.)

Bidder’s Legal Name: ___________________________ Page _______ of _______ pages JVCA Partner Legal Name: ___________________________ Similar Contract No.
__[insert specific number] of ___[insert total number of contracts] required Description of the similarity in accordance with Sub-Factor 2.4.2a) of Section III (Evaluation and Qualification Criteria): Information Amount Physical size Complexity _________________________________ _________________________________ _________________________________ Methods/Technology _________________________________ Physical Production Rate _________________________________ Section IV - Bidding Forms 1-65 Form EXP – 2.4.2(b) Specific Experience in Key Activities Bidder’s Legal Name: ___________________________ Date: _____________________ JVCA Partner Legal Name: _________________________Bidding No.
: __________________ Page _______ of _______ pages Subcontractor’s Legal Name: ______________ Contract Identification _______________________________________ Information Award date Completion date Role in Contract _______________________________________ _______________________________________ Contractor Management Contractor Subcontractor Total contract amount _________________________ US$________ If partner in a JVCA or subcontractor, specify participation of total contract amount Employer’s Name: Address: Telephone/fax number: E-mail: __________% _____________ US$________ _______________________________________ _______________________________________ _______________________________________ _______________________________________ _______________________________________ 1-66 Section IV - Bidding Forms Form EXP – 2.4.2 (b)(cont.)
Specific Experience in Key Activities (cont.)
Bidder’s Legal Name: ___________________________ Page _______ of _______ pages JVCA Partner Legal Name: ___________________________ Subcontractor’s Legal Name: __________________________ Description of the key activities in accordance with Sub-Factor 2.4.2b) of Section III (Evaluation and Qualification Criteria): Information Section V - Eligible Countries 1-67 Eligible Countries are: Regional Anguilla, Antigua and Barbuda, The Bahamas, Barbados, Belize, British Virgin Islands, Cayman Islands, Colombia, Dominica, Grenada, Guyana, Haiti, Jamaica, Mexico, Montserrat, St. Kitts and Nevis, St. Lucia, St. Vincent and the Grenadines, Suriname, Trinidad and Tobago, Venezuela, Turks and Caicos Islands.
Non-Regional Brazil, United Kingdom, Canada, China, Germany, Italy.
2-1 PART 2 – Employer’s Requirements 2-3 Section VI - Employer’s Requirements Table of Contents Specifications ........................................................................................................................... 4 Drawings .................................................................................................................................. 5 Supplementary Information ................................................................................................ 11 2-4 Section VI – Employer’s Requirements Specifications Section 6 – Employer’s Requirements 2-5 Equivalency of Standards and Codes Wherever reference is made in the Contract to specific standards and codes to be met by the goods and materials to be furnished, and work performed or tested, the provisions of the latest current edition or revision of the relevant standards and codes in effect shall apply, unless otherwise expressly stated in the Contract.
Where such standards and codes are national, or related to a particular country or region, other authoritative standards that ensure a substantially equal or higher quality than the standards and codes specified will be accepted subject to the Project Manager's prior review and written consent.
Differences between the standards specified and the proposed alternative standards shall be fully described in writing by the Contractor and submitted to the Project Manager at least 28 days prior to the date when the Contractor desires the Project Manager's consent.

In the event the Project Manager determines that such proposed deviations do not ensure substantially equal or higher quality, the Contractor shall comply with the standards specified in the documents.

1.

2.
1.

2.

Architectural Specification Civil/Structural Specifications - refer to drawings 3.
MEP Specifications - refer to Volume 2 MATERIALS AND WORKMANSHIP PREAMBLES MATERIALS AND WORKMANSHIP PREAMBLES Generally Excavations & Earthworks Concrete Work Blockwork Roofing Carpentry & Joinery Metalwork Floor, Wall & Ceiling Finishes Plumbing Installation Electrical Installation Glazing Painting and Decorating External Works ........ ........ ........ ........ ........ ........ ........ ........ ........ ........ ........ ........ ........

Page No.

MW/1 Page No.

MW/3 Page No.

MW/5 Page No.


MW/9 Page No.

MW/10 Page No.

MW/12 Page No.

MW/21 Page No.

MW/23 Page No.

MW/28 Page No.

MW/32 Page No.

MW/34 Page No.

MW/36 Page No.

MW/39 MATERIALS AND WORKMANSHIP PREAMBLES GENERALLY Weights and Measures A B C D E Weights and measures referred to in this document are those normally in use in Barbados.
Calculation of Quantities All work, unless otherwise described, has been measured nett as fixed in position and the Contractor shall allow in his prices for waste, laps, etc.

The quantities given are therefore not to be used for the ordering of materials.

Dimensions Figured dimensions on drawings shall be followed in preference to scaled dimensions and large scale drawings in preference to small.
Manufacturer's Recommendations All branded materials shall be used strictly in accordance with the manufacturer's recommendations or instructions unless otherwise instructed by the Architect.

Should the Contractor obtain from the Architect recommendations or instructions varying from the manufacturer's, he shall notify the Architect in writing and obtain his written approval before proceeding with the work.
The Contractor shall be responsible for obtaining from manufacturers all relevant details regarding the use of their products and shall allow for all costs in connection therewith.
Where a manufacturer's name or the proprietary name of an article appears in this document, it is given as an indication to tendering contractors of the standard and description required and contractors may quote for any manufacturer's article, provided it is of the standard and description specified and approved by the Architect in writing prior to the submission of the tender.
Protection Where an item is measured for protection, the Contractor is to include for all labour and materials necessary to protect finished work for which payment has been made in interim certificates from damage of any kind.

Where the Architect considers that insufficient protective measures are being taken, the Contractor will be instructed to upgrade the level of protection.
The issue of such an instruction will not constitute a variation requiring adjustment of the Contract Sum since the Contractor is assumed to have included in his tender amount for providing sufficient protection.
MW/1 MATERIALS AND WORKMANSHIP PREAMBLES (Cont’d) GENERALLY (Cont’d) Testing of Materials A B C Where the Contractor is required to carry out tests on materials he is to include within his prices for those items, for the cost of testing together with the cost of delivery, fees payable, preparation of reports, plant and consumable goods.
Materials not incorporated in the completed Works Materials which are not to be incorporated into the completed building, for example: formwork materials, will be treated as plant and equipment and will not be paid for in interim certificates as materials on site.

Materials and Workmanship Materials and workmanship shall be of the best quality and executed in accordance with proper working practices conforming to the relevant British Standards and Codes of Practice referred to in these Preambles.
The works shall be carried out in accordance with the drawings and specifications and the quality and standard of materials and workmanship shall be to the reasonable satisfaction of the Architect.

Accuracy in building shall be in accordance with the permissible values as set out in BS 5606.

Setting out the Works D The Contractor shall diligently and accurately set out the works in conformity with the contents of BS 5964.
MW/2 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) EXCAVATIONS AND EARTHWORKS GENERAL A The Contractor is referred to the Civil and Structural Specification which is embodied within these preambles for items referring to Excavations and Earthworks.

Definitions Nature of Ground B C The Contractor shall be deemed to have inspected the site and examined the soils report to determine the nature of and difficulties which might be encountered during the excavations.
No assurance is given that the soils report is typical of conditions over the area of excavation and he must make whatever investigations as he considers necessary to determine to his own satisfaction the nature of excavations to be carried out.

Prices for excavations shall include for excavating in all types of material except rock.
Normal Water Level If excavations are to be carried out below the normal water table, the level shall be measured and agreed with the Quantity Surveyor prior to pumping operations being commenced.
Termite Treatment D Subterranean termite treatment of the site of the building shall be with the toxicant listed as an emulsion in water at the minimum concentrations listed: Terrador SC - 0.05% by weight The toxicant emulsion shall be applied by spray immediately before pouring of concrete at the rate recommended by the manufacturer.

Treatment shall not be carried out when rain is falling or when ground is excessively wet.
A warranty of at least 5 years is required against infestation by subterranean termites, during which period the Contractor shall carry out any remedial work free of charge.

MW/3 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) EXCAVATIONS AND EARTHWORKS (Cont’d) Rock Rock is defined as any material to be excavated which requires for its removal the use of wedges and levers, compressed air jack hammers or explosives.

Prices for excavation are to include for any other material than that defined herein.
Both the Engineer and the Quantity Surveyor are to be informed before any excavation in rock is commenced.

BS and CP References BS 6031 BS 3882 Earthworks Top soil CP 2004 Excavations.

A B C MW/4 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) CONCRETE WORK General A B The Contractor is referred to the Civil and Structural Specification which is embodied within these preambles for items referring to concrete works.
Responsibility No approval or acceptance by the Architect or his representative shall in any way relieve the Contractor of his responsibility for the quality of materials and the standard of workmanship in the finished works and for the strength and durability of the finished concrete works.

Cements C The cement shall be Portland cement complying with BS 12.

All cement shall be delivered in the original sealed containers of the manufacturer.
No rebagged cement will be permitted to be brought on to the site.

On no account shall a change in the type or source of supply be permitted during the course of construction and every endeavour shall be made to ensure that the colour of the cement is constant throughout the contract.

Labour The Contractor shall employ sufficient skilled and unskilled workers under trained and experienced supervision to ensure that degree of skill necessary to produce the quality of workmanship demanded.
Finished work to Concrete Faces General After removal of the formwork, no treatment of any kind other than that required for curing the concrete shall be applied to the concrete faces until they have been inspected by the Architect's and Engineer's representatives.

Exposed Concrete Faces Unless otherwise specified, all concrete faces to be exposed in the finished works shall be left as struck.

After inspection, all superfluous fins and similar projections shall be carefully removed.
No render or other applied finish shall be used to obtain a fair face to the concrete.

D E F MW/5 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) CONCRETE WORK (Cont’d) Defective Work A Where in the opinion of the Architect or Engineer any of the finished works or the materials or workmanship in any part of the works, does not comply with all the relevant requirements of this specification that part of the works shall be classed as defective work.
All work classed as defective work shall be cut out and removed from the works and replaced to the satisfaction of the Architect and the Engineer.

The extent of the work to be removed and the methods to be used in the removal and replacement of this work shall be in accordance with the Architect's and Engineer's directions.
In all cases cutting out of defective concrete work shall be carried back to a satisfactory construction joint before the replacement of defective work and any other work thereby affected is commenced.

Qualifications of the SMM Beds or the like laid in Bays B C D E Notwithstanding the provisions of the SMM, the description of work laid in bays shall be deemed to include formwork between the bays and for preparing the edges of bays as described in these preambles before the adjacent bays are laid.
Steel Bar and Fabric Reinforcement Notwithstanding the provisions of the SMM, the descriptions of steel bar and fabric reinforcement shall be deemed to include bends, hooks, tying wire, distance blocks and ordinary spacers, unless otherwise described.

Notwithstanding the provisions of the SMM, the description of fabric reinforcement shall be deemed to include notching around obstructions.
Making Good Notwithstanding the provisions of the SMM, the descriptions of holes and mortices shall be deemed to include making good concrete.

Flexible Sheet Membranes No allowance has been made for laps or welts in the measurement of flexible sheet membrane.

MW/6 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) CONCRETE WORK (Cont’d) Concrete Prices A B C Prices for concrete shall include for placing in position, vibrating and curing and forming all necessary construction joints.
Prices for concrete cast in earth or rock cuts shall include for any additional concrete over the size stated necessitated by the irregularity of the surfaces retaining concrete.

Formwork Prices Include in the price for formwork for all cleaning and oiling of forms.
BS and CP References BS BS BS BS BS BS BS BS BS BS BS BS BS BS BS BS BS CP CP CP CP CP CP CP CP ) ) ) ) 12 882 1198 - 1201 5328 3148 4027 4466 4449 4461 4482 - 3 4429 (Part 2 ) 340 368 1239 1881 5642 4374 101 102 111 114 114.100 114.105 116 117 ) ) Portland Cement Aggregates Ready mixed concrete Test for water Sulphate resisting Portland cement Bending dimensions of bars Steel bars Steel fabric Metric sizes of bars Kerbs Paving slabs Lintels Concrete test cubes Coping units Sills Foundations Protection from ground water Structural recommendations Reinforced concrete for walls Suspended concrete floors roofs and staircases Structural use of precast concrete Composite construction in structural steel and concrete MW/7 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) CONCRETE WORK (Cont’d) A Barbados National Standards Institute BNS 69 Protection Portland Cement B Protection of finished work is clearly imperative at all times and the Architect reserves the right to condemn previously accepted work if subsequently damaged and to withhold further payment until the work has been rectified.
The amount included for the item is deemed to include for the protection of all work and where no price is included against this item, it will be assumed that the Contractor has included elsewhere in the Bills of Quantities for these costs.

MW/8 MATERIALS AND WORKMANSHIP PREAMBLES (Cont’d) BLOCKWORK General The Contractor is referred to the civil and structural specification which is embodied within these preambles for items referring to Blockwork.
Where sheet damp-proof courses are measured, the requirement that "no allowance in measurement has been made for laps" shall be deemed to be included in the description.

Where reinforcement in walls is measured, the requirement that "no allowance in measurement has been made for laps" shall be deemed to be included in the description.
BS and CP References BS 12 BS 890 BS 1198-1200 BS 882 BS 743 BS 5628 BS 4887 CP 101 CP 012 CP 111 CP 121 Portland Cement Limes Sand Aggregate Damp proof courses Structural use of masonry Mortar plasticisers Foundations Protection from ground water Structural recommendations Block walling Barbados National Standards Institution BNS 69 BNS 38 Protection Portland cement Hollow concrete blocks Protection of finished work is clearly imperative at all times and the Architect reserves the right to condemn work previously accepted if subsequently damaged and to withhold further payment until the work has been rectified.
The amount included for the item is deemed to include for the protection of all finished work and where no price is included against this item, it will be assumed that the Contractor has included elsewhere in the Bills for these costs.

A B C D E F MW/9 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) ROOFING Testudo Spunbond System A The whole surface to be covered shall be primed with an adhesive bituminous coat, ie.
a bituminous solution based on oxidised bitumin, additives and solvents which has 50% solids content and a FORD Viscosity no, 4 at 251C from 20 to 25 sec.

The waterproofing shall consist of a 4 mm thick TESTUDO SPUNBOND 20 membrane with FLAMINA based on elastomers and bitumen modified with polypropylene, reinforced with a continuous single strand extruded polyester non woven isotropic fabric.
The sheets shall have an ultimate longitudinal and transverse tensile stress of 80 Kg/5 cm and 70 Kg/5 cm respectively, a length and transverse ultimate elongation equal to 50% a hydraulic pressure resistance to burse on free discs including a 177 cm5 ie.

3 Kg/cm5 surface and a high resistance to 1000 fatigue cycles on active slit opening 3mm in both directions.

A cap sheet of MINERAL DEFEND 3.5 Kg should be placed parallel with and astride the overlaps of the previous layer.
Fixing must be by fully flame welding to the lower surface, allowing for 10 cm overlaps and then being turned and flame welded on the vertical section to a minimum height of 20 cm above the maximum water level.

A five year guarantee is to be provided.

Metal Roof Sheeting B Colourclad roof sheeting shall be 24 gauge with a minimum of PVF 2 Finish comprising 5 microns anti-corrosion primer with 20 microns PVF 2 finishing on both sides of the sheeting.

The colour shall be white.


The roof sheets shall be fixed to wood purlins with wood grip fasteners (self-drilling 12" long spaced every 12" along the purlin.

The roof sheets shall be fixed to steel purlins with metal fasteners (self-drilling) 12" long spaced every 24" along side lap and 12" along the purlin.

Fasteners shall have the pre-painted to match the roof sheeting.
Roof sheeting shall be installed completely with all flashings, ridge, hip coverings, eaves strips, etc., and shall be left complete watertight on completion.

A ten year guarantee is to be provided.

MW/10 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) ROOFING (Cont’d) Protection A Protection of finished work is clearly imperative at all times and the Architect reserves the right to condemn previously accepted work if subsequently damaged and to withhold further payment until the work has been rectified.
The amount included for the item measured under Clause M61 of the SMM is deemed to include for the protection of all work and where no price is included against this item, it will be assumed that the Contractor has included elsewhere in the Bills of Quantities for these costs.
MW/11 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) CARPENTRY AND JOINERY Timber Generally A B C D Timber shall be sound with reasonably straight grain and at least 85% heartwood, free from large shakes, waney edges splits, loose or dead knots, worm, rot, fungus, decay or infestation.
Pitch Pine Pitch pine shall be best imported quality of mature growth, free from gross defects, well seasoned and having a minimum density of 673 Kgs/m3 and an average equilibrium moisture content of 10 per cent in accordance with BS 1186 Part 1.

Hardwood Purple heart, mahogany and green heart shall be the best quality available and must be free from gross defects.
The Contractor must exercise care in selecting this timber and shall notify the Architect and obtain his written approval of the type and sources of the hardwoods he proposes to use.
Treated Timber Treat softwood against termite attack and decay damage by wolmanising or similar pressure/vacuum impregnation with an approved preservative in order to obtain a minimum net chemical retention of 8.01 Kgs/m3 of timber in accordance with the manufacturer's instructions and thereafter either air dry or kiln dry all timber to the satisfaction of the Architect.

Provide a certificate of treatment from the timber suppliers if requested by the Architect.
Where cross cutting or boring of treated timber is unavoidable, liberally swab or dip treat all exposed faces with an approved preservative.

Where timber is described as having a natural oiled or varnished finish, an approved clear preservative shall be site applied to the approval of the Architect.

Wood preservation is to be in accordance with BS 4072.

Plywood E Plywood shall conform to BS 6566 and marine plywood shall conform to BS 1088.
Where plywood is to have a natural or varnished finish, Grade 1 shall be used.

Where plywood is to be painted, Grade 2 may be used.

MW/12 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) CARPENTRY AND JOINERY (Cont'd) Tolerances A All structural timbers shall be sawn timbers to the section given on the drawings.

Permissible tolerance on cross section dimensions will be ¼” and 1/8” with no allowance for wane.
B Exposed Faces Timber which is to be exposed in the finished work shall be 'dressed' unless otherwise described.

The term 'dressed' where used in this document shall mean the hand selection of timber members and site preparation by means of planer and/or belt sander.

NB: Where the term 'nominal size' is used in this document, it shall mean the sawn size and where timbers are to be wrought or dressed 3mm shall be allowed from the nominal size for each wrought face or edge.
C Plastic Laminate Plastic laminate shall be 2mm 'Formica', 'Arborite' or equal and approved and comply with the BS 3794 and be bonded to plywood or timber backing with synthetic resin adhesive to BS 1204 strictly in accordance with the manufacturer's printed instructions.

Solid Surfacing D Solid surfacing shall be ½” thick Wilsonart Gibraltor or 1/8” Wilsonart SSV fixed to ½” thick chipboard backing.

E Joinery Work All joinery work shall be carried out in accordance with BS 1186, Part 1 & 2.
F Carpentry Work All carpentry work shall be carried out in accordance with CP 112.

G Natural Finish When natural finish or finish for staining, clear polish or varnishing is specified, the timber in adjacent pieces shall be selected and matched to be uniform and symetrical in colour and grain.
MW/13 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) CARPENTRY AND JOINERY (Cont'd) A Fixings All fixings, plates, shoes or straps shown on the drawings shall be neatly formed out of mild steel plate drilled and welded as necessary.

Prior to erection, all mild steel components shall be wire brushed and primed with one coat of red zinc chromate primer.

All surfaces in contact with wood shall be painted a further two coats of bituminous paint.

All fixing accessories shall conform to BS 1494.


B Ironmongery Provide samples of all ironmongery for selection by the Architect without charge.

Carefully wrap and protect all ironmongery until completion of the work and replace any which may be defaced or damaged without charge as the Architect shall direct.

Oil all locks and adjust and leave in perfect working order on completion and properly label all keys and deliver up in accordance with the Architect's instructions.
Fix all ironmongery with screws of the same metal and finish as the fitting themselves.

Remove and replace with new ones all screws damaged when driven by the turnscrew or from any other cause.

Remove all ironmongery when painting or carrying out other works likely to damage the fittings and replace on completion.

C Door Frames and Doors Door frames shall be constructed to conform with BS 1567 and BS 4748 Part 1, and where frames are to be painted, shall be primed on all faces prior to fixing.
Doors shall be constructed in the joinery shops of the Contractor or by a specialist joinery manufacturer and not upon the site.

Timber for use in doors shall be specially selected for straightness and freedom from faults, tenoned, glued and wedged or pinned together.
Furnish the owner with an extended guarantee to warrant wood framed doors solid core flush wood doors against warping, twisting, core ghosting, swelling, sagging, splitting and delamination for a period of three (3) years from the date of the certificate of Practical completion of the work.

D External Doors External doors shall conform to BS 459 and BS 4787.
Framing shall comprise 100mm wide stiles top and bottom rails, securely tenoned and glued together having intermediate rails filling 60% of the core void.

Plywood facings shall be in accordance with BS 1186 and 4mm thick.

Facings shall be glued to framing with Type WPB glue to BS 1204.

MW/14 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) CARPENTRY AND JOINERY (Cont'd) A Internal Doors Internal doors shall conform to BS 459 and BS 4787.
Framing shall comprise 100mm wide stiles, top and bottom rails securely tenoned and glued together having intermediate rails filling 40% of the core void.

Plywood facings shall be in accordance with BS 1186 and 4mm thick.

Facings shall be glued to framing with Type MR glue to BS 1204.

Hollow Metal Doors B Hollow metal doors as manufactured by S.W.

Fleming Limited, or approved equal, slab type constructed of not lighter than 16 gauge (1.6mm) steel with solid fiberglass core.
Face sheets and all internal components to be made with A40 paintable galvanneal steel.

The doors shall be flush faced with no face seams, and having continuously welded edge seams on all edges, weld 20 gauge (90mm) interlocking stiffeners at 6” (150mm) centres.
The door frames: single piece welded frames of pressed steel with mitred corners of approved manufacture to suit details on the drawings, from not lighter than 16 gauge (1.6mm) Build units square, true, accurate to size, free from distortion, waves, twists, buckles or other defects detrimental to appearance and performance.

Provide all holes for connections and fastenings.

Continuously weld corners and joints of metal doors along the inside.

Grind smooth and flush.


Reinforce hollow metal doors and door frames and prepare for hardware application in the shop.

Reinforce frames for door closer or holder bracket.

Cover reinforcement plates or attachments and cutouts with light metal boxes to protect against mortar.

Provide channel or angle spreaders (2 per frame) at the bottom of door frames to ensure proper alignment, with removable spreaders.
Where metal frames are to be built into masonry provide three adjustable “TEE” anchors for each jamb under 2.1m (6’10”), four anchors for jambs over 2.1m high.

Reinforce head of frames wider than 1.2m (4’0”).

Prime paint hollow metal doors, frames and accessories after fabrication with one coat of baked-on rust inhibitive primer.
MW/15 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) CARPENTRY AND JOINERY (Cont'd) Detention Grade Metal Doors A Detention doors shall be as manufactured by Apex Industries Inc., or equal and approved.

Doors shall be 50mm thick constructed of 12ga steel flush faced with no seams, continuously welded edge seams.

Window Frames and Windows B Windows shall be constructed to conform with BS 644 and where frames are to be painted, shall be primed on all faces prior to fixing.
Windows shall be constructed in the joinery shops of the Contractor or by a specialist joinery manufacturer and not upon the site.

Timber for use in doors shall be specially selected for manufacturer and not upon the site.

Timber for use in doors shall be specially selected for straightness and freedom from faults, tenoned, glued and wedged or pinned together.
Furnish the owner with an extended guarantee to warrant window frames and windows warping, twisting, core ghosting, swelling, sagging, splitting and delamination for a period of three (3) years from the date of the certificate of Practical Completion of the work.

C Storage of Materials Materials shall be protected from the weather during transit to the site and shall be stored clear of the ground in a clean, dry, ventilated enclosed structure.
Where timber for carpentry and joinery work is incorporated into the works, the Contractor is to ensure that adequate protection is provided to prevent staining or damage caused by inclement weather or other causes.
BS and CP References D Nails Fixing accessories Connectors for timber Strength of structural softwood Drive screws Softwood flooring Softwood Wood battens BS 1202 BS 1494 BS 1579 BS 1860 BS 4174 BS 1297 BS 4471 Part 1 BS 4471 " 2 BS 1186 Parts 1 & 2 Quality of timber in joinery BS 1210 BS 1455 BS 1088 Wood screws Plywood Plywood, marine MW/16 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) CARPENTRY AND JOINERY (Cont'd) BS and CP References (Cont’d) BS 3493 BS 3842 BS 584 BS 644 BS 4787 :459 BS 1567 BS 5212 BS 585 BS 1195 BS 1292 BS 5756 BS 6375 BS 4190 BS 4072 CP 98 CP 112 CP 201 Part 1 CP 151 " 2 Generally Information about plywood Preservatives for plywood Wood trim Windows Doors Door frames and linings One part gun grade polysulphide based sealants Stairs Kitchen fitments Storage fitments Tropical hardwood Performance of windows Isometric black bolts, screws and nuts Wood preservation Preservative treatments Structural use of timber Wood flooring Doors, windows and frames.
A B The work is to be framed as soon as possible after the Contract is signed and it is to be kept in a dry place under cover and arranged so that a current of air can freely circulate around it but must not be wedged up until required for fixing.
Should any joints give or open in the least before the maintenance period has expired, such defective joinery is to be taken down, refitted and redecorated or replaced by new joinery as the case may be and all work disturbed made good at the Contractor's expenses.

Construction The Contractor shall be responsible for sound construction of components using recognised forms of joints in appropriate positions where these are not specified.

Joints shall be in accordance with BS 1186 Part 2.


In framed work all joints shall be mortice and tenon, wedged and glued where required.

Faces of members jointed shall be flush with one another when intended to be so.

MW/17 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) CARPENTRY AND JOINERY (Cont'd) A Exposed timber shall be secret nailed wherever possible.

Where it is not possible to secrete nail, nails shall be punched below the surface and the depression filled flush with putty and sanded off.
Carpentry Generally B The whole of the carpentry work is to be framed, fixed and executed in the best and most workmanlike manner.

Joints shall be so placed that knots do not occur in tension zones.

The word 'framed' is to be understood as including all the best methods of jointing woodwork together by mortice and tenon, dovetail or other method.
In addition, the quality of workmanship for structural timber shall be not less than that recommended in CP 112 Part 5, as modified by any specific requirements given in this Specification.

Joinery Generally C The quality of workmanship shall be not less than that set out in BS 1186 Part 2, as modified by any specific requirements given in this Specification.
Nails, sprigs, etc., shall be punched below the surface; holes shall be stopped with putty or other equal and approved filler specially selected to match colour and texture of timbers which are to be polished, etc.

Screws (other than brass screws with cups) shall be countersunk head wood screws driven to 1/12" below the surface.
Screw heads in work for painting shall be stopped in putty or other equal and approved filler before any trace of rust appears; all rusted screws shall be replaced before painting.

Screw heads in work described as flush pellated shall be let in at least 1/4" below the surface and pellated in grain with matching hardwood glued in.

Cross tongued joints shall be glued.

All joinery that is to be painted shall be knotted and primed with the primer before being fixed.
This applies particularly to the 'covered up' or 'hidden' parts of joinery work.

All external joinery work shall be put together in a thick mixture of red or white lead and linseed oil or waterproof adhesive.

The arrangement, jointing and fixing of all joinery works shall be such that shrinkage in any part and in any direction shall be compensated in the joints and shall not impair the strength and appearance of the finished work and shall not cause damage to contiguous materials or structures.
MW/18 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) CARPENTRY AND JOINERY (Cont'd) Framed Joinery A Joinery work described as 'framed' shall be jointed using mortice and tenon, combed or dovetail joints only.

Construct joinery exactly as shown on the Architect's details.

Where joints are not specifically indicated they shall be the recognised forms of joints for each position.
Surface Finish on Joinery B The surface finish on joinery shall be such that if properly finished with a gloss paint, imperfections in manufacture will not be apparent.

Double Tenons C Lock rails shall have double tenons.

Cutting back Tenons D E F G Tenons in the edges of door stiles to receive clear finish shall be cut back 1/4" and made good with matching wood.
Door Frames and Linings Door frames and linings shall be constructed in accordance with BS 1567 and BS 459 Part 3, except that profiles and sizes of individual members shall be as detailed.

Priming before Fixing Priming of (or first coat of clear treatment on) joinery before fixing has been specified in the painting section but rates for joinery shall include for priming, lacquering or varnishing (as appropriate) any surface exposed by cutting and fitting.
Tolerances All structural timber shall be sawn timbers to the sections given on the drawings.

Permissible tolerances on cross- section dimensions will be plus 1/4" and minus 1/8" with no allowance for wane.

Provide reasonable tolerance at all connections between joinery work and the building carcass so that any irregularities, settlements or other movements shall be adequately compensated for.
MW/19 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) CARPENTRY AND JOINERY (Cont'd) Shrinkage A B C Arrange, joint and fix all joinery work in such a manner that shrinkage in any part and in any direction shall not impair the strength and appearance of the finished work and shall not cause damage to adjoining material or structure.
Fixing to Blockwork or Concrete Where timber is described as plugged or fixed to blockwork or concrete it shall include for cutting holes as required and for supplying and fixing wooden plugs treated with termite fluid.

Alternatively, plugs may be 'Rawlplug' or other approved proprietary make.

The use of any approved system of fixing to blockwork or concrete with special nails, screws or bolts, inserted with spring cartridges or power tools will be permitted in lieu of plugging.
Protection Protection of finished work is clearly imperative at all times and the Architect reserves the right the condemn work previously accepted if subsequently damaged and to withhold further payment until the work has been rectified.

The amount included for the item is deemed to include for the protection of all work and where no price is included against this item, it will be assumed that the Contractor has included elsewhere in the Bills for these costs.
MW/20 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) METALWORK General A Mild steel plates, bars, sections, tubes, etc., shall conform to BS4360.

The surface of steel shall be smooth, clean and free from rust.

Loose rust and scale shall be removed from the steel prior to despatch from the works, and any subsequent accumulation of dirt, oil or grease shall be cleaned off immediately prior to erection.
Welding B Weld by an approved method using suitably qualified operatives to give ductility and tensile strength comparable with that of the metal joined.

Grind all soldered or welded joints, seams, etc., to a smooth finish, remove all rough edges and leave the whole perfect to the satisfaction of the Architect.
C D E F Forged Work Clean all forged work and put together in the best and most workmanlike manner, drill all holes and clear off burrs and ensure that all counter-sinkings are concentric and threads and tappings are accurately fitted.

Bolts All bolts unless otherwise described shall be BS Whitworth black bolts with hexagonal heads and nuts and round washers.

Use splayed washers where necessary to effect tight joints.

Fixing Form all mortices, chases, etc.


and securely anchor to the structure all metalwork and make good the surfaces to which they are fixed.

Leave Clean Clean all exposed metal surfaces on completion with water or an approved petroleum product such as methylated spirit or kerosene.

Make good any damage caused by the use of an improper cleaning material.

Painting of metal work is described in the Painting and Decorating Section of these Preambles.
MW/21 A B MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) METAL WORK (Cont’d) BS and CP References BS 4190 BS 4360 BS 1387 BS 729 (Part I) Bolts Weldable structural steels Steel tubes and tubulars Galvanizing.

Protection Protection of finished work is clearly imperative at all times and the Architect reserves the right to condemn work previously accepted if subsequently damaged and to withhold further payment until the work has been rectified.
The amount included for the item is deemed to include for the protection of all work and where no price is included against this item, it will be assumed that the Contractor has included elsewhere in the Bills for these costs.
MW/22 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) FLOOR, WALL AND CEILING FINISHES General A B C Where a manufacturer's name or the proprietary name of an article appears in this section, it is given as an indication to tendering contractors of the standard and description required and contractors may quote for any manufacturer's article, provided it is of the standard and description specified and approved by the architect in writing, prior to the submission of tender.
Vinyl Tiles Vinyl floor tiles shall be vinyl tiles to BS 3260 laid with an approved adhesive all in accordance with the manufacturer's printed instructions and with CP 203.

On completion of the works the tiles are to be thoroughly cleaned and two coats liquid floor polish applied.

Porcelain/Ceramic Tiles Porcelain/Ceramic tiles shall be unglazed to BS 6431 Parts 2 & 6, and shall be laid in accordance with BS 5385.
Tiles shall be laid with BAL-CEM GOLD STAR cement based tile adhesive to BS 5980, possissing Class AA water resistance with BAL-ADMIX ADI additive.

Joints between tiles shall be a constant width 3 mm wide.

Floor tiles shall be grouted with BAL-EPOXY GROUT WF.

The joints shall be completely filled.

BAL products are manufactured by Building Adhesives Limited, Longton Road, Trenthan, Stoke-on-Trent, Tel.

0782 859921: Fax 0782 643909.

The manufacturer's printed instructions must be strictly adhered to.
Cement/Sand Bed D Screeds shall be laid in accordance with CP 204.

Mix screeds of cement and sand (1:4) and lay to the thickness described.

Finish screeded beds with a rough surface to receive ceramic tiles and a steel trowelled surface to receive vinyl asbestos tiles, ceramic tiles when fixed with approved adhesive and floor paint.

Thoroughly brush clean surfaces to receive screeds of all foreign matter and well soak prior to laying screed.
Provide an adequate bond between screeds and in-situ concrete by the use of an approved concrete bonding agent or by well hacking, wetting and applying cement grout immediately prior to laying the screed.

MW/23 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) FLOOR, WALL AND CEILING FINISHES (Cont’d) An approved hardener is to be added to the cement/sand mix such as 'Cementone No.

8' 'Lithurin' or other equal and approved.

Beds shall be laid in bays not exceeding 375 square feet.
Edges of adjoining bays shall be well hacked and wetted prior to laying the next day.

Immediately the beds are laid, they shall be cured and protected for at least five days to prevent damage or shrinkage of any kind.

The method of curing is to be approved by the Architect.

Levels Generally A Ensure that the levels of floors within any one area and between adjoining areas are constant unless specifically described or shown to be otherwise.
Make up for any variations in the thickness of precast or premoulded floor finishings and irregularities in the surface of the structural base by adjusting the thickness of the screed as necessary.

Protection B Protect all premoulded floor finishings from walking or other disturbance for five days after laying.

Cover all floors up to the completion of the works with a temporary covering approved by the Architect.
On completion of the works, remove covering, clean off stains and mortar splashes, etc., from the floors and leave perfect for handing over.

Wall Finishes: Rendering C Mix rendering of cement and sand (l:4) including a plasticiser additive at the rate as detailed in the manufacturer's printed instructions.

Proportion materials by measure and not by estimation and provide proper approved measuring boxes for this purpose.

Make up mix on site in a close boarded wood platform with upstand edges.
Where approved mechanical batch mixers are employed, rotate each batch in the drum at least two minutes and use immediately thereafter.

Mix only quantities which can be used at once and reject rendering which has begun to set before being required.

Carefully float all work and finish to the stated thicknesses with surfaces perfectly flat to stand the straight edge every way, free from all cracks and leave perfectly clean.

External angles shall be true and slightly rounded.
MW/24 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) FLOOR, WALL AND CEILING FINISHES (Cont'd) Walls A 'Throw' all rendering and plaster onto the wall and give the minimum of 'working' to ensure a plumb and even finish.

Complete each section of walling in one operation but where this is not possible, the existing edge shall be well hacked and wetted before recommencing operations.

Throughout the whole of the works, order sufficient sand to prevent any discrepancy between the quality of different renderings.
Thoroughly prepare and set all surfaces prior to commencement of operation and allow for any additional thicknesses required in dubbing out and for working around and behind pipes with their connections and fixtures.

An approved filler shall be applied to the surface of internal and external plasterwork to obtain a smooth surface suitable to receive the finishing decoration.
The raking out of joints or hacking faces of blockwork to provide a key for rendering have been referred to in the Blockwork section of these preambles.

The prices for rendering on concrete surfaces shall include for hacking the face of concrete to provide a key.

Glazed Wall Tiling B Glazed wall tiles shall be of sizes and thicknesses specified and shall be accurately fixed to floated backing with cement and sand (l:5) and grouted with white cement.
Alternatively, tiles may be fixed with an approved tile adhesive and grouted with white cement.

All tiles shall be of the cushion-edge type.

All external angles shall be rounded edge tiles of radius approved by the Architect.

Tiles shall be in accordance with BS 1281 and BS 5385, Part 1.

C Plasterboard Gypsum wall board to BS 1230 Part 1 type 1 shall be taper edged boards fixed with plasterboard screws or flat head nails as BS 8212 Clause 6.3.
Boards shall be as manufactured by British Gypsum Limited and shall be installed in accordance with BS 8212 and the manufacturers printed instructions.

Wall boards shall be jointed by applying jointing compound to the depression between the boards, firmly embedding the jointing tape, covering it with the jointing compound and striking off flush.

Finishing compound shall be applied over the joint and feathered out approx.

2".
2".

This process shall be repeated and feathered out a further 2" beyond the first application, finished flush and smooth.

Nail holes shall be filled and finished flush.

MW/25 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) FLOOR, WALL AND CEILING FINISHES (Cont'd) Textured Ceiling Finish A The underside of fair face concrete slabs shall be rubbed smooth to remove all projections and all small voids are to be filled with an approved filler.
Textured ceiling finish shall be 1mm interior grade white Berger textured finish or other equal and approved by the Architect.

Suspended Ceiling Systems B The suspended ceiling system shall be acoustical non-combustible mineral fibreboard with standard type suspension hung directly from concrete soffits.

The suspended ceiling system shall be installed in accordance with CP 290 by skilled workmen.

The suspension systems shall be supported by No.


12 gauge steel hanger wires secured to the concrete soffit and the exposed grid framing shall be securely fixed to the hangers.

The lay-in panels shall be set loose within the grid and care shall be taken not to stain or damage the panels on the exposed face or on the edges.

The installation must be carried out in accordance with the Manufacturer's written instructions, all to the satisfaction of the Architect.
The panels shall have factory applied washable white vinyl latex paint finish.

The suspension system shall be exposd grid type with electro-galvanised steel framing finished on exposed surface with low sheen satin white enamel.
Spares C The Contractor is to supply the Employer at practical completion of the works with the following spares: - Floor and Wall Ceramic tiles - Suspended ceilings: - Carpet tiles - Vinyl tiles - 2% of quantity - - - 1 box tiles 2 boxes 1 box MW/26 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) FLOOR, WALL AND CEILING FINISHES (Cont'd) BS and CP References Portland Cement BS 12 BS 1199 Sand for screeds and plaster BS 1369 Metal lathing BS 1246 Glazed wall tiles BS 5262 External rendering Internal rendering BS 5492 Internal wall tiling BS 5385 Dry linings BS 8212 Installation of textile floor coverings BS 5325 Inflexible floor tiling CP 202 CP 203 Flexible floor tiling In-situ floor finishes CP 204 Suspended ceilings CP 290 Protection Protection of finished work is clearly imperative at all times and the Architect reserves the right to condemn work previously accepted if subsequently damaged and to withhold further payment until the work has been rectified.
The amount included for the item is deemed to include for the protection of all work and where no price is included against this item, it will be assumed that the Contractor has included elsewhere in the Bills of these costs.

A B MW/27 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) PLUMBING INSTALLATION Generally A The whole of the work shall be carried out in accordance with the Byelaws and Regulations of the Sanitary Water and Gas Authorities and to the entire satisfaction of their inspectors.
The entire plumbing and drainage installation shall be carried out by experienced craftsmen under the supervision of a competent foreman to the entire satisfaction of the Architect.

Rainwater Pipes and Fixtures B Rainwater pipes and fittings shall conform to BS 4576 Part 1, with spigot and socket joints and neoprene sealing gaskets conforming to BS 2494 Part 2.

All pipes for use as soil and waste pipes shall comply with the provisions of BS 4514 and those for cold water service pipes with BS 3505.
Fittings shall be of the solvent weldable type.

Brackets and clips shall be of non-ferrous metal or PVC coated steel.

Traps shall comply with the provisions of BS 3943 and have a 75mm deep seal.

PVC Pipes C D E PVC pipes for use as soil and waste pipes shall comply with the provisions of BS 4514 and those for cold water service pipes with bs 3505.

Fittings shall be of the solvent- weldable type.

Brackets and clips shall be of non-ferrous metal or PVC coated steel.
Traps shall comply with the provisions of BS 3943 and have a 75mm deep seal.

Polythene Pipes Polythene pipes for use as cold water service pipes shall comply with the provisions of BS 1972 or BS 3284.

Fittings shall be of the solvent weldable type.

Brackets and clips shall be of non-ferrous metal or PVC coated steel.

Galvanized Steel Pipes Galvanized steel pipes shall comply with the provisions of BS 1387.

Fittings, clips, brackets and hangers shall be galvanized steel, wrought or malleable iron.
Joints shall be screwed and socketed.

Unless otherwise described, pipes shall be of medium weight (blue band).

Lightweight (brown band) pipes shall not be used.


MW/28 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) PLUMBING INSTALLATION (Cont’d) Copper Pipes A B C D E F Copper pipes shall be light gauge pipes complying with the provisions of BS 2781 Part 1, underground pipes complying with the provisions of Table Y. Fittings shall either be of the capillary type (Yorkshire, Wendesbury or equal) or 'compression' type (Securex or equal) as described and conforming with BS 864 Part 2.
Alternatively, fittings may be site made and bronze welded provided that this is carried out by thoroughly experienced workmen.

Pipe clips, brackets and hangers shall be of copper, brass, bronze or gun metal.

Stainless Steel Pipes Stainless steel pipes shall comply with BS 4127 Part 2.

Fittings shall be either capillary or compression type as specified for copper pipes.

Valves All valves, taps, cocks, etc., shall be fullway and comply with the provisions of BS 1010 where applicable.
They shall be fixed so as to be easily accessible and so that re- washering may be carried out without the necessity for cutting away walls, etc.

Bending Pipes Wherever possible, bends shall be made in the run of the pipe.

Bending springs, sand loading or other suitable means shall be employed to ensure a true diameter all round the length of the bend.

Fixing Pipes Soil waste and overflow pipes shall be fixed vertically or at 221 from the horizontal.
Water pipes shall be fixed vertically or with slight falls towards draw-off points to facilitate draining off of the system.

Overflow pipes shall be fixed to discharge in readily observed positions.

Workmanship All plumbing work shall be carried out be skilled workmen and by or under the supervision of a licensed Sanitary Contractor and in conformity with the Regulations of the Sanitary and Water Authorities.
Installation shall comply with CP 304 for Soil and Waste Pipes above ground, with CP 310 for Water Service and Distribution Pipes and with CP 312 for Plastic Pipework.

MW/29 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) PLUMBING INSTALLATION (Cont’d) Testing A B C The testing of pipework and fittings shall be carried out to the satisfaction of the Architect and Sanitary and Water Authorities.
The Contractor is to include in his prices for testing which shall include for supplying all necessary appliances, water and attendance.

Cutting, Patching, Repairing, etc.

The Plumbing sub-contractor shall furnish the Contractor with the sizes and locations of chases and openings in walls, partitions, etc., before they are built.
The Contractor shall furnish and install, without delay in the execution of the work of other trades, the sleeves or boxes in the form of floor slabs for all his pipes before the floor slabs for all his pipes before the floor slabs are poured.

The Contractor shall do all drilling required for the installation of hangers.

All cutting of walls, partitions, floors, etc., required for the installation of work called for under this section, will be done by the Contractor.
Cutting of structural members shall not be done without the approval of the Architect.

All patching will be done by the General Contractor.

Any cutting or patching required in connection with the installation of this work, due to errors on the part of the Plumbing sub-contractor, shall be paid for by him.
Excavation and Backfilling The Contractor shall do all excavating and backfilling necessary to the installation of work, including the patching and repair of pavements, shall provide all sheeting and shorting required to perform and protect the excavations and to safeguard employees and shall remove from the premises all rubbish and surplus earth occasioned thereby.

Trenches shall not be backfilled until the facilities therein have been tested and the work has been accepted as tight.
BS and CP References D BS 864 BS 1010 BS 1387 BS 1415 BS 1972 BS 2494 (Part 2) BS 2871 (Part 1) BS 3284 Capillary and compression type fittings of copper and copper alloy Draw-off valves and stop valves Steel tubes Mixing valves Polythene pipe for cold water services Neoprene gaskets Copper tubes Polythene pipe for cold water services MW/30 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) PLUMBING INSTALLATION (Cont'd) BS and CP Reference (Cont’d) BS 3505 BS 3943 BS 4346 BS 4515 BS 4576 (Part 1) U PVC pipe for cold water services U PVC traps Joints and fittings PVC pipes U PVC soil and waste pipes Rainwater pipes and fittings CP 304 CP 310 CP 312 Soil and waste pipes Water supply Plastic pipework Barbados National Standards Institution A BNS CP 16 (Part 1).
Protection B Protection of finished work is clearly imperative at all times and the Architect reserves the right the condemn work previously accepted if subsequently damaged and to withhold further payment until the work has been rectified.

The amount included for the item is deemed to include for the protection of all work and where no price is included against this item, it will be assumed that the Contractor has included elsewhere in the Bills for these costs.
MW/31 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) ELECTRICAL INSTALLATION Regulations A B C All electrical work shall be carried out in strict conformity with local regulations and a certificate of test from the Government Electrical Inspectorate shall be handed to the Architect by the Main Contractor at completion of the work.
Drawings Drawings and/or diagrams giving details of the circuits, panel boards, etc., as installed shall be prepared by the Contractor or nominated sub-contractor and 2 copies handed to the Architect at completion of the work.

Where an Electrical sub-contractor has been nominated, the sub-contract amount shall be deemed to include for the preparation of the aforementioned drawings.

Cutting, Patching, Repairing, etc.


The Electrical sub-contractor shall furnish the Contractor with the sizes and locations of chases and openings in walls, partitions, etc., before they are built.

The Contractor shall furnish and install, without delay in the execution of the work of other trades, the sleeves or boxes in the forms of slabs, beams and columns for all conduit and fittings before concrete is poured.
The Contractor shall do all drilling required for the installation of hangers, supports, etc.

All cutting of walls, partitions, floors, etc., required for the installation of work called for under this section, will be done by the Contractor.

Cutting of structural members shall not be done without the approval of the Architect.

All patching will be done by the General Contractor.
Any cutting or patching required in connection with the installation of this work due to errors on the part of the Contractor or Electrical sub-contractor shall be paid for by him.
Excavation and Backfilling D The Contractor shall do all excavating and backfilling necessary to the installation of the work, including the patching and repair of pavements; shall provide all sheeting and shoring required to perform and protect the excavations and to safeguard employees and shall remove from the premises all rubbish and surplus earth occasioned thereby.

Trenches shall not be backfilled until the facilities therein have been tested.
MW/32 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) ELECTRICAL INSTALLATION (Cont’d) Protection A Protection of finished work is clearly imperative at all times and the Architect reserves the right to condemn work previously accepted if subsequently damaged and to withhold further payment until the work has been rectified.
The amount included for the item measured under Clause T43 of the SMM is deemed to include for the protection of all work and where no price is included against this item, it will be assumed that the Contractor has included elsewhere in the Bills for these costs.

MW/33 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) GLAZING Generally A Glass shall be obtained from an approved manufacturer and shall conform to BS 952.
All glass shall be delivered in proper containers with maker's name, guarantee, type of glass and thickness or weight of glass attached to the outside of the containers.

The work shall be carried out in accordance with BS 6262.

Sheet glass B Sheet glass shall be selected glazing quality (SQ) and of the weights and thicknesses stated.

Float and Plate glass C Float glass and plate glass shall be of the thicknesses stated and be perfectly flat and true.
D E Wired glass Georgian wired glass shall be 3" thick and be perfectly flat and true.

When set in position, the wires shall be perfectly horizontal and vertical and align with those of adjacent panes.

Glazing Cut glass to sizes required as measured on site with a small clearance and set plumb, square, level and at their proper elevation and plane and locate in proper alignment with other work.

Cut louvre blades to sizes specified and polish arrised edges.
The Contractor is to allow for cleaning all stains from the glass both inside and out and for leaving perfect to the satisfaction of the Architect.

All glass and timber fixing beads are to be fully bedded in mastic compound.

MW/34 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) GLAZING (Cont’d) Mirrors A Mirrors shall be of selected quality polished plate glass silvered and enamelled after cutting, polishing edges and drilling.
Fix mirrors with chromium plated dome headed screws and plastic washers to walls with 3/8" thick plywood backing, lipped all round with hardwood lipping.

BS and CP Reference BS 952 BS 4315 Part 1 BS 5215 BS 544 BS 6262 Glass for glazing Methods of test for resistance to air and water penetration One part gun grade polysulphide based sealants Linseed oil putty Glazing of buildings CP 145 Patent Glazing.
Protection B Protection of finished work is clearly imperative at all times and the Architect reserves the right the condemn work previously accepted if subsequently damaged and to withhold further payment until the work has been rectified.

The amount included for the item, is deemed to include for the protection of all work and where no price is included against this item, it will be assumed that Contractor has included elsewhere in the Bills for these costs.
MW/35 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) PAINTING AND DECORATING Generally A All painting shall be carried out in accordance with BS 6150.

All materials used unless otherwise stated, shall be anti-fungus.

Supply paints on site in sealed cans bearing the manufacturer's name and all thinning, mixing, etc., shall be in accordance with the manufacturer's instructions.
Produce vouchers as and when required by the Architect to prove to his satisfaction that all materials supplied are genuine and as specified herein.

Preparation B Thoroughly dust and clean down all surfaces to be painted, cut out and fill cracks, stop holes, treat knots and resin pockets in wood with two coats knotting varnish and clean steelwork of rust, oil, grease, scale and moisture, all in accordance with approved practice.
Apply an approved filler to the surface of internal plasterwork to provide a smooth surface where painting is specified.

Previously painted surfaces must be thoroughly cleaned to remove all dirt, grease, etc.

All loose and flaking material to be rubbed down with a fine grade sandpaper and touch primed.

Aluminium and zinc must be washed with a detergent to remove all grease and treated with a self etching primer.
Before applying polyurethane varnish or wood stain, the wood must be perfectly dry and rubbed down with fine sandpaper to remove all dust and debris to provide a smooth, clean surface.

All nail holes and other defects in timber shall be filled with putty or other approved filler after priming and rubbed down to give a smooth surface.

The backs of all joinery surfaces, notches, etc., and where areas are to be hidden by the fixing of, metal work shall be primed before these are fixed in position.
Concrete surfaces are to be smooth and even, free from loose sand, mortar splashes and efflorescence with all small voids filled with an approved filler, prior to receiving painted finish.

The Contractor is to allow in his price for all such preparatory work.

MW/36 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) PAINTING AND DECORATING (Cont’d) Application A Apply paint by brush, roller or spray with the minimum of dilution.
Strain the prepared paint free from skins and similar impurities immediately before application.

Allow to dry and well rub down each coat of paint before the next is applied and no two successive coats shall be to the same tint.

No paint shall be applied to a damp surface and no external painting shall be carried out during wet weather.

Remove metal hardware and fittings before painting to general surfaces and afterwards refix.
Alternatively, they shall be adequately protected to prevent being marked by paint.

Allow for carrying out work in such positions and in such order as shall be directed by the Architect.

Cover and protect all surfaces which may become marked by paint and thoroughly clean all surfaces throughout, after completion of the work, all to the satisfaction of the Architect.
On no account shall the Contractor allow employees to empty washings or painting materials into sanitary fittings or drainage systems and shall provide a suitable receptacle outside the building to receive same.

Brand Names B C All brand names of painting materials shall be approved by the Architect.

Oil paint shall be best quality alkyd enamel or equivalent grade.

Prepare surfaces and apply paint in strict accordance with the specifications of the manufacturer of the brand approved by the Architect.
Colour Schemes Allow for varying colours in the individual rooms in accordance with the Architect's colour scheme and also for executing fairly large sample panels of the finishing colours, as and when directed by the Architect.
MW/37 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) PAINTING AND DECORATING (Cont’d) BS and CP References A Linseed oil putty Water paints Oil stains Classification of wood preservatives Knotting BS 544 BS 1055 BS 1215 BS 1282 BS 1336 BS 2521 BS 2523-4 BS 3698 BS 2525-2527 Undercoating and finishing paints exterior BS 4800 Paint colours for building purposes BS 5082 BS 5358 BS 6150 Priming paints Painting of buildings Priming paints ) ) ) ) ) CP 2008 Protection Protection of iron and steel structures from corrosion.
B Protection of finished work is clearly imperative at all times and the Architect reserves the right the condemn work previously accepted if subsequently damaged and to withhold further payment until the work has been rectified.

The amount included for the item, is deemed to include for the protection of all work and where no price is included against this item, it will be assumed that Contractor has included elsewhere in the Bills for these costs.
MW/38 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) EXTERNAL WORKS General A B The Contractor is referred to the Civil and Structural Specification which is embodied within these Preambles for items referring to External Work.

Drainage Regulations The Contractor shall conform with the regulations and bye-laws of the Public Health Authority and/or other competent authority.

The whole of the drainage works shall be executed to conform to BNS Code of Practice CP 16 Part 1.
Materials C The sand, aggregates, cement and steel shall be as specified under 'Concrete Work'.

Hollow blocks shall be as specified under 'Blockwork'.

Cement mortar shall be as specified under 'Blockwork' for hollow block-walling.

Cement/sand render shall be as specified under 'Wall Finishes'.

PVC pipe and fittings shall be obtained from an approved manufacturer and shall conform to BS 4660.

All fittings shall be of the same joint design as the pipe and must conform to BS 2494 Part 2.
Prices for fittings on all types of drain pipe shall include for cutting and extra joints.

Concrete pipes and fittings shall conform to BS 556 with ogee joints jointed with cement mortar 1:1.

Workmanship D The drains shall be laid to suit the general progress of the building work and at such time and in such a manner as to be adequately protected against damage and deterioration.
All drains and pipes shall be kept clear of obstruction during the process of laying and maintained until completely clear of obstructions and handed over in a clean condition.

The holes previously left below joints for jointing purposes shall be carefully filled in.

Pipes passing through manholes shall be securely made good with cement mortar.
MW/39 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) EXTERNAL WORKS (Cont'd) Testing A The drains, soil and vent pipes shall be tested in the presence of and in a manner approved by the Architect.

Prices for testing are to include for providing all necessary equipment, water and attendance.

Pipe lines shall be submitted to a hydraulic test before the trenches are completely backfilled.

Test pressures shall be 12 times the working head.


If any leaks are discovered, the joints shall be resealed and the pressure pipes shall be removed and replaced with sound pipes.

The Contractor shall provide all equipment and materials necessary for the tests and attendance upon the Engineer while the tests are being carried out.

During the tests, the backfilling of the trenches shall be complete except that the joints of the pipe and fitting shall remain exposed for visual inspection.
Upon satisfactory completion of the test, the remainder of the backfill shall be undertaken in the same way as described in 'Backfilling'.

Excavations B Excavations are to be carried out to the lines and levels shown on the Engineer's drawings or to such other dimensions as the Engineer may specify.

Excavations shall be kept dry regardless of the source of water and the Contractor shall allow for all measures necessary to achieve this.
The Contractor shall allow for the provision of all temporary works for the support of excavations where necessary, to avoid slips, falls and excess excavation.

The extent of all excavations in open cut shall be the minimum necessary or practicable for the construction of the works.

Trenches shall have at the bottom, at least 6” clearance between the barrel of the pipe to be laid and the face of the excavation or timber sheeting.
Roomy joint holes shall be provided so that pipes may rest for their whole length on a properly prepared bed.

Excavations with battered or stepped sides may only be adopted with the prior approval of the Engineer.

The excavation of trenches more than two days in advance of pipe laying and permission to open up new lengths of excavation will be conditional on satisfactory pipe laying and initial backfilling.

Trenches shall not be left open longer than is reasonably necessary.
The Contractor must inform the Quantity Surveyor 24 hours prior to commencing backfilling any excavations associated with drainage.

MW/40 MATERIALS AND WORKMANSHIP PREAMBLES (Cont'd) EXTERNAL WORKS (Cont'd) Laying Concrete pipes A A bed of concrete (Grade B:21N/mm5 at 28 days) for the concrete pipes shall be laid in a minimum thickness of 2".

Purpose-made precast concrete blocks shall then be set on the concrete in cement mortar and carefully levelled.
The pipes shall be laid on the blocks, care being taken to ensure that the jointing rings are correctly located and are not damaged during laying.

After laying, the pipes shall be true to line and level and there shall be a gap not less than 3" and not more than 2" wide, between the end of the spigot and the inner face of the socket.

The use of steel packings will be permitted on top the concrete blocks to raise the pipes.
Backfilling B After laying the pipes and placing the concrete cradle under the pipe, 'selected fill' shall be carefully placed around the pipe in 4" layers and well compacted to at least 90% of the materials maximum density.

'Selected fill' shall be placed and lightly tamped over the crown of the pipe for a depth of not less than 12" unless otherwise specified on the drawings.
'Selected fill' shall be uniform readily compactible material, free from tree roots, vegetable matter, building rubbish, clay and stones greater than 1" diameter.

Additional filling required to complete backfilling shall be carried out with suitable excavated material placed in 6" layers and thoroughly compacted.
Protection C Protection of finished work is clearly imperative at all times and the Architect reserves the right the condemn work previously accepted if subsequently damaged and to withhold further payment until the work has been rectified.

The amount included for the item, is deemed to include for the protection of all work and where no price is included against this item, it will be assumed that Contractor has included elsewhere in the Bills for these costs.
MW/41 2-6 Section VI – Employer’s Requirements Drawings The actual Drawings, including site plans, are annexed in a separate drawing folder.

The list of drawings is set out below for reference.

Tenderers are referred to the drawings used in the preparation of these bid documents.

Any queries should be communicated to the Engineer.

In every case, details shown on large scale drawings take precedence over smaller scale drawings.
Section 6 – Employer’s Requirements 2-7 Architectural Drawing List Drawing No.
S1 A1 AA1 AA2 AA3 AA4 AA5 AA6 AA7 AA8 AA9 AA10 AA11 AA12 AA13 AC1 AT1 BA1 BA2 BA3 BA4 BA5 BA6 BA7 BA8 BA9 BA10 BA11 BA12 BA13 BC1 BC2 BT1 BT2 Drawing Title Site Plan Site Plan Administration Block – Block A Ground Floor Plan Sections AA & BB Roof Framing Plan Roof Plan Elevations Stair and General Details Stair and Ramp Details Ramp Details Door Schedule Window Schedule Finishes Schedule Washroom Internal Elevations Kitchen Internal Elevations Reflected Ceiling Plan Ground Floor Tile Plan Science Laboratory – Block B Ground Floor Plan First Floor Plan Sections AA & BB Roof Framing Plan Roof Plan Elevations Details Stair Details Stair Details Door Schedule Window Schedule Finishes Schedule Washroom Internal Elevations Reflective Ceiling Plan – Ground Floor Reflective Ceiling Plan – First Floor Ground Floor Tile Plan First Floor Tile Plan 2-8 DA1 DA2 DC1 Section VI – Employer’s Requirements Security Booth – Block D Ground Floor Plan, Elevations, Section Door & Window Finishes Schedule Reflected Ceiling Plan Civil/Structural Engineer’s Drawing List Drawing No.
001.1 001.2 001.3 001.4 002.1 002.1A 002.2 002.2A 003.1 004.1 005.1 005.2 006.1 001.1 001.2 001.3 002.1 002.2 003.1 003.2 003.3 004.1 005.1 005.2 006.1 006.2 006.3 001.1 Drawing Title Block A Foundation Plan Footing Details Foundation Column Details Foundation Column Details Grade Beam Plan Grade Beam Section & Details Capping & Floor Beam Plan Capping & Floor Beam Details Floor Slab Reinforcement Plan Column/Stiffener Column Plan & Detail Ring Beam/Roof Beam Plan & Details Roof Slab Details Step & Ramp Details Block B Foundation Plan Footing Details Cistern Details Grade Beam Plan & Details Ground Floor Capping Floor Beam Plan and Detail Ground Floor Slab Reinforcement Plan Ground Floor Slab Sections First Floor Slab Reinforcement Plan and Details Ground Floor & First Floor Column & Stiffener Plan & Details First Floor Beam Plan & Details Ring Beam Plan & Details Details Elevator Shaft Details Staircase Details Block D Structural Plans & Details Section 6 – Employer’s Requirements 2-9 C001.1 C001.2 C002.1 External Civil Works Drainage Plan Road and Parking Lot Plan Drainage Detail & Road Detail Services Engineer’s Drawing List 1207-2-EL-GN-50 1207-2-EL-LG-10 1207-2-EL-LG-11 1207-2-EL-LG-12 1207-2-EL-LG-13 1207-2-EL-LG-16 1207-2-EL-LG-17 1207-2-EL-LV-20 1207-2-EL-LV-21 1207-2-EL-LV-23 1207-2-EL-LV-25 1207-2-EL-LV-40 1207-2-EL-FA-01 1207-2-EL-FA-02 1207-2-EL-FA-03 1207-2-EL-FA-20 1207-2-EL-FA-50 1207-2-EL-PA-01 1207-2-EL-PA-02 1207-2-EL-SE-01 1207-2-EL-SE-02 1207-2-EL-SH-60-1 1207-2-EL-SH-60-2 1207-2-EL-TE-01 1207-2-ME-AC-01 1207-2-ME-AC-101 1207-2-ME-GP-01 1207-2-ME-GP-02 1207-2-ME-GP-03 1207-2-ME-PW-01 1207-2-ME-PW-02 1207-2-ME-PW-03 1207-2-ME-PW-101 1207-2-ME-PW-102 Electrical Grounding Riser & Details Lighting Layout – Ground Floor Block A Lighting Layout – Ground Floor Block B Lighting Layout – First Floor Block B Lighting Layout – First Floor Block B Site Perimeter Lighting & Security Booth Lighting & Power Layout Site Perimeter Lighting Isometric Power Layout – Ground Floor Block A Power Layout – Ground
 Floor Block B Power Layout – First Floor Block B Solar Power Details Electrical Single Line Diagram Fire Services Alarm System Riser Block A Fire Alarm Layout Block B Fire Alarm Layout Fire Suppression System Layout – Blocks A & B Fire Suppression System Detail Public Address System PA System Riser Block A PA Layout Security System Riser Diagram Security System Site Layout Lighting Fixtures & Panel Schedule – Sheet 1 Lighting Fixtures & Panel Schedule – Sheet 2 Telecom Systems Telecom Riser Mechanical AC Ventilation Layout – Block A HVAC Isometric – Block A Gas Piping Layout & Isometric – Block A Gas Piping Layout – Ground Floor B – Science Laboratory Gas Piping Layout & Isometric – First Floor Block B Potable Water Layout & Roof – Block A Potable Water Layout – Block B Ground Floor Potable Water Layout – Block B First Floor and Roof Potable Water Isometric – Block A Potable Water Isometric – Block B 2-10 Section VI – Employer’s Requirements Potable Water Site Distribution Layout Potable Water Isometric Rain Water Harvesting Layout & Isometric – Block B 1207-2-ME-PW-200 1207-2-ME-PW-201 1207-2-ME-WH-01 1207-2-ME-WW-01 Waste Water Layout & Isometric – Block A 1207-2-ME-WW-02 Waste Water Layout – Ground & First Floors - Block B 1207-2-ME-WW-101 Waste Water Isometric – Block B 1207-2-ME-WW-200 Waste Water Distribution Layout 1207-2-ME-WW-201 Waste Water Site Isometric Section 6 – Employer’s Requirements 2-11 Supplementary Information 1.
2.
Preliminaries Bills of Quantities 2-12 Section VI – Employer’s Requirements Preliminaries Names of Parties Employer Architect Structural Engineer Mechanical & Electrical Engineer Quantity Surveyor Ministry of Education, Science & Technology Government of Antigua & Barbuda Queen Elizabeth Highway St. Johns Antigua and Barbuda Tel: (268) 562-1305 Fax: (268) 462-4970 Email: Moulton Mayers Architects McKies Hill Kingstown St. Vincent Tel: (784) 457-2072 Fax: (784) 457.2290 Email: mayersarch@vincysurf.com Addison Workman Weatherrills Road St. John's Antigua Tel: (268) 462-3700 Fax: (268) 461-1459 Email: awork@candw.ag Sylvester Engineering Ltd #30A Vierra Drive Champs Fleur Trinidad & Tobago Tel: (868) 662-7935 Fax: (868) 662-9562 Email: admin@syleng.com Design Collaborative “Lauriston” Collymore Rock St. Michael Tel: (246) 426-1741 Fax: (246) 429-4595 Email: admin@desgin-collaborative.net PRELIMINARIES LOCATION OF SITE A B C D E The site is located at Bolans, St. Mary's, Antigua Access to the site is by way of the main public access road.
SITE RESTRICTIONS AND LIMITATIONS The site is within and adjacent to the existing school which will continue to operate, thus the Contractor must organize and arrange his work in such a manner to accommodate access to and ongoing day to day operation of the school.

The Contractor must do his best in order to prevent vibration, dust and noise emanating from the works being a nuisance and causing disruption to the normal operations of the school.
The Contractor must put adequate measures in place in order to prevent such an occurrence.

The Contractor must ensure that debris emanating from the work does not accumulate on the public road or the internal road or hinder the public from using the public road in any way.

MATERIALS EXCAVATED FROM THE SITE The Contractor is strictly prohibited under any circumstances from excavating to obtain excavated material for his own use.
Any excavated material obtained from the authorised excavations shall be the property of the Employer and may, if approved be used in the works.
To Collection $ P/1 ------------------------ GENERAL MATTERS CONT’D Preliminaries Cont’d A PRELIMINARY INVESTIGATIONS The tenderer must examine the drawings and Conditions of Contract, visit the site and satisfy himself as to local conditions, means of access, necessity for and extent of temporary drainage, location of existing services, the extent and nature of the site and work, the restrictions and limitations, the conditions under which work will be carried out, conditions affecting the supply of labour and materials, storage space for materials and plant and generally of all conditions which may in any way affect his tender, as no claim on the grounds of lack of knowledge of any such matters will be entertained.
The Architect shall be informed of any area of the proposed works which the tenderer can envisage as causing problems during construction.

The tenderer must note that construction of the works will take place when the existing school is operational.

All costs associated with protection, security and all measures to ensure the safety of students and staff must be included in the tender amount.
GENERAL DESCRIPTION The tenderer is referred to the drawings and specifications for a full description of the scope of works.

SIZES OF BUILDINGS The Contractor is referred to the drawings for the sizes of the proposed buildings and the Scope of the Works.

All drawings and forms of contract may be inspected at the office of the Architect.
B C To Collection $ P/2 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) BILLS OF QUANTITIES A B C D The Tenderer’s attention is specifically drawn to the fact that the Bills have been prepared generally in accordance with the SMM6 as issued by the Royal Institution of Chartered Surveyors and the Construction Confederation and adapted for local use.

The Tenderer shall allow in his tender for any items required but not measurable in his rates and prices for the work.
Tenderers are required to submit with their tender a copy of the Bills of Quantities priced in US$ fully extended out to agree with the total Tender amount.

It is emphasized that all items, including those contained in these Preliminaries, must be individually priced.

Dayworks: The Contractor shall insert rates and prices to the Daywork schedules in the Bill of Quantities as an integral part of his tender.
Ordering Materials: The necessary particulars for ordering materials are to be obtained from the full details and information which shall be approved by the Architect.

The Contractor must not use the Bills of Quantities for this purpose.

No claims will be admitted in respect of materials which have been ordered without such details and information being sought.
Conflicting Clauses: In the event of any descriptions within the Bills of Quantities being at variance, in conflict or inconsistent with the Architect’s, Structural Engineer’s or Services Engineer’s drawings or Specification or with the manufacturers printed recommendations then the requirements of the specification or manufacturer’s recommendation will prevail.
To Collection $ P/3 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) TENDERS Forms of Tender A All prices inserted shall be based upon the cost of labour and materials and other services current at the date of tender.
The form of tender shall be completed quoting firm prices on the basis that there shall be no adjustment to the Contract Sum for fluctuations in prices and any differences in the price between the total on the Summary page and the Form of Tender shall be taken into account by an adjustment to the amount of the Preliminaries and the Bill of Quantities.

Validity of Tender The offer shall be open for a period of 120 days from the closing date for the submission of Tenders.
Alterations to Documents No alterations in the text of these documents shall be made by the Contractor tendering unless so instructed in writing.

Should any alteration, amendment note or addition be so made, the same will not be recognised but the reading of the printed documents will be adhered to.

If the Contractor wishes to make an observation as to the printed text in connection with the rates he has inserted, this shall be in the form of a covering letter.
Pricing Every price or rate inserted into the documents by the Contractor shall be in ink.

The Contractor's prices for any items against which he does not insert prices will either be deemed to be included in items against which prices have been inserted or assumed that he will perform this work or service free of charge.
B C D To Collection $ P/4 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) Currency A B C D All prices and sums contained in and mentioned in these documents and all prices inserted by the Contractor shall be in US dollars.
Materials and goods required specifically for this project shall be deemed to include for the provision of all labour, materials and return of empties, the erection, maintenance, adjustment and removal of scaffolding, temporary stagings, plankways, protection, hoardings, etc., and for all other things necessary for the completion of the works in accordance with the drawings and specification to the reasonable satisfaction of the Architect.
Visiting Site Persons shall at their own expense, visit the site of the works and obtain for themselves on their own responsibility all information that may be necessary for negotiating and entering into a contract and must examine the Contract Documents and inspect and consider the site and its surroundings.
Obtaining Information Any neglect or failure on the part of the Contractor to obtain reliable information upon any matters affecting the execution, construction, completion and maintenance of the works shall not relieve him from any risks or liabilities for the completion of the works, nor will any claim for increase of the Contract Sum or extension of the Contract period be entertained as a result of such neglect or failure.
Lump Sum Additions or Deductions to arrive at Tender If the Contractor, to arrive at the amount of the contract shall have added to or deducted from the total any sum either as a percentage or proportionate sum, it shall be added to or deducted from the amount of variations in the same percentage or proportion, provided always that in determining the percentage or proportion of the sum so added or deducted by the Contractor the total amounts of any provisional sums of money shall previously be deducted from the contract sum.
To Collection $ P/5 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) Queries A B C D E F G H The Contractor shall refer all queries arising out of any of the documents to the Architect whose decision, shall be final.

Import Duty and other Tax Concessions Imported materials and goods required specifically for this project shall be free of import duties.

This privilege is expressly for the benefit of the Employer.
The allowable concessions at present in force in respect of the duty on imported materials to be incorporated in the Works shall be ascertained from a responsible official of the Customs Department.

Any special rules in force in respect of the importation of plant, scaffolding, tools, equipment and consumable stores not incorporated in the works, shall also be ascertained.
The Contractor shall familiarise himself with the workings of the Customs Department and he shall accept responsibility for preparing and processing the necessary documents involved in the importation of materials, etc; to be incorporated in the Works, including those of suppliers.

Detailed lists of all materials to be imported for incorporation in the Works, shall be submitted to the Architect in triplicate within fourteen days of taking possession of the site.
The Contractor shall obtain from each nominated sub-contractor within fourteen days of the award of the respective sub-contracts, detailed lists in triplicate of all materials to be imported for incorporation in the sub-contractor's work and such lists shall be forwarded to the Architect.

The Contractor shall assist all sub-contractors, nominated or otherwise with the preparation of their documents so that a uniform presentation is made to the appropriate authorities.
The Contractor shall allow in this bid for the time and costs involved in the above procedures and in making necessary applications.

To Collection $ P/6 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) A The Contractor will be responsible for the cost of licenses, bonds, deposits, levies, taxes, stamp duties, bank charges (for letters of credit or sign drafts, etc) wharfage dues, package tax and any other charges in connection with the importation of goods and materials.
Correction of Errors B Errors will be corrected by the Employer as follows: (a) (b) where there is a discrepancy between amounts in figures and in words, the amount in words will govern: and where there is a discrepancy between the unit rate and the total amount derived from the multiplication of the unit rate and the quantity, the unit rate as quoted will govern, unless, in the opinion of the Employer, there is an obviously gross misplacement of the decimal point in the unit rate, in which event the total amount as quoted will govern and the unit rate be corrected.
Contract Particulars Conditions of Contract C The works embraced in this contract shall be carried out in accordance with the FIDIC Conditions of Contract for Construction Multilateral Development Bank Harmonised Edition June 2010.

A copy of the contract conditions is included in this document.
To Collection $ P/7 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) Definitions A B Where the term “Engineer”, “Architect”, “Quantity Surveyor”, occurs in this document it shall read as meaning the Engineer named in the Contract Data.

The term 'approved' 'directed' or 'selected' means the approval, direction and selection by the Architect unless otherwise described.

C Where the term 'allow' occurs in this document the cost of the item is at the risk of the Contractor.
D E F The abbreviations 'BS and CP' mean the latest British Standard Specification and British Code of Practice respectively.

The term 'local' means Barbados.

All sums of money quoted in this document shall be in local currency Barbados dollars.

Abbreviations G The following abbreviations are used: Bill(s) of Quantities B.Q.

B.S.

British Standard B.N.S.

British National Standard Code of Practice C.P.


Standard Method of Measurement 6th Edition SMM Metre Square Metres Cubic Metres Square Millimetre Linear Millimetre Pair Kilogramme Newtons Hour m m2 m3 mm2 mm Pr.

Kg.

N Hr.
Kg.

N Hr.

N/mm2 Newton Per Square Millimetre One Document H Read the Conditions of Contract, and Specifications, the Bills of Quantities and drawings as one document and carry out everything for the proper execution of the Works whether or not specifically described or shown therein, provided the same may reasonably be inferred therefrom.
To Collection $ P/8 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) Discrepancies A Verify on drawings or on site all dimensions shown or given before commencing construction.

Work to figured dimensions only and in the absence of any dimensions, or cases of discrepancies between dimensions, bring the matter to the immediate attention of the Architect for a decision.
For the purpose of construction, the drawings shall take precedence over the Bill of Quantities but in all cases of discrepancies between the documents, bring the matter to the attention of the Architect whose decision shall be final and binding.

Copies B Two copies of the Bill of Quantities and drawings shall be furnished free of charge to the Contractor for his own use until the completion of the contract.
They shall be accessible at all reasonable times, to the Architect, to whom they shall be returned at the completion of the Contract.

Additional copies will be provided to the Contractor on request and charged at nett cost.

Ordering of Materials C Prepare own materials ordering list based on the construction drawings and schedules issued and on site measurements where appropriate.

Contract drawings and schedules will be issued on possession of site.
At the first site meeting, the Contractor should indicate what information is outstanding and suggest order or priority of receipt of such information to avoid delay by late ordering.

Record Drawings D Keep accurate records of the Works in a form acceptable to the Architect.

As-Built Drawings E The Contractor will be provided with three sets of Contract Drawings.

One set is to be available on the Project Site at all times.
The Contractor shall, during the course of the Works, keep a full, neat and accurate record of all changes to the Works from the Contract Drawings and Specifications and shall promptly note these fully on one set of A1 size prints of the Contract Drawings which shall be kept at his site office and be available for inspection by the Engineer upon request.

These records shall constitute the As-Built Drawings.
To Collection $ P/9 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) A The As-Built Drawings shall also include all utility location and relocation information relevant to the site of the Works.

The Contractor shall allow, in the Tender Item for As-Built Drawings, for the cost of modifying a set of Contract Drawings, to be supplied by the Engineer, to fully incorporate all of the As-Built changes he has recorded during construction for the approval of the Engineer.
He shall also allow for the provision of four full sets of A1 size prints of the approved As-Built Drawings, to be distributed as follows:-  Employer  Engineer  Contractor - 2 sets - 1 set - 1 set These drawings shall be completed and supplied to the Engineer together with an electronic copy within thirty days of the taking- over certificate.
Any failure of the Contractor to submit the "As-Built" drawings within the stipulated period will entitle the Engineer to have the base drawings modified by others at the expense of the Contractor.

Fire Precautions B The Contractor is to take all reasonable precautions to avoid the outbreak of fire particularly in work involving the use of naked flames.
He is to impress on the workmen the dangers involved in the careless disposal of matches, cigarette ends, etc., and in the accumulation of rubbish on site.

Fire extinguishers are to be kept on site and operatives instructed as to their whereabouts and use.

Smoking is NOT permitted in any part of the premises and it is the Contractor's responsibility to ensure that this condition is met and enforced throughout the contract period.
Plant, tool and vehicles C Provide all implements, tools, hoists, plant, vehicles, etc., necessary for the proper execution of the works (for scaffolding, see Temporary Works section).
To Collection $ P/10 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) Safety, health and welfare of workpeople A The Contractor shall, at his own expense, comply in all respects with the requirements of local regulations relating to the safety, health and welfare of operatives and shall provide such mess huts, changing and toilet facilities as are required under local working agreements including providing and maintaining an adequate First Aid kit upon the site or any places where work is being prepared for incorporation into the Works.
Tenderers are referred to clause 4.8 of the Conditions of Contract – Safety Precautions and to clause 6.7 Health and Safety for their full contractual responsibility.
Benefits B Allow for all costs in respect of workpeople including but not limited to costs arising from the following: (a) (b) (c) (d) (e) (f) (g) (h) (i) Social Services Scheme National Insurance including training fund, unemployment, employment injury, severance fund, health service levy and transport levy Vacation and Public Holidays leave Sick leave Cost of Living Allowance Subsistence Allowance Bonus payments Travelling time and expenses Workman's compensation and to all other emoluments and expenses payable to or in connection with the employment of persons for the works.
Transport for Workpeople C Allow for obtaining an adequate labour force for the Works and include for transporting workers to and from the site, as necessary.

Imported Labour D The Contractor must comply with all immigration and other laws in force in respect of the importation of supervisory staff, skilled and unskilled labour and allow for security bonds and other payments in this connection.
To Collection $ P/11 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) Overtime A The contract sum will be deemed to include any overtime working which the Contractor may consider necessary to complete the Works by the date stated.

If work is to be executed outwith normal working hours, 24 hours notification must be given and the consent of the Architect must be obtained before commencement.
Safeguarding the Works, materials and plant against damage and theft B Allow for all necessary watching and lighting and protection of the Works, materials, plant, etc., on the site from theft or damage of any kind.
Maintenance of public and private roads C Make good any damage to roads and footways whether public or private caused by or attributable in any way to the cartage of plant or materials for or by either the Contractor or any sub-contractor under the contract and indemnify the Contracting Authority against loss or damage or claims by the Government or others for damage to roads, paths, etc., by reason of unusual traffic or other causes.
The Contractor is also to take reasonable steps to prevent the excessive deposit on adjacent public or private roads, carparks and footways of mud, clay, hazardous waste etc., from his vehicles or those of any sub- contractor under the contract and is to clear away any dangerous deposits attributable to such vehicles.

Allow for providing all necessary temporary crossovers and hard- standings and clear away on completion and make good all damaged areas.
Police Regulations D The Contractor is to ascertain and comply with all police regulations in regard to access to and from the site and to any works that may be executed in public thoroughfares adjacent to the site.
Additional obligations and restrictions imposed by the Employer E The Contractor is to carry out the work with the minimum of noise and inconvenience to the occupants of the adjoining properties by the use of plant and equipment incorporating up-to-date methods of sound reduction in accordance with BS 5228.

Positions of all fixed plant installation on site shall be agreed with the Architect.
To Collection $ P/12 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) Access to the site shall be during daylight hours only.

The Contractor must inform the Architect of all working operations of a dangerous nature or which he proposes carrying on outside normal working hours.

In the event that exceptionally noisy operations have to be undertaken, the Contractor shall notify the Architect 24 hours in advance of each operation taking place.
Quality Assurance Plan A The Contractor shall issue within 28 days after receiving notice for Commencement of Works, a detailed Quality Assurance Plan in a format to be agreed with the Architect.

Tenderers are referred to clause 4.9 of the Conditions of Contract for their full contractual responsibility.

B Environmental Control Plan The Contractor shall issue within 28 days after receiving notice for Commencement of Works a detailed Environmental Control Plan in a format to be agreed with the Architect.
Tenderers are referred to clause 4.18 of the Conditions of Contract for their full contractual responsibility.

Site Record Book C The Contractor is to keep on site a site record book in which the Architect or Engineer can enter and confirm verbal instructions given on site.

Any verbal instructions given to the Contractor at site meetings shall be deemed to have been given in writing when either entered in the site record book or included in the minutes of the site meetings.
Progress Meetings D Regular progress meetings will be held throughout the duration of the contract and a principal representative of the Contractor will be required to attend in addition to his senior staff and if specifically requested by the Architect, representatives of any sub-contractors and principal material suppliers.
To Collection $ P/13 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) Programme A The Contractor shall within twenty eight days after receiving the notice for the Commencement of Works, produce a draft outline programme for the information of the Architect.

This draft programme shall indicate the dates for commencement and completion of all works including sub-contractors' work and the delivery dates required for materials from nominated suppliers.
The Contractor, shall, not more than four weeks after the date for possession and after agreement of working and delivery dates with sub-contractors and nominated suppliers, produce a draft detailed programme indicating the critical path for the information of the Architect and after making any necessary amendments and after agreement of the programme with the sub-contractors, prepare final copies for all consultants and for his own use.
Tenderers are referred to clause 8.3 of the Conditions of Contract for their full contractual responsibility.

The Contractor shall allow for preparing any revised programmes which may become necessary and for notifying all sub-contractors and suppliers and consultants of any changes in programme.
The production of revised programmes and their issue to the Architect shall not relieve the Contractor of his responsibility under Clause 20.1 of the Conditions of Contract relating to the giving of formal written notice of delays in, or disturbance of, the regular progress of the Works.

Progress chart and reports B Keep a permanent written record on the site of the progress of the Works.

This record shall be open to the inspection of the Architect at all reasonable times.
The record shall show the date of commencement and completion of all trades and parts of the work coming under the Contract.

It shall also include particulars regarding daily weather conditions, excavation work, erection and removal of formwork, pouring of concrete, removal of formwork, etc., as well as the number of employees of the various trades engaged on the Works.
Submit a written progress report to the Architect at the end of each month showing, but not limited to the percentage of work completed in each trade shown on the programme and progress chart; quality control matters covered by the Quality Assurance Plan; Environmental Control Plan updates; progress photographs, etc.

Keep up-to-date a copy of the programme marked with coloured crayon to indicate weekly progress on the site compared to the programmed progress.
This copy shall be made accessible to the consultants on their request.

To Collection $ P/14 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) Tenderers are referred to clause 4.21 – Progress Reports for their full contractual responsibility.

Utilities A The Contractor shall be responsible for arranging and co-ordinating the work of utility companies to suit his work programme and to avoid all possible delays.
Performance Bond B The Contractor is to insert in the Summary the cost of providing a Performance Bond with an approved insurance company or bank based or fully represented in Antigua and Barbuda an amount equal to 10% of the Contract Sum, if required by the Employer.

Failure to comply with this requirement will mean that the cost of the Performance Bond, if required, will be provided by the Contractor free of charge.
The successful contractor shall be required to enter into the Bond not later than the date for possession of the site.

A specimen Performance Bond is included as an appendix to this document for tenderers' information.

The Bond shall be maintained by the Contractor until such time as he shall receive the Performance Certificate.
Where applicable, the Bond shall be executed in accordance with the specimen format and shall be deposited with the Architect until such time as the Performance Certificate has been issued.

Mobilisation Payment C Should the successful tenderer so request, a mobilisation payment up to an amount of 10% of the contract sum will be considered by the Employer to meet expenditure resulting from the commencement of the Contract.
If the contractor requests a mobilisation payment he will be required to provide a mobilisation payment guarantee bond issued by an approved insurance company or bank based or fully represented in Antigua and Barbuda.
No advance shall be granted until: a) the signing of the Contract; b) provision to the Employer by the Contractor of the Performance To Collection $ P/15 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) Bond and insurances required under the contract; c) provision to the Employer by the Contractor of a separate directly liable guarantee for the full amount of the advance which shall remain effective until the advance has been completely repaid by the Contractor out of interim payments under the Contract.
The Contractor shall use the advance exclusively for operations connected with the execution of the Works.

Should the Contractor misuse any portion of the advance, it shall become due and repayable immediately and no further advance payments will be made to him.
If the Contract is terminated for any reason whatsoever, the guarantees securing the advances may be invoked forthwith in order to repay the balance of the advance still owed by the Contractor, and the guarantor shall not delay payment or raise objection for any rason whatever.

The advance guarantee shall be released as when advances are repaid.

The mobilisation payment if requested, will be recovered in equal installments deducted from interim payment certificate No 2 through to No 7.
Site Signboard A The Contractor shall erect a signboard displaying his name, the client's name and project title, the names of all consultants and the names of the major sub-contractors.

The location, design and layout of the board will be agreed with the Architect.

Allow the Provisional Sum of $4,000.00 for this signboard.

Samples B Include the Provisional Sum of $1,000.00 for sample panels, etc., to be expended as directed by the Architect.
C Tenderers are referred to clause 7.2 of the Conditions of Contract for their full contractual responsibility.

$4,000.00 $ 1,000.00 To Collection $ P/16 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) Watching and protection A The site of the proposed works shall be under the Contractor's sole charge from the date of possession to the date of completion of the contract.

The Contractor shall be responsible for keeping unauthorized persons off the site.
Provide all necessary day and night watching to effectively protect the Works and materials stored on site and accept all risks for damage or loss.

The Contractor shall as he sees fit, provide all that is necessary for the protection of work-people, adjoining property and the public and alter, adapt and maintain them as necessary and clear away on completion and reinstate all works disturbed.
Handover of completed work B A provisional date for handing over the Works shall be agreed and approximately two weeks prior to this, the Architect subject to his being satisfied that the work is in such a state of readiness, shall compile a 'snag list' of omitted and/or defective items and the formal handover shall not take place until all items on the 'snag list' have been completed or remedied or shall be conditional upon completion of these.
C The Architect shall arrange for the formal handover normally within one week after satisfactory completion by the Contractor of the 'snag list'.

D At the formal handover, a responsible representative of the Contractor shall accompany the Architect together with such other representatives that the Architect and Employer deem necessary, on an inspection of the Works and if such an inspection shows the Works to be complete in every respect, the Works shall be taken over.
Any minor omissions and/or defects found to exist at this point, shall be remedied by the Contractor within seven days.

Contractor's Liability E The Contractor shall undertake all risks and liabilities arising out of incidental to or connected with the construction, completion and maintenance of the Works.
The Contractor's liability shall extend to all risks involved in the execution of the Works with regard to temporary supports, struts, braces, shores and other works of supports, steadying, restraints or upholding and shall, at his own expense, make good damage or defects resulting from the inadequacy or failure of his actions or work in these respects.
To Collection $ P/17 ------------------------ Preliminaries Cont’d GENERAL MATTERS (Cont'd) NAMED SUB-CONTRACTORS AND SUPPLIERS Attendance A Provide attendance upon, cut away for and make good after all trades and in all trades performed by own workmen and own sub-contractors and leave perfect on completion.
Provide general attendance on named sub-contractors which shall be deemed to include allocation, for free use by sub-contractors of suitable areas on site for office accommodation and storage of plant and materials, reasonable and free use of scaffolding and hoisting tackle already erected by the Contractor, free use of messrooms, sanitary accommodation and their work and cleaning away rubbish.

Provide special attendance on named sub-contractors, ie.
cutting chases and the like, only when specifically instructed so to do following the items in the Bills of Quantities which described the particular named sub-contract work.

When a lump sum price is inserted against this item, it shall be adjusted in direct proportion to the amount of the named sub-contract PC sum actually expended.
To Collection $ P/18 ------------------------ Preliminaries Cont’d NAMED SUB-CONTRACTORS & SUPPLIERS (Cont'd) Provisional and Prime Cost Sums A The term 'Provisional Sum' shall mean a sum provided for work or for costs which cannot be entirely foreseen, defined, or detailed at the time the tendering documents are prepared.

Such sum shall be used in part or in whole as directed by the Architect and shall be deemed to be inclusive of any profit required by the Contractor unless otherwise indicated.
The term 'Prime Cost Sum' or 'PC Sum' shall mean a sum provided for work services to be executed by a sub-contractor named by the Architect, a statutory authority or a public undertaking or for materials or goods to be obtained from a supplier named by the Architect.

Such sums may be used in part or in whole as directed by the Architect and shall be deemed to be exclusive of any profit required by the Contractor and provision is made for the addition thereof.
When profit is added by the Contractor, the sum so added shall be adjusted in direct proportion to the amount of the PC Sum actually expended.

When a PC Sum is given in the description of any item of work, it shall be taken as a price only for the materials or services referred to (delivered to site unless otherwise stated) and the Contractor shall use this price in the build-up of the rate for the supply and installation of that item of work.
The PC price shall be deemed to include the Contractor's cash discount and the Contractor shall be deemed to have allowed in his unit price build-up for the profit, overheads, attendance, etc., he may require on the PC price given.

A net adjustment shall be made to the Contractor's build-up price should the service or item selected by the Architect cost more or less than the PC price given.
Named Sub-Contractors B The Contractor shall enter into sub-contracts with each of the named sub-contractors embodying such conditions as would make them liable to him for the obligations he owes to the Employer, including the signing of a Performance Bond, as far as they are applicable to the main contract and are relevant to the sub-contract.
The Contractor shall produce the signed sub-contracts for inspection by the Architect before the commencement of any work by the sub-contract will not relieve the Contractor from any of his responsibilities under the Contract.

To Collection $ P/19 ------------------------ Preliminaries Cont’d NAMED SUB-CONTRACTORS & SUPPLIERS (Cont'd) Provide all named sub-contractors and specialists with proper facilities for carrying out their work and proper means of access thereto.
Ascertain from all named sub-contractors and specialists at the proper time what their requirements are and make the necessary arrangements for them including leaving or forming chases and holes, etc., in the structure.

Should either delay or extra expense be occasioned in consequence of any fault on the part of the Contractor in this respect, the penalty for such delay and extra expense incurred shall be borne by the Contractor.
It shall be the responsibility of the Contractor and each sub-contractor to ensure, by means of regular examination, that the work and materials installed by others do not create conditions which would prevent him from satisfactorily carrying out his work and inform the Architect in writing, as soon as such a condition exists.
Failure to notify the Architect of such conditions before work is put in hand shall be construed as an acceptance of all preceding work and a waiver of all claims for questions as to its suitability for receiving his work.

At the time of every valuation of the works for certificate purposes, the Contractor is to submit to the Architect or Quantity Surveyor a statement from each of the named sub-contractors, showing: 1.
The gross amount (including discounts and retention) claimed in the current certificate.

2.

The net amount received from the Contractor to date.

Amounts in respect of named sub-contractors will not be included in valuations unless these statements are received.
It shall be the responsibility of the Contractor to co-ordinate the performance of named suppliers, on site operations of all nominated sub-contractors and to programme and reprogramme as required, the various operations including builders' work in connection with named sub-contractors' and suppliers' work.

Regular site meetings should be held by the Contractor with all the named sub-contractors to enable proper co-ordination and the minutes of these meetings are to be sent to the Architect.
To Collection $ P/20 ------------------------ Preliminaries Cont’d NAMED SUB-CONTRACTORS & SUPPLIERS (Cont'd) Named Suppliers A The term 'Fix' (or similar term to the same effect) where prescribed in these Bills of Quantities for the performance of services in connection with materials to be supplied by a nominated supplier, shall in default of express indication to the contrary be deemed to include for taking delivery at site, off-loading, getting in, storing, distributing including hoisting or lowering, assembling and for returning empties, the whole to be at the Contractor's charge and to be included in the rates inserted against the several items to which the description 'fix' applies.
All or any damage or breakage sustained by such materials after acceptance of delivery which in the opinion of the Architect, is attributable to the Contractor's neglect of proper precautions, shall be held to be the Contractor's responsibility and all or any replacement or making good of such broken or damaged materials shall be at his expense.
Where materials are to be supplied by an overseas named supplier, the term 'fix' (or similar term to the same effect) shall also include for clearing from the port of entry to Antigua, paying for customs brokerage fees, port and storage charges, bank charges and transportation to the site of the works.

TEMPORARY WORKS General B All temporary works are to be placed on site in positions to be agreed by the Architect.
The price for all temporary works shall include for the provision of works, the hire and maintenance of equipment for as long as required by the work, the removal as required and the making good of any disturbed work or area.

Altering, shifting and adapting from time to time as necessary must also be included.

Access and temporary road C Access to the site is to be by way of the public access road to the school.
Provide and maintain any temporary sleeper or other temporary main access to the works from the existing road or adjoining properties as necessary and obtain any way leaves that may be required including those in connection with cranes, where jibs enter the air space over adjoining property.
To Collection $ P/21 ------------------------ Preliminaries Cont’d Temporary Works – (Cont’d) Temporary lighting and power for the Works A Provide any temporary lighting and electric power required for the carrying out of the work including the works of any sub-contractor and install all temporary wiring, fittings, electric meter, etc.
Water for the Works B The Employer will allow the Contractor to tap into the existing supply but this supply must be metered as the Employer shall be reimbursed for water used.

Provide all temporary services, temporary plumbing, storage, etc., as required.

Temporary buildings for use by the Contractor C Provide and maintain proper offices for the Contractor's site staff.

Provide and maintain suitable weathertight sheds and other protection necessary for the storage of materials.
Temporary telephone D Provide and install a fax/telephone in the site office including paying the cost of all the Contractor's calls.

Allow for providing free use of the telephone for the Architect and all other consultants or their appointed representatives for local calls in connection with the Works, clear away at completion and make good all ground disturbed.
Latrines E Provide and maintain sanitary accommodation for the use of the workmen in conformity with the requirements of the local Sanitary Authority and also deodorise and keep the same in thoroughly clean condition.

Chemical closet type latrines must be used.


Temporary hoardings, gantries and the like F Provide all necessary temporary fences, hoardings, planked footways, guard rails, gantries and the like necessary for the protection of the public, the proper execution of the works and comply with the requirements of the local authority and other official bodies having authority in connection with the works, clear away at completion and make good all ground disturbed.
To Collection $ P/22 ------------------------ Preliminaries Cont’d TEMPORARY WORKS (Cont'd) Provide all necessary fans, hoardings, tarpaulins, flying scaffolds or other protection that may be required for the protection of adjoining property, buildings, the public and persons employed on the Works.

Provide all dust sheets, tarpaulins, temporary roofing, etc., as required and carefully cover up and protect the building and contents during the carrying out of the works.
Provide all temporary rainwater pipes, chutes, ducts, etc, as required.

Access A The Contractor is to provide at all times during the execution of the works and the defects liability period, proper means of access with ladders, gangways, etc., and the necessary attendance to move or adapt them, as directed for the inspection or measurement of the works by the Architect or his representative.
General Scaffolding B Provide all scaffolding necessary for the proper execution and completion of the Works including altering, adapting and maintaining during the progress of the Works.

Scaffolding shall be in accordance with BS 5973.

If the Contractor should strike any of his scaffolding before ascertaining whether it is required by any sub-contractor, nominated sub-contractor or public undertaking, he must re-erect it at his own expense if so required.
Protecting, drying and cleaning the Works C Cover up and protect the Works including that executed by sub- contractors during inclement weather or from damage from any occurrence whatsoever.

The Contractor shall reinstate at his own expense any work so damaged to the satisfaction of the Architect.
To Collection $ P/23 ------------------------ Preliminaries Cont’d TEMPORARY WORKS (Cont'd) Removing rubbish and cleaning A Clear away all rubbish and materials from time to time as necessary or as directed by the Architect and leave the site and premises finally clear.

Clean out all gutters and down pipes, clean glass and metal work, scrub floors, etc., oil locks throughout, touch up paintwork and leave the buildings perfectly clean and entirely fit for occupation.
To Collection $ P/24 ------------------------ COLLECTION Amount of Page No.

1 Amount of Page No.

2 Amount of Page No.

3 Amount of Page No.

4 Amount of Page No.

5 Amount of Page No.

6 Amount of Page No.

7 Amount of Page No.

8 Amount of Page No.

9 Amount of Page No.

10 Amount of Page No.

11 Amount of Page No.

12 Amount of Page No.

13 Amount of Page No.

14 Amount of Page No.

15 Amount of Page No.

16 Amount of Page No.

17 Amount of Page No.

18 Amount of Page No.

19 Amount of Page No.


20 Amount of Page No.

21 Amount of Page No.

22 Amount of Page No.

23 Amount of Page No.


24 P/25 AMOUNT OF PRELIMINARIES TO SUMMARY $ --------------------------- --------------------------- BILL OF QUANTITIES ST. MARY'S SECONDARY SCHOOL BLOCK A SUBSTRUCTURE Notes: (i) The items and quantities included under this heading include all structural work below the top of the structural ground floor slab (ii) No allowance for working space has been allowed in computing the quantities of excavation.
Any working space which is considered necessary by tenderers must be allowed for in their unit rates for these items.
Excavations Excavate over area of building to remove top soil and stockpile on site Ditto below ditto in isolated pits not exceeding 5'0" deep and ditto Ditto exceeding 5'0" but not exceeding 10'0" deep and ditto Prepare, level and ram bottom of excavations to receive concrete Planking and strutting to sides of pit excavations not exceeding 5'0" deep Ditto exceeding 5'0" but not exceeding 10'0" deep Backfilling to pits well compacted in maximum 8" layers Ditto around building after walls are built Well compacted backfilling in maximum 8" layers within foundations under slab Imported fill material well compacted in 8" layers within ditto Prepare surface of fill to receive concrete 500 gauge polythene damp proof membrane well lapped Concrete Work A B C D E F G H I J K L 297 295 59 177 699 140 280 21 272 332 543 543 CY CY CY SY SY SY CY CY CY CY SY SY M 2" thick blinding concrete (1:4:8) 177 SY To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/1 Substructure (Cont'd) Reinforced ins-situ concrete 3000 psi at 28 days 3/4" aggregate In isolated column bases In columns In beams In slab 6" thick In slabs 6" thick laid to slopes In steps Reinforcement to ASTM A615 A B C D E F In foundations G #6 bars H I J K L In columns #6 bars #4 bars In beams #6 bars #4 bars In slabs #4 bars In steps 59 17 94 477 53 2 CY CY CY SY SY CY 11,510 Lbs.
4915 235 20,100 630 Lbs.

Lbs.

Lbs.

Lbs.

6500 Lbs.

M #4 bars 270 Lbs.

In stirrups and the like N #3 bars #3 bars in spiral to circular columns Sawn formwork to: Sides of foundations Vertical faces of columns Ditto to circular columns 12" dia P Q R 7175 150 Lbs.

Lbs.
Lbs.

140 169 10 SY SY SY To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/2 A B C D E F G Substructure (Cont'd) Sides and soffits of beams Ditto curved on plan Edges of slabs 6" high Risers of steps 7" high Blockwork Hollow concrete blocks 1000 psi laid in 1:3 cement/sand mortar In walls 8" thick filled solid with concrete Ditto laid to curves 580 14 147 42 83 3 SY SY LY LY SY SY #4 bars in vertical reinforcement 735 Lbs.
"Durowall" or similar horizontal mild steel ladder reinforcement laid in: H 8" thick walls 192 LY Protection I Allow for the protection of all of the work contained in this section Item To Collection Collection Amount of Page No.

BQ/1 Amount of Page No.

BQ/2 Amount of Page No.


BQ/3 Amount of Substructure To Block A Summary $ $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/3 BLOCKWORK WALLS Hollow concrete blockwork 1000 psi laid in 1:3 cement/sand mortar: In walls 6" thick 4" thick Concrete filling (2000 psi at 28 days) to single core of blockwork reinforced with 1No.
1/2" dia ht bar 6" thick walls 4" thick walls "Durowall" or similar horizontal mild steel ladder reinforcement laid in 6" thick walls 4" thick walls 388 54 625 73 436 61 SY SY LY LY LY LY Drill concrete 4" deep for and grout in #3 bars 16" long, built into joints of blockwork at connection of walls to columns 135 No.
Concrete, 3000 psi at 28 days in lintel and capping beams Reinforcement in ditto Sawn formwork to sides and soffits of ditto Form concrete cills 10" x 4" once checked bevelled and grooved on underside, include rebar and formwork Concrete in surrounds to circular window, type #11 Reinforcement in ditto Sawn formwork to sides Ditto 6" wide curved to 3'0" dia Protection 8 1110 98 61 1 90 8 13 CY Lbs.

SY LY CY Lbs.
SY LY Allow for protection of all of the work contained in this section Item A B C D E F G H I J K L M N O P Amount of Blockwork Walls To Block A Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/4 ROOF AND ROOF FINISHES Concrete Work Reinforced insitu concrete 3000 psi at 28 days, 3/4" aggregate In columns and stiffeners In beams In suspended slabs 6" thick In upstand beams In beam filling between timber rafters at 2'0" centres Reinforcement to ASTM A615 In columns and stiffeners #5 bars #4 bars In beams and upstand beams #6 bars #5 bars #4 bars In suspended slabs #4 bars In stirrups and the like #3 bars Sawn formwork to: Vertical faces of columns Ditto to circular columns Sides and soffits of beams Soffit of suspended slabs Sides of beam filling average 10" high cut and fitted between 2" x 6" rafters at 2'0" centres To projecting band 2" x 6" Saw cut concrete/blockwork for flashings A B C D E F G H I J K L M N O P Q R S 16 55 254 22 5 2500 150 5890 3750 2885 CY CY SY CY CY Lbs.
Lbs.

Lbs.

Lbs.

Lbs.

6855 Lbs.

5060 Lbs.
173 31 699 202 171 147 126 SY SY SY SY LY LY LF To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/5 Roof and Roof Finishes (Cont'd) Timber Roof Note: All timber in this section is to be treated pitch pine 2" x 8" ridge 2" x 8" valley rafters 2" x 6" rafters T111 plywood sheeting 1/2" thick 1" x 3" battens PVF2 metal roof sheeting 24 gauge screw fixed to battens at 3'0" centres Ditto ridge capping Ditto valley gutter Ditto in verge flashing girth 16" overall, 3 times bent fixed to sheeting, dressed up wall and into groove at top, include for sealing with non-setting sealant Foam filler strip at ridge and eaves 1" thick rigid foam insulation 199 78 2340 5355 2032 5355 199 78 126 706 5355 LF LF LF SF LF SF LF LF LF LF SF Allow a Provisional Sum for metal connectors PROV SUM 600.00 Flat Roof Finishes Cement/sand screed (1:4) laid to falls and crossfalls on concrete slab Average 2" thick 3" x 3" triangular fillet Torch-on mineral fibre roofing membrane in two layers laid to falls and crossfalls Ditto upstand flashing dressed over triangular fillet and up wall, girth 16" overall Dress roofing membrane to roof outlets Roof Drainage 182 225 182 225 18 SY LY SY LY No.
Harmer or similar cast iron roof outlets with dome grating, set in concrete and connection to 3" dia pipe 18 No.

To Collection $ A B C D E F G H I J K L M N O P Q R ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/6 A B C Roof and Roof Finishes (Cont'd) 3" dia PVC pipes set in concrete Extra over for 45 degree bends Protection 18 54 No.

No.

Allow for the protection of all of the work contained in this section Item To Collection Collection Amount of Page No.

BQ/5 Amount of Page No.


BQ/6 Amount of Page No.
BQ/7 Amount of Roof and Roof Finishes To Block A summary $ $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/7 DOORS AND WINDOWS Windows Refer to Drawing AA10 Supply and fix the following, include for 8.28mm thick laminated grey tinted glass (3mm glass/ 2.28mm pvb/3mm glass) White aluminium awning windows: A B C D E F Type W1 Type W2 Type W3 Type W4 Type W8, with insect screen Type W9 White aluminium vertical sliding sash windows G Type W7, with insect screen Fixed glass windows in white aluminium frames, glass to be butt jointed with colourless silicone H I J K L M N Type W5 Type W6 Secretaries glazed screen 12'0" x 4'0" 7'6" x 4'0" 7'5" x 4'0" White aluminium fixed louvre window Type W10 Type W11, with insect screen Doors Refer to Drawing AA9 Aluminium door with fanlight over, aluminium frames 7 5 11 1 1 1 5 4 1 1 1 1 2 4 No.
No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

O Type D1 7 No.
To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/8 A B C D E F G H I J K L M N O P Q R Doors and Windows (Cont'd) Aluminium fixed louvre doors with frames Type D10 Type D11 Solid core timber doors with frames and stops, natural oak finish to doors Type D2 with laminated glass insert Type D3 Type D4 Type D5 Type D6 (aluminium frame) Ironmongery Supply, fit and fix the following Elite Architectural Ironmongery or equal and approved: Stainless steel hinges Ditto falling hinge Aluminium level lock set, (Note: alllow for master and sub-master keying) Weather saddle screwed to concrete 5'0" long 3'0" long Door closer Toilet indicator bolts Push plates 6" slip bolt to aluminium with keeper set in concrete Sliding door set for 3'0" wide pocket door Male/female toilet signs Galvanise Metal Gates Fabricate and install the following, include for all decoration and ironmongery as described S Type D7 1 1 2 2 5 1 1 42 10 13 1 8 4 5 10 2 1 2 1 No.
No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/9 A B C D E Doors and Windows (Cont'd) Type D8 Type D9 Decoration 1 1 No.

No.
No.

Prepare and paint 1 coat primer and 2 coats gloss oil paint on: Timber frames girth over 9" but not exceeding 12" 31 LY Sundries Caulk around frames with non-setting sealant 284 LY Protection Allow for the protection of all of the work contained in this section Item To Collection Collection Amount of Page No.

BQ/8 Amount of Page No.

BQ/9 Amount of Page No.
BQ/10 Amount of Doors & Windows To Block A Summary $ $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/10 A B C D E F FLOOR FINISHES 12" x 12" Clay tiles laid to pattern, jointed and pointed in cement mortar Clay step tiles bullnosed and grooved, 12" x 12" Clay tiles in risers 7" high 12" x 12" Porcelain floor tiles fixed with adhesive and grouted with acid resistant grout Epoxy floor paint, include for preparing screed Trowelled finish to concrete slab with hardener added Insitu Finishes Cement/sand screed (1:4) trowelled smooth 455 31 31 24 99 10 SY LY LY SY SY SY G 1" thick on horizontal concrete floor slabs 123 SY H I J Skirtings 1" x 6" wpp skirting once bevelled plugged to blockwork 371 LF Prepare and paint 1 coat primer and 2 coats gloss oil paint on: Skirting girth 6" to 9" Protection 124 LY Allow for the protection of all of the work contained in this section Item Amount of Floor Finishes To Block A Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/11 WALL FINISHES In-situ Finishes (Internal and External) Cement/sand render (1:4) 1/2" thick in one coat finished smooth on: Concrete/block walls Circular concrete columns 12" dia Tiling 12" x 12" Porcelain tiles fixed with adhesive and grouted with acid resistant grout 2" x 1" hardwood rail pencil rounded on two arrises, plugged to blockwork Prepare and paint 3 coats matt varnish on ditto girth 3" to 4" Decoration Prepare and paint 1 coat concrete primer and 2 coats emulsion paint on: 1756 31 73 127 42 SY SY SY LF LY Cement/sand rendered walls 1714 SY Protection Allow for the protection of all of the work contained in this section Item A B C D E F F Amount of Wall Finishes To Block A Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/12 CEILING FINISHES Suspended Ceilings Gyproc ceiling boarding 1/2" thick with joints taped and finished smooth, include for 2" x 2" wpp framing at 2'0" centres both ways and for hangers to rafters above Ditto, waterproof 2'0" x 2'0" Accoustic drop-in ceiling tiles as Armstrong 'Minatone' or equal and
 approved, including white suspension system with hanger wire to rafters above Decoration Prepare and paint 1 coat primer and 2 coats gloss oil paint on: 85 55 SY SY 175 SY Exposed timber ceiling 362 SY Prepare and paint 3 coats emulsion paint on: Gyproc ceiling boarding 140 SY Rub down, fill, prepare and paint 2 coat concrete primer and 2 coats emulsion paint on: A B C D E F Soffit of concrete slabs 137 SY Protection G Allow for the protection of all of the work contained in this section Item Amount of Ceiling Finishes To Block A Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/13 FITTINGS AND FIXTURES Kitchen Refer to drawing AA13 Base units 6'0" long x 2'0" wide x 2'11" high splayed one end having 3 doors and 3 drawers, solid surface top with 2" deep fascia and 6" high backsplash, include for adjustable shelving, all hardware and decoration Ditto L-shaped on plan 14'3" long overall, 2'0" wide x 2'11" high having 8 doors and 8 drawers, ditto High level cupboards 15'0" long x 1'0" wide x 3'0" high having 9 doors, include for adjustable shelving, all hardware and decoration Ditto 8'0" long having 5 doors, include for ditto Ditto 3'0" long x 1'0" wide x 1'4" high having 2 doors, include for ditto Toilets Refer to drawing AA12 Solid surface vanity tops with 8" deep fascia front and one end and 6" high backsplash returned one end, include for all support framework and cut out for 1No.
wash basin Solid surface urinal division, screens 1'5" x 2'6" fixed to walls with stainless steel connectors Mirrors with 1/4" ply backing set in 2" x 1" hardwood frame, include for decoration A B C D E F G H 2'6" x 3'0" I J K Supply, fit and fix: Toilet roll holders Counter top mounted soap dispenser, include for hole in solid surfacing Balustrades The following in typical corridor balustrades 1½" dia galvanise posts 3'6" long having 5" x 5"x⅜" thick ms plate 4 times drilled for and including ⅜" dia raw bolts to concrete slab, welded one end and welded joint to top rail other end L 1½" dia galvanise top rail 2 2 1 2 1 2 2 3 6 2 No.
No.

No.

No.

No.

No.

No.

No.

No.

No.

26 136 No.
LF To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/14 Fittings and Fixtures (Cont'd) Ditto to curve 1½" dia intermediate rails Ditto to curve 5" x 5" x ⅜" thick ms plate welded to rails 4 times drilled for and including 3/8" dia rawlbolts to concrete columns Welded joints of intermediate rails to posts The following in handrail to ramp Refer to drawing AA8 1½" dia galvanise rail MS wall brackets welded to rail comprising 1" dia L-shaped bracket welded to 3" x 3" plate 3 times drilled for and including ⅜" dia rawl bolts to concrete 1½" dia ¼" thick end plate welded to rail Welded connection of rail at angle Decoration Grind smooth all welded joints, prepare and paint 2 coats zinc chromate primer and 2 coats gloss oil paint on: 20 408 60 27 126 LF LF LF No.
No.

35 LF 6 2 1 No.

No.

No.

1½" dia galvanise pipe rails 219 LY Provisional Sums Allow a provisional sum for book store shelving PROV SUM Allow a provisional sum for computer lab white board PROV SUM 2,000.00 1,000.00 A B C D E F G H I J K L M Protection Allow for the protection of all of the work contained in this section Item To Collection Collection Amount of Page No.

BQ/14 Amount of Page No.
BQ/15 Amount of Fittings and Fixtures To Block A Summary ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/15 $ $ BUILDERS WORK IN CONNECTION WITH SERVICES All Provisional Electrical Installation Cut and pin the following to blockwork or concrete and afterwards make good: Distribution panel/transformer Power outlets Ditto floor mounted Telephone/computer points Equipment points Fire alarm panel Smoke/heat detection points Pull or break glass boxes Outdoor sounder Lighting points - ceiling Ditto - walls Switch points Clock, wall mounted Wall mounted speaker PA station Wall mounted CCTV camera points Cut gypsum/concrete board ceilings for and afterwards make good: Ceiling lights Ditto - 2'0" x 4'0" Ditto in suspended ceiling system A/C Installation 6 47 18 11 11 1 13 4 3 17 17 15 2 4 1 7 5 15 22 No.
No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

Allow a Provisional sum for BWIC with A/C Installation PROV SUM 1,300.00 To Collection $ A B C D E F G H I J K L M N O P Q R S T ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/16 A B Builders Work (Cont'd) Plumbing and Gas Installation Allow a provisional sum for BWIC PROV SUM 2,000.00 Protection Allow for the protection of all of the work contained in this section Item To Collection Collection Amount of Page No.
BQ/16 Amount of Page No.

BQ/17 Amount of Builders Work in Connection with Services to Block A Summary $ $ ST. MARY'S SECONDARY SCHOOL BLOCK A OCTOBER 2016 BQ/17 ST. MARY'S SECONDARY SCHOOL BLOCK A SUMMARY Substructure from Page No.

BQ/3 Blockwork Walls from Page No.

BQ/4 Roof and Roof Finishes from Page No.

BQ/7 Doors and Windows from Page No.

BQ/10 Floor Finishes from Page No.

BQ/11 Wall Finishes from Page No.

BQ/12 Ceiling Finishes from Page No.

BQ/13 Fittings and Fixtures from Page No.


BQ/15 BWIC with Services from Page No.

BQ/17 Amount of BLOCK A To Tender Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK A - SUMMARY OCTOBER 2016 SA/1 ST. MARY'S SECONDARY SCHOOL BLOCK B SUBSTRUCTURE Notes: (i) The items and quantities included under this heading include all structural work below the top of the structural ground floor slab (ii) No allowance for working space has been allowed in computing the quantities of excavation.
Any working space which is considered necessary by tenderers must be allowed for in their unit rates for these items.
Excavations Excavate over area of building to remove top soil and stockpile on site Ditto below ditto in isolated pits not exceeding 5'0" deep and ditto Ditto exceeding 5'0" but not exceeding 10'0" deep and ditto Prepare, level and ram bottom of excavations to receive concrete Planking and strutting to sides of pit excavations not exceeding 5'0" deep Ditto exceeding 5'0" but not exceeding 10'0" deep Backfilling to pits well compacted in maximum 8" layers Ditto to foundation walls after built Well compacted backfilling in maximum 8" layers within foundations under slabs Imported fill material well compacted in 8" layers within ditto Prepare surface of fill to receive concrete 500 gauge polythene damp proof membrane well lapped Concrete Work A B C D E F G H I J K L 172 305 61 183 233 47 58 40 77 94 154 300 CY CY CY SY SY SY CY CY CY CY SY SY M 2" thick blinding concrete (1:4:8) 183 SY Reinforced insitu concrete 3000 psi at 28 days 3/4" aggregate N In isolated column bases To Collection $ 12 CY ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/1 A B C D E Substructure (Cont'd) Cistern base slab 10" thick In columns In beams In slabs 6" thick In suspended slabs 6" thick Reinforcement to ASTM A615 In foundations F #6 bars In cistern base slab G #4 bars In columns H #5 bars In beams #6 bars In slabs #4 bars I J 146 5 19 130 130 SY CY CY SY SY 2070 Lbs.
2600 Lbs.

1050 Lbs.

4150 Lbs.

6550 Lbs.

In stirrups and the like K #3 bars 2145 Lbs.


L M N O P Sawn formwork to: Sides of foundations Vertical faces of columns Sides and soffit of beams Soffit of suspended slabs Edges of slabs 6" high Blockwork 47 64 176 130 6 SY SY SY SY LY Hollow concrete blocks 1000 psi laid in 1:3 cement/sand mortar Q In walls 8" thick filled solid with concrete 150 SY To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/2 Substructure (Cont'd) A #4 bars in vertical reinforcement 3500 Lbs.
'Durowall' or similar horizontal mild steel ladder reinforcement laid in B 8" thick walls Insitu Finishes Cement and sand render (1:4) finished smooth ½" thick in one coat on concrete/block walls ¾" thick in two coats on ditto 6" radius cove at junction of walls and base 2 coats thoroseal on cistern base Ditto on rendered walls Sundries Allow a provisional sum for cistern access manhole covers Protection C D E F G H I 337 LY 119 197 96 121 197 SY SY LY SY SY PROV SUM 1,000.00 Allow for the protection of all of the work contained in this section Item To Collection Collection Amount of Page No.
BQ/1 Amount of Page No.

BQ/2 Amount of Page No.
BQ/3 Amount of Substructure To Block B Summary $ $ ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/3 CONCRETE WORK Reinforced insitu concrete 3000 psi at 28 days ¾" aggregate In columns and stiffeners In beams in suspended slabs 6" thick 5" thick In upstand beams In beam filling between timber rafters at 2'0" centres 6" dia metal columns 8'0" long welded both ends to 12" x 6" x ⅜" thick metal plates twice drilled for bolts Drill concrete for and including ⅝" expansion bolts 5" long Non-shrinking grout 12" x 6" to top and bottom of columns Reinforcement to ASTM A615 In columns and stiffeners #6 bars #5 bars In beams and upstand beams #6 bars #5 bars #4 bars In suspended slabs A B C D E F G H I J K L M N 26 29 33 88 15 5 7 14 14 1800 260 3350 2150 1640 CY CY SY SY CY CY No.
No.

No.

Lbs.

Lbs.

Lbs.

Lbs.

Lbs.

O #4 bars 3270 Lbs.

In stirrups and the like P #3 bars 3036 Lbs.
Sawn formwork to: Q R Vertical faces of columns Sides and soffits of beams 136 350 SY SY To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/4 A B C D E Concrete Work (Cont'd) Soffit of suspended slabs Sides of beamfilling average 10" high cut and fitted between 2" x 6" rafters at 2'0" centres To projecting band 2" x 6" Saw cut concrete/blockwork for flashings Protection 99 96 48 120 SY LY LY LY Allow for the protection of all of the work contained in this section Item To Collection Collection Amount of Page No.
BQ/4 Amount of Page No.

BQ/5 Amount of Concrete Work To Block B Summary $ $ ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/5 BLOCKWORK WALLS Hollow concrete blockwork 1000 psi laid in 1:3 cement mortar In walls 6" thick 4" thick Concrete filling (2000 psi at 28 days) to single core of blockwork reinforced with 1No.
½" dia ht bar 6" thick walls 4" thick walls "Durowall" or similar horizontal mild steel ladder reinforcement laid in 6" thick walls 4" thick walls 303 43 574 64 340 53 SY SY LY LY LY LY Drill concrete 4" deep for and grout in #3 bars 16" long, built into joints of blockwork at connection of walls to columns 105 No.
Concrete 3000 psi at 28 days in lintel and capping beams Reinforcement in ditto Sawn formwork to sides and soffit of ditto Form concrete sills 10" x 4" once checked, bevelled and grooved on underside, include rebar and formwork Concrete in surrounds to circular window Type #11 Reinforcement in ditto Sawn formwork to sides Ditto 6" wide curved to 3'0" dia Protection 1 95 9 69 ½ 50 7 6 CY Lbs.

SY LY CY Lbs.
SY LY Allow for the protection of all of the work contained in this section Item A B C D E F G H I J K L M N O P Amount of Blockwork Walls To Block B Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/6 A B C D E F G H I J K L M N O P ROOF & ROOF FINISHES Timber Roof Note: All timber in this section to be treated pitch pine 2" x 8" ridge 2" x 6" rafters T111 plywood sheeting ½" thick 1" x 3" battens PVF2 metal roof sheeting 24 gauge screw fixed to battens at 3'0" centres Ditto ridge capping Ditto in verge flashing girth 16" overall, 3 times bent, fixed to sheeting, dressed up wall and into groove at top, include for sealing with non-setting sealant Foam filler strip at eave and ridge 1" thick rigid foam insulation 69 840 1932 828 1932 69 56 276 1932 LF LF SF LF SF LF LF LF SF Allow a provisional sum for metal connectors PROV SUM 500.00 Flat Roof Finishes Cement and sand screed (1:4) laid to falls and crossfalls on concrete slab Average 2" thick 3" x 3" triangular fillet Torch-on roofing mineral fibre membrane in two layers laid to falls and crossfalls Ditto upstand flashing dressed over triangular fillet and up wall, girth 16" overall Dress roof membrance to roof outlets Roof Drainage Harmer or similar cast iron roof outlets with dome grating, set in concrete and connection to 3" dia pipe 99 120 99 120 8 8 53 SY LY SY LY No.
No.

LY Q 3" dia PVC pipe set in concrete To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/7 A B C Roof & Roof Finishes (Cont'd) Extra over for 45 degree bends 24 No.

Provisional Sum Allow a provisional sum for the fabrication and installation of roof access ladder PROV SUM 1,300.00 Protection Allow for the protection of all of the work contained in this section Item To Collection Collection Amount of Page No.

BQ/7 Amount of Page No.
BQ/8 Amount of Roof & Roof Finishes To Block B Summary $ $ ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/8 DOORS AND WINDOWS Windows Refer to Drawing BA11 Supply and fix the following, include for 8.28mm thick laminated grey tinted glass (3mm glass/ 2.28mm pvb/3mm glass) White aluminium awning windows Type 1 Type 2 Type 3 Type 4 Type 5 Type 9 White aluminium fixed louvre window Type 11, with insect screen Doors Refer to Drawing BA10 Aluminium door with fanlight over, aluminium frames A B C D E F G H Type D1 Solid core timber doors with frames and stops, natural oak finish to doors I J K L M Type D2 Type D3 Type D3 with laminate glass insert Type D4 Type D5 White aluminium accoustical sliding/folding door (8No.
3'0" wide panels) with aluminium frames including all tracks, hinges, locks and bolts N Type D4, 24'0" wide x 8'0" high 6 4 10 1 9 1 2 8 1 1 1 6 2 2 No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.


To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/9 Doors and Windows (Cont'd) Ironmongery Supply, fit and fix the following Elite Architectural Ironmongery or equal and approved: Stainless steel hinges Ditto falling hinge Aluminium lever lockets, (Note: allow for master and sub-master keying) Weather saddle screwed to concrete 3'0" long Toilet indicator bolt Push plates Male/female toilet signs Decoration 33 16 11 8 8 16 2 No.

No.

No.
No.

No.

No.

No.

No.

No.

Prepare and paint 1 coat primer and 2 coats gloss oil paint on: Timber frames girth over 9" but not exceeding 12" 60 LY Sundries Caulk around frames with non-setting sealant 258 LY Protection Allow for the protection of all of the work contained in this section Item To Collection A B C D E F G H I J Collection Amount of Page No.

BQ/9 Amount of Page No.
BQ/10 Amount of Doors and Windows To Block B Summary ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/10 $ $ FLOOR FINISHES 12" x 12" Porcelain floor tiles fixed with adhesive and grouted with acid resistant grout Epoxy floor paint, include for preparing screed Trowelled finish to concrete slab to receive ditto 51 447 447 SY SY SY Skirtings 1" x 6" wpp skirting once bevelled, plugged to blockwork 138 LF Prepare and paint 1 coat primer and 2 coats gloss oil paint on: Skirtings girth 6" to 9" 46 LY Protection Allow for protection of all work contained in this section Item A B C D E F Amount of Floor Finishes To Block B Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/11 WALL FINISHES In-situ Finishes (Internal & External) Cement/sand render (1:4) 1/2" thick in one coat finished smooth on: Concrete/block walls 1178 SY Tiling 12" x 12" Porcelain tiles fixed with adhesive and grouted with acid resistant grout 2" x 1" hardwood rail pencil rounded on two arrises, plugged to blockwork Prepare and paint 3 coats matt varnish on ditto girth 3" to 6" Decoration Prepare and paint 1 coat concrete primer and 2 coats emulsion paint on: 105 SY 155 52 LF LY Cement/sand render walls 1159 SY Protection Allow for the protection of all of the work contained in this section Item A B C D E E Amount of Wall Finishes To Block B Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/12 CEILING FINISHES Suspended Ceilings A Gyproc ceiling boarding ½" thick with joints taped and finished smooth, include for 2" x 2" wpp framing at 2'0" centres both ways and for hangers to rafters above B Ex 1" x 3" wpp cornice moulding Decoration Rub down, fill, prepare and paint 1 coat concrete primer and 2 coats emulsion paint on: 160 224 SY LF C D E F Soffit of concrete slabs 349 SY Prepare and paint 3 coats emulsion paint on: Gyproc ceiling boarding 160 SY Prepare and paint 1 coat primer and 2 coats gloss oil paint on: Timber cornice moulding girth 3" to 6" 75 LY Protection Allow for the protection of all of the work contained in
 this section Item Amount of Ceiling Finishes to Block B Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/13 FITTINGS AND FIXTURES Science Laboratory/Home Management Base units 2'0" wide x 3'0" high with doors one side and intermediate shelf, solid surface top with 2" deep fascia, include for all hardware and decoration 31'6" long with 6" backsplash 23'0" long with ditto 16'0" long with ditto 13'6" long with ditto 12'0" long with ditto 8'0" long with ditto 11'0" long free standing unit with back panel 6'0" long, ditto Extra over for cutting hole in worktop for sink High level cupboard 1'0" wide x 3'0" high, include for 2No.
Intermediate adjustable shelves, all hardware and decoration 16'0" long, 8No.

doors 12'0" long, 6No.

doors 1 1 1 2 1 1 12 1 25 1 1 No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

Include a Provisional Sum for science laboratory raised teaching platform PROV SUM A B C D E F G H I J K L M Include a Provisional Sum for 2No.
white boards PROV SUM Toilets Refer to Drawing BA13 Solid surface vanity tops with 8" deep fascia front and one end and 6" high backsplash returned one end, include for all support framework and cut out for 3No.

wash basins Mirrors with ¼" ply backing set in 2" x 1" hardwood frame, include for decoration 2'6" x 3'0" 2'2" x 3'0" N O P 2 6 3 No.

No.

No.
To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/14 1,200.00 2,000.00 A B C D E F G H I J Fittings & Fixtures (Cont'd) Supply, fit and fix: Toilet roll holders Counter top mounted soap dispenser, include for hole in solid surfacing Balustrades The following in typical corridor balustrades 1½" dia galvanise post 3'6" long having 5" x 5" x ⅜" thick ms plate 4 times drilled for and including ⅜" dia rawl bolts to concrete slab, welded one end and welded joint to top rail other end 1½" dia top rail 1½" dia intermediate rails Welded joints of intermediate rails to posts 9 6 12 165 258 132 No.
No.

No.

LF LF No.

5" x 5" x ⅜" thick ms plate welded to rails 4 times drilled for and including ⅜" dia rawl bolts to concrete columns 24 No.

1½" dia galvanise rails in panel 7'0" wide x 8'0" high having 3No.

Vertical rails and 7No.

horizontal rails all welded together and bolted to concrete with 8No.

⅜" dia rawl bolts 2 No.


Decoration Grind smooth all welded joints, prepare and paint 2 coats zinc chromate primer and 2 coats gloss oil paint on: 1½" dia galvanise pipe rails 204 LY Protection Allow for the protection of all of the work contained in this section Item To Collection Collection Amount of Page No.

BQ/14 Amount of Page No.
BQ/15 Amount of Fittings and Fixtures To Block B Summary ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/15 $ $ BUILDERS WORK IN CONNECTION WITH SERVICES All Provisional Electrical Installation Cut and pin the following to blockwork or concrete and afterwards make good A B C D E F G H I J K L M Distribution panel Power outlets Ditto floor mounted Telephone/computer points Equipment points Fire alarm panel Smoke/heat detection points Pull or break glass boxes Lighting points Switch points Cut gypsum/concrete board ceilings for and afterwards make good: Ceiling lights Ditto - 2'0" x 4'0" Ditto in suspended ceiling system Plumbing and Gas Installation 4 40 7 2 6 1 9 3 10 9 6 28 17 No.
No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

N Allow a provisional sum for BWIC PROV SUM 2,000.00 Protection O Allow for the protection of all of the work contained in this section Item Amount of Builders Works in Connection with Services to Block B Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK B OCTOBER 2016 BQ/16 ST. MARY'S SECONDARY SCHOOL BLOCK B SUMMARY Substructure from Page No.

BQ/3 Concrete Work from Page No.

BQ/5 Blockwork Walls from Page No.


BQ/6 Roof and Roof Finishes from Page No.

BQ/8 Doors and Windows from Page No.

BQ/10 Floor Finishes from Page No.

BQ/11 Wall Finishes from Page No.

BQ/12 Ceiling Finishes from Page No.

BQ/13 Fittings and Fixtures from Page No.

BQ/15 BWIC with Services from Page No.


BQ/16 Amount of BLOCK B To Tender Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK B - SUMMARY OCTOBER 2016 SB/1 ST. MARY'S SECONDARY SCHOOL BLOCK C DEMOLITIONS AND ALTERATIONS Carefully take out existing doors and frames 3'0" x 7'0" 5'0" x 7'0" Ditto existing windows 4'0" x 4'0" Disconnect, carefully remove the following and remove from site: WC's Vanity tops with 2No.
Washbasins Wash basin Carefully demolish existing concrete blockwalls and remove all debris from site Make good floors and walls where walls removed Carefully demolish existing reinforced concrete stair with balustrades and remove with all debris from site (south of existing admin block) Construct new 6" thick concrete block walls & Cement/sand render 1/2" thick finished smooth both sides Bond ends of new 6" block walls to existing blockwork Doors (Refer to Drawing CA9) Supply and install the following: Aluminium door with fanlight over, aluminium frames A B C D E F G H I J K L M Type D1 Type D6 Solid core timber doors with frames and stops, natural oak finish to doors N Type D5 12 2 4 5 2 1 76 55 Item 66 21 5 2 2 No.
No.

No.

No.

No.

No.

SY LY SY LY No.

No.

No.
To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/1 A B C D E F G H I J K Demolitions and Alterations (Cont'd) Ironmongery Supply, fit and fix the following: Stainless steel hinges Aluminium lever lock set (Note: allow for master and sub-master keying) Weather saddle screwed to concrete 5'0" long 3'0" long 6" slip bolt to aluminium with keeper to concrete Male/female toilet signs Galvanise Metal Gates Fabricate and install the following, include for all decoration and ironmongery as described Type D2 Type D3 Type D7 Decoration Prepare and paint 1 coat primer and 2 coats gloss oil paint on: Timber frames girth 9" to 12" Caulk around frames with non setting sealant Windows (Refer to Drawing CA9) Supply and fix the following, include for 8.28mm thick laminated grey tinted glass (3mm glass/ 2.28mm pvb/3mm glass) White aluminium awning windows 6 9 2 7 4 2 1 1 1 11 56 No.
No.

No.

No.

No.

No.

No.

No.

No.

LY LY L Type W1 Provisional Sums 2 No.
M Allow for the removal and construction of new vanity in female washroom PROV SUM 2,000.00 To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/2 A B C D E F G H I J K L M N O P Q Demolitions and Alterations (Cont'd) Allow for repairs to existing cupboards and tops in science laboratory and home economics General Maintenance Work to Existing Buildings Prepare and paint 2 coats emulsion on interior and exterior walls Ditto 1 coat emulsion on ceilings Clean down and paint 2 coats oil paint on timber soffit and eaves of first floor walkways Prepare and paint existing concrete floor with epoxy floor paint Remove and replace the following with new stainless steel fittings toilet roll holders mirrors 18" x 18" PROV SUM 6,000.00 2924 1753 168 1753 10 16 SY SY SY SY No.
No.

Prepare and paint 2 coats gloss oil paint on existing timber doors 109 SY Remove existing and replace with new aluminium lever lock sets (Note: allow for master and sub-master keying) 20 No.

Prepare and apply rust inhibitor and 3 coats gloss oil paint on existing metalwork generally 133 SY Repair leaking connections at top of rainwater pipes Carefully cut out existing concrete and repair around exposed rebar on walkway (2No.)
Ditto and repair cracks along entire length of concrete fascia Ditto and repair cracks below windows on ground floor Wire brush all starter bars on first floor to remove rust Check and service existing A/C in library Ditto in computer laboratory Item Item Item Item Item Item Item To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/3 5,000.00 2,000.00 10,000.00 7,500.00 5,000.00 5,000.00 Demolitions and Alterations (Cont'd) Provisional Sums Allow provisional sums for the following: A B C D E F G Repairs to existing windows PROV SUM Checking and repairing reported water in wall of staff room PROV SUM Allow for cleaning gutters and for general repairs to roof PROV SUM Repair water leaks in 4# locations PROV SUM Repair work to ground floor east walkway floor slab Cut out and repair cracks on first floor walkway (approximately 23#) PROV SUM PROV SUM Protection Allow for the protection of all of the work contained in this section Item To Collection Collection Amount of Page No.
BQ/1 Amount of Page No.

BQ/2 Amount of Page No.

BQ/3 Amount of Page No.

BQ/4 Amount of Demolitions and Alterations To Block C Summary $ $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/4 SUBSTRUCTURE Notes: (i) The items and quantities included under this heading include all structural work below the top of the structural ground floor slab (ii) No allowance for working space has been allowed in computing the quantities of excavation.
Any working space which is considered necessary by tenderers must be allowed for in their unit rates for these items.
(iii) The items and quantities included under this heading include both access stairs and the outdoor dining area Excavations Excavate over area of building to remove top soil and stock pile on site Ditto below ditto in isolated pits not exceeding 5'0" deep Ditto exceeding 5'0" but not exceeding 10'0" deep Prepare, level and ram bottom of excavations to receive concrete/fill Planking and strutting to sides of pit excavations not exceeding 5'0" deep Ditto exceeding 5'0" but not exceeding 10'0" deep Backfilling to pits well compacted in 8" layers Backfilling around building after walls are built Imported fill, material well compacted in 8" layers Prepare surface of fill to receive concrete 500 gauge polythene damp proof membrane well lapped Concrete Work A B C D E F G H I J K 49 17 3 11 53 7 13 3 11 43 43 CY CY CY SY SY SY CY CY CY SY SY L 2" thick blinding concrete (1:4:8) 11 SY Reinforced insitu concrete 3000 psi at 28 days ¾" aggregate M N O In foundations In columns In beams 4 1 3 CY CY CY To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/5 A B C D E F G Substructure (Cont'd) In slabs 5" thick In steps Reinforcement to ASTM A615 In foundations #6 bars In columns #6 bars #5 bars In beams #6 bars #4 bars In slabs 17 1 SY CY 750 Lbs.
150 100 700 25 Lbs.

Lbs.

Lbs.

Lbs.

H #4 bars 300 Lbs.

I J K L M N O P In steps #4 bars In stirrups and the like #3 bars Sawn formwork to: Sides of foundations Vertical faces of columns Sides & soffits of beams Risers of steps 7" high Blockwork 150 Lbs.

300 Lbs.

11 14 29 5 SY SY SY LY Hollow concrete blocks 1000 psi laid in 1:3 cement mortar In walls 8" thick filled solid with concrete #4 bars in vertical reinforcment 14 150 SY Lbs.
To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/6 Substructure (Cont'd) "Durowall" or similar horizontal mild steel ladder reinforcement laid in: 8" thick walls Protection 31 LY Allow for the protection of all of the work contained in this section Item To Collection A B Collection Amount of Page No.

BQ/5 Amount of Page No.

BQ/6 Amount of Page No.
BQ/7 Amount of Substructure To Block C Summary $ $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/7 CONCRETE WORK Reinforced insitu concrete 3000 psi at 28 days ¾" aggregate A B C D E F G H I J K L In columns In beams In suspended slabs 6" thick In upstand beams In stairs and landings Reinforcement to ASTM A615 In columns and stiffeners #6 bars #5 bars In beams and upstand beams #6 bars #5 bars #4 bars In suspended slabs #4 bars In stairs and landings #4 bars In stirrups and the like 3 4 17 2 3 250 40 950 650 500 CY CY SY CY CY Lbs.
Lbs.

Lbs.

Lbs.

Lbs.

750 Lbs.

400 Lbs.

M #3 bars 500 Lbs.
Sawn Formwork to: Vertical faces of columns Sides and soffits of beams Soffits of suspended slabs and landings Sloping soffit of stairs Exposed stringer of stair 12" wide Sides of upstand beams N O P Q R S 38 30 17 12 18 17 SY SY SY SY LY SY To Collection $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/8 A B C Concrete Work (Cont'd) To projecting band 2" x 6" Saw cut concrete/blockwork for flashings Protection 33 13 LY LY Allow for the protection of all of the work contained in this section Item To Collection Collection Amount of Page No.
BQ/8 Amount of Page No.

BQ/9 Amount of Concrete Work To Block C Summary $ $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/9 BLOCKWALL WALLS Hollow concrete blockwork 3000 psi laid in 1:3 cement/sand mortar In walls A 6" thick 50 SY Concrete filling (2000 psi at 28 days) to single core of blockwork reinforced with 1No.
½" dia ht bar B 6" thick walls 80 LY Durowall' or similar horizontal mild steel ladder reinforcement laid in 6" thick walls Concrete 3000 psi at 28 days in lintel beams Reinforcement in ditto Sawn formwork to sides and soffits of ditto Concrete in surrounds to circular windows, Type #6 Reinforcement in ditto Sawn formwork to sides Ditto 6" wide curved to 5'0" diameter Protection 65 ½ 70 2 1 125 22 15 LY CY Lbs.

SY CY Lbs.
SY LY Allow for the protection of all of the work contained in this section Item C D E F G H I J K Amount of Blockwork Walls To Block C Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/10 ROOF AND ROOF FINISHES Flat Roof Finishes Cement/sand screed (1:4) laid to falls and crossfalls on concrete slab Average 2" thick 3" x 3" triangular fillet Torch-on mineral fibre roofing membrane in two layers laid to falls and crossfalls Ditto upstand flashing dressed over triangular fillet and up wall girth 16" overall Dress roofing membrane to roof outlets Roof Drainage Harmer or similar cast iron roof outlets with dome grating set in concrete and connection to 3" dia 3" dia PVC pipes set in concrete Extra for 45 degree bends Protection 16 16 16 16 1 1 8 3 SY LY SY LY No.
No.

LY No.

Allow for the protection of all of the work contained in this section Item A B C D E F G H I Amount of Roof and Roof Finishes To Block C Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/11 DOORS AND WINDOWS Windows Refer to Drawing CA9 Supply and fix the following, include for 8.28mm thick laminated grey tinted glass (3mm glass/ 2.28mm pvb/3mm glass) Fixed glass window in white aluminium frame Type W6, 5'0" dia Sundries 2 No.
Caulk around frames with non setting sealant 15 LY Protection Allow for the protection of all of the work contained in this section Item A B C Amount of Doors and Windows To Block C Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/12 FLOOR FINISHES A B C Epoxy floor paint, include for preparing concrete Trowelled finish to concrete to receive ditto 25 25 SY SY Protection Allow for the protection of all of the work contained in this section Item Amount of Floor Finishes To Block C Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/13 WALL FINISHES In-situ Finishes (Internal & External) Cement/sand render (1:4) ½" thick in one coat finished smooth on: A Concrete/block walls 168 SY Decoration Prepare and paint 1 coat concrete primer and 2 coats emulsion on: B C Cement/sand render walls 168 SY Protection Allow for the protection of all of the work contained in this section Item Amount of Wall Finishes To Block C Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/14 CEILING FINISHES Decoration Rub down, fill, prepare and paint 1 coat concrete primer and 2 coats emulsion on: Soffit of concrete slabs Sloping soffit of concrete stairs Protection 17 12 SY SY Allow for the protection of all of the work contained in this section Item A B C Amount of Ceiling Finishes To Block C Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/15 A B C D E F FITTINGS AND FIXTURES The following in stair handrails Raking balustrade panel comprising 2No.
1½" dia posts and 3No.

1½" dia rails all welded together 3'0" high x 6'0" long 3 No.
5" x 5" x ⅜" thick ms base plate welded to post drilled 4 times for and including ⅜" dia expansion bolts to concrete 1½" dia galvanise rail MS wall brackets welded to rails comprising 1" dia L-shaped bracker welded to 3" x 3" plate 3 times drilled for and including ⅜" dia expansion bolts to concrete Welded connection of rail at angle 1½" dia ¼" thick end plate welded to rail Decoration Grind smooth all welded joints, prepare and paint 2 coats zinc chromate primer and 2 coats gloss oil paint on: 6 34 14 4 4 No.
LF No.

No.

No.

G 1½" dia galvanise pipe rails 38 LY Protection H Allow for the protection of all of the work contained in this section Item Amount of Fittings and Fixtures To Block C Summary $ ST. MARY'S SECONDARY SCHOOL BLOCK C NOVEMBER 2018 BQ/16 ST. MARY'S SECONDARY SCHOOL - PHASE 2 TENDER SUMMARY SUMMARY Amount of Preliminaries from Page No.

P/25 Amount of Block A from Page No.

SA/1 Amount of Block B from Page No.

SB/1 Amount of Block C from Page No.

SC/1 Amount of External Works from Page No.


EW/12 Amount of MEP Installation from Page No.

MEP/1 Amount of Dayworks from Page No.

DW/4 Fringe Benefits (as Preliminaries) Third Party Insurance Insurance Against Fire, etc.
Contingencies Profits & Overheads (if not previously included) US$ 100,000.00 TOTAL TO FORM OF TENDER US$ ST. MARY'S SECONDARY SCHOOL TENDER SUMMARY NOVEMBER 2016 TS/1 EXTERNAL WORKS ST. MARY'S SECONDARY SCHOOL EXTERNAL WORKS ROADS, CAR PARK AND CONCRETE PAVING Excavate to reduce levels starting from existing ground level and remove from site 1192 CY Extra over ditto for excavating in existing asphalt road 56 CY Prepare and grade surfaces of excavations to receive fill 1430 SY Marl fill material consolidated in layers not exceeding 6" before compaction 12" base course (graded limestone 1" - 3") with penetration to receive asphalt 1½" thick hot mix asphalt wearing course Prepare and paint 2 coats road marking paint on: Asphalt surfacing in strip 4" wide Ditto in handicap reserved parking sign In-situ concrete, Grade 20, ¾" aggregate in: Kerb size 5" x 16" overall finished smooth on exposed surfaces girth 20", include for all reinforcement and formwork, excavation and haunching ref.
engineers drawing C002.1 detail 02 Ditto to curves 5" thick beds with exposed aggregate finish A142 mesh fabric in ditto Sawn formwork to edges of bed 5" high 477 1295 1295 84 1 239 77 135 135 103 CY SY SY LY No.

LY LY SY SY LY 6" x 6" precast concrete wheel stops 6'0" long anchored in place 17 No.
Provisional sum for repairs to existing sidewalk and roadway at entrance PROV SUM 1,000.00 Protection Allow for the protection of all of the work contained in this section Item A B C D E F G H I J K L M N O P Amount of Roads, Car Park and Concrete Paving To External Work Summary $ ST. MARY'S SECONDARY SCHOOL EXTERNAL WORKS NOVEMBER 2016 EW/1 SURFACE WATER DRAINAGE Excavate in trench not exceeding 5'0" deep for pipes, part return fill and ram selected excavated material and spread and level surplus on site, include for grading bottom and keeping free from general water, for: 8" dia pipe average 3'0" deep 6" dia pipe average 3'0" deep Sand surround to pipes A B C 334 LY 84 44 LY CY Excavate through existing reinforced concrete floor slab and fill, part return fill and ram selected excavated material, spread and level surplus on site, include for grading bottom and keeping free from general water, for: D 8" dia pipe 11 LY PVC pipes schedule 80 laid and jointed in trenches E F G H I J K L M N 8" dia 6" dia Construct land drain including excavation, backfill, gravel surround to and including 4" perforated pipe, and geotextile fabric all as per engineers drawing C002.1 detail 3 Ditto with 6" perforated pipe Construct manhole with metal cover as engineers drawing L002.1, detail 6 Construct catch pit with ductile iron grating as engineers drawing C002.1 detail 4 334 84 395 55 5 11 LY LY LY LY No.
No.
Excavate over courtyard area to reduce level and remove from site 482 CY Imported top soil spread abd levelled in 12" thick layer 1445 SY Provisional Sum for concrete head walls at drain outfalls PROV SUM 3,000.00 Protection Allow for the protection of all of the work contained in this section Item Amount of Surface Water Drainage To External Works Summary $ ST. MARY'S SECONDARY SCHOOL EXTERNAL WORKS NOVEMBER 2016 EW/2 SOIL AND WASTE DRAINAGE Excavate in trenches not exceeding 5'0" deep for large bore pipes, return fill and ram selected excavated material and spread and level surplus on site, include for grading bottom and for keeping free from general water Average 2'6" deep Sand surrounds to pipes PVC pipes laid and jointed in trenches 4" diameter 2" diameter Extra over bends 4" dia 2" dia Extra for branches 4" dia 4" - 2" dia 2" dia Construct clean outs all as detailed on engineers drawing Construct grease trap ZURN-Z1172 all as ditto 4139 litres 1758 litres Construct septic tank all as detailed on engineers drawing 1207-ME-WW-300 Construct sand filter all as detailed on engineers drawing 1207-ME-WW-300 #1 #2 Supply and install 341 litre neutralisation tank all as detailed on engineers drawing Testing 71 10 50 21 10 7 6 6 8 9 1 1 1 1 1 1 LY CY LY LY No.
No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

No.

Allow for testing the whole of the drainage installation to the satisfaction of the Architect Item To Collection $ A B C D E F G H I J K L M N O P Q ST. MARY'S SECONDARY SCHOOL EXTERNAL WORKS NOVEMBER 2016 EW/3 Soil and Waste Drainage (Cont'd) Protection A Allow for the protection of all of the work contained in this section Item To Collection To Collection Amount of Page No.

EW/3 Amount of Page No.
EW/4 Amount of Soil and Waste Drainage To External Works Summary $ $ ST. MARY'S SECONDARY SCHOOL EXTERNAL WORKS NOVEMBER 2016 EW/4 BUILDERS WORK IN CONNECTION WITH SERVICES Water Supply Excavate in trenches for large bore pipes not exceeding 5'0" deep part return fill and ram selected excavated material and spread and level surplus on site, include for keeping free from general water average 2'0" deep Sand filling in trenches around pipes Construct gate valve/meter chamber of 3" thich reinforced concrete foundations, 4" blockwalls, concrete capping with chequer plate cover, size: 3'0" x 2'0" x 2'0" deep internally Construct concrete foundation for fire hydrant Electrical and Telephone Distribution Excavate in trenches not exceeding 5'0" deep, part return, fill and ram selected excavated material and spread and level surplus on site, include for keeping free from general water 3'0" deep for multiple ducts 1'6" deep for small bore conduit Sand filling in trenches around ducts 12" x 12" clay tile laid in trench with electrical caution tape above Construct electrical manholes 4'0" x 4'0" internally all as shown on M&E site plan manhole layout drawing 4'0" deep internally Excavate in isolated pits for and including 2'0" x 2'0" x 1'6" deep concrete foundation for light poles A/C Installation 157 18 1 1 169 317 25 486 5 18 LY CY No.
No.

LY LY CY LY No.

No.
Allow a provisional sum for BWIC A/C condensate drains PROV SUM 1,300.00 Protection Allow for the protection of all of the work contained in this section Item A B C D E F G H I J K L Amount of BWIC with Services To External Work Summary $ ST. MARY'S SECONDARY SCHOOL EXTERNAL WORKS NOVEMBER 2016 EW/5 SECURITY BOOTH Substructure Notes: (i) The items and quantities included under this heading include all structural work below the top of the structural ground floor slab (ii) No allowance for working space has been allowed in computing the quantities of excavation.
Any working space which is considered necessary by tenderers must be allowed for in their unit rates for these items.
Excavations Excavate over area of building to remove top soil and stockpile on site Ditto below ditto in isolated pits not exceeding 5'0" deep and ditto Ditto exceeding 5'0" but not exceeding 10'0" deep and ditto Prepare, level and ram bottom of excavations to receive concrete Planking and strutting to sides of pit excavations not exceeding 5'0" deep Ditto exceeding 5'0" but not exceeding 10'0" deep Backfilling to pits well compacted in maximum 8" layers Ditto to foundation walls after built Imported fill material well compacted in 8" layers within ditto Prepare surface of fill to receive concrete 500 gauge polythene damp proof membrane well lapped A B C D E F G H I J K Concrete Work L 2" thick blinding concrete (1:4:8) Reinforced insitu concrete 3000 psi at 28 days 3/4" aggregate 2 4 10 4 25 10 22 9 2 3 3 4 CY CY CY SY SY SY CY CY CY SY SY SY M In isolated column bases 1½ CY To Collection $ ST. MARY'S SECONDARY SCHOOL EXTERNAL WORKS NOVEMBER 2016 EW/6 A B C D E F G Security Booth (Cont'd) In columns In beams In slabs 6" thick Reinforcement to ASTM A615 In foundations #5 bars In columns #5 bars In beams #5 bars #4 bars In slabs ½ 1 4 CY CY SY 40 Lbs.
40 Lbs.

55 30 Lbs.

Lbs.

H #4 bars 45 Lbs.

I J K L M N In stirrups and the like #3 bars Sawn formwork to: Sides of foundations Vertical faces of columns Sides and soffit of beams Structure Reinforced insitu concrete 3000 psi at 28 days ¾" aggregate In beams In beam filling between timber rafters at 2'0" centres Reinforcement to ASTM A615 In stiffeners O #4 bars In beams and upstand beams 80 Lbs.

5 6 6 1 1 SY SY SY CY CY 85 Lbs.

P #5 bars 55 Lbs.
P #5 bars 55 Lbs.

To Collection $ ST. MARY'S SECONDARY SCHOOL EXTERNAL WORKS NOVEMBER 2016 EW/7 A B C D Security Booth (Cont'd) #4 bars In stirrups and the like #3 bars Sawn formwork to: Sides of soffits of beams Sides of beamfilling average 10" high cut and fitted between 2" x 6" rafters at 2'0" centres Blockwork Walls Hollow concrete blockwork 1000 psi laid in 1:3 cement mortar In walls E 6" thick 20 Lbs.

40 Lbs.
40 Lbs.

7 14 SY LY 15 SY Concrete filling (2000 psi at 28 days) to single core of blockwork reinforced with 1No.
½" dia ht bar F 6" thick walls 58 LY "Durowall" or similar horizontal mild steel ladder reinforcement laid in 6" thick walls Concrete 3000 psi at 28 days in lintel beams Reinforcement in ditto Sawn formwork to sides and soffit of ditto Form concrete sills 10" x 4" once checked, bevelled and grooved on underside, include rebar and formwork Timber Roof Note: All timber in this section to be treated pitch pine 2" x 8" hips 2" x 6" rafters T111 plywood sheeting ½" thick 1" x 3" battens 1" x 12" fascia G H I J K L M N O P 19 ½ 40 4 3 30 60 88 48 32 LY CY Lbs.
SY LY LF LF SF LF LF To Collection $ ST. MARY'S SECONDARY SCHOOL EXTERNAL WORKS NOVEMBER 2016 EW/8 Security Booth (Cont'd) PVF2 metal roof sheeting 24 gauge screw fixed to battens at 3'0" centres Ditto hip capping Ditto in apex flashing 16" square fixed to sheeting, include for sealing with non-setting sealant Foam filler strip at eave 88 30 1 276 SF LF No.
LF Allow a provisional sum for metal connectors PROV SUM 100.00 A B C D E Windows Refer to Drawing DA1 Supply and fix the following, include for 8.28mm thick laminated grey tinted glass (3mm glass/ 2.28mm pvb/3mm glass) White aluminium horizontal sliding windows F Type 1 Doors Refer to Drawing DA1 Aluminium door with alumium frames G Type D1 Ironmongery Supply, fit and fix the following: Stainless steel hinges Alumium lever locks, (Note: allow for master and sub-master keying Weather saddle screwed to concrete 3'0" long Sundries H I J K L 3 No.
1 3 1 1 No.

No.

No.

No.
Caulk around frames with non-setting sealant 20 LY Floor Finishes 12" x 12" Porcelain floor tiles fixed with adhesive and grouted with acid resistant grout 3 SY To Collection $ ST. MARY'S SECONDARY SCHOOL EXTERNAL WORKS NOVEMBER 2016 EW/9 Security Booth (Cont'd) Skirtings A 1" x 6" wpp skirting once bevelled, plugged to blockwork 18 LF Prepare and paint 1 coat primer and 2 coats gloss oil paint on: B Skirtings girth 6" to 9" 6 LY Wall Finishes In-situ Finishes (Internal & External) Cement/sand render (1:4) 1/2" thick in one coat finished smooth on: C Concrete/block walls 41 SY Decoration Prepare and paint 1 coat concrete primer and 2 coats emulsion paint on: Cement/sand render walls 41 SY Ceiling Finishes Timber ceilings Builders Work in Connection with Services All Provisional Electrical Installation Cut and pin the following to blockwork or concrete and afterwards make good Distribution panel Power outlets Telephone/computer points Lighting points Switch points 10 SY 1 2 1 2 1 No.
No.

No.

No.

No.

D E F G H I J To Collection $ ST. MARY'S SECONDARY SCHOOL EXTERNAL WORKS NOVEMBER 2016 EW/10 Security Booth (Cont'd) Collection Amount of Page No.

EW/6 Amount of Page No.

EW/7 Amount of Page No.

EW/8 Amount of Page No.

EW/9 Amount of Page No.

EW/10 Amount of Security Booth To External Works Summary $ ST. MARY'S SECONDARY SCHOOL EXTERNAL WORKS NOVEMBER 2016 EW/11 EXTERNAL WORKS SUMMARY Amount of Roads, Car Park and Concrete Paving from Page No.
EW/1 Amount of Surface Water Drainage from Page No.

EW/2 Amount of Soil and Waste Drainage from Page No.

EW/4 Amount of Builders Work in Connection with Services from Page No.

EW/5 Amount of Security Booth from Page No.


EW/11 Amount of External Works To Tender Summary $ ST. MARY'S SECONDARY SCHOOL EXTERNAL WORKS NOVEMBER 2016 EW/12 MEP INSTALLATION NOTE: This section of the Bills of Quantities has been prepared by the M&E Consultant and has not been measured in accordance with the Standard Method of Measurement of Building Works Fifth Edition Imperial.
Tenderers are to price this section in accordance with the Specifications and Drawings issued with the tender documents and must complete the enclosed Summary of Prices.

The total cost of the MEP Installation is to be carried to the Tender Summary.

The quantities in this section are indicative and tenderers must use their own quantities.

The items describe the works for all of the proposed redevelopment of the school and tenderers must only price the work applicable to Blocks A, B and External Works.
ST. MARY'S SECONDARY SCHOOL BILL OF MATERIALS - MEP INSTALLATION SERVICES DOCUMENT NO.

: 1207-2-GE-10-009-1 MECHANICAL INSTALLATIONS - MEASURED WORKS PROJECT: BEP II (ANTGUA) - ST. MARY'S SECONDARY SCHOOL DOC.

NO.

: 1207-2-GE-10-009-1 DATE: 21-SEP-2016 REVISION NO.

: A DOC.

TITLE: BILL OF MATERIALS - MECHANICAL INSTALLATIONS (MEASURED WORKS) Item Description Qty Unit Rate Amount $ .
c Supply, Installation, Testing and Commisioning (SITC) of Ventilation Equipment from the list of approved makes given in the technical spec For detail technical specification, Voltage available on Site : 400/230, 3-ph and 230V, 1-ph.

1.0 Exhaust Hood 1.1 Type 1 wall mounted exhaust canopy with UL 300 Fire suppression system, minimum exhaust rate of 750 CFM.

1.2 SITC of Ducting Work 24 Gauge metal Ducting & Insulation Supply fabrication and installation of G.I.
ducting , as per enclosed specification 1.3 SITC of Exhaust Ait Grilles without VCD Exhaust air diffuser in Aluminum extruded, powder coated construction.

2.0 SITC of Compressor / Condensor Unit 2.1 12 Ton Unit 2.2 4 Ton Unit 3.0 SITC of Evaporator Units 3.1 2 Ton Unit 3.2 1 Ton Unit 4.0 Condensate Valve Hepvo Valve 5.0 SITC of Air Conditioning Associated Air Conditioning Associated piping & Insulation 6.0 PRELIMINARIES To include mobilistaion etc.
4 4 4 1 1 7 1 8 1 1 Nr Nr Nr Nr Nr Nr Nr Nr Lot Lot To Collection MS/1 PROJECT: BEP II (ANTGUA) - ST. MARY'S SECONDARY SCHOOL DOC.

NO.

: 1207-2-GE-10-009-1 DATE: 21-SEP-2016 REVISION NO.

: A DOC.

TITLE: BILL OF MATERIALS - MECHANICAL INSTALLATIONS (MEASURED WORKS) Item Description Qty Unit Rate Amount $ .

c SUMMARY Measured Work Page Nr MS/1 TOTAL - MECHANICAL INSTALLATIONS MS/2 ELECTRICAL INSTALLATIONS - MEASURED WORKS PROJECT: BEP II (ANTGUA) - ST. MARY'S SECONDARY SCHOOL DATE: 21-SEP-2016 DOC.

NO.
NO.

: 1207-2-GE-10-009-1 REVISION NO.

: A DOC.

TITLE: BILL OF MATERIALS - ELECTRICAL INSTALLATIONS Item Description Qty (MEASURED WORKS) Rate Unit Amount POWER DISTRIBUTION A TR-1, 400Y208-120V, 3-phase, 30kVA, Dry-Type Ventilated, ES Shielded 1 Nr $ .

c B SITC Panel Boards (See panel schedule 1207-2-EL-SH- 60 (Sheets 1 to 10) MEM or equivalent to BS SPEC.
All panels are to be complete with feeder breakers as detailed in panel schedules B1 Main Distribution MDP-1; 400/230, 3-ph, 300A 12Way, TP B2 Emergency Load Centre MDP-E; 230V, 1-ph, 100A 12Way, SP B3 3-PH, 400/230V Distribution Panels P230-A1; 32W, SP P230-B1; 24W, SP P230-C2; 24W, SP B4 3-PH, 208/120V Distribution panels P120-A1/C2; 12Way SP B5 1-PH, 12W-SP, 230V Distribution Panels LP-A1/B1 -12W,SP LP-C1/C2 - 24W,SP C. RECEPTACLES (complete with wall boxes) All switches and receptacles to be flush in wall C1 230V duplex wall receptacle with face plate C2 230V duplex wall receptacle weather proof C3 230V GFCI duplex wall receptacle with face plate C4 120V duplex wall receptacle with face plate SWITCHES (complete with wall boxes) D All switches and receptacles to be flush in wall D1 20A, 230V, 1-way switch; with face plate D2 20A, 230V, 3-way switch; with face plate D3 Occupancy Sensor (ceiling/surface mount) 230V operation D4 External Photocell (230V) 1 1 1 1 1 2 2 2 88 4 20 61 44 6 34 3 Nr Nr Nr Nr Nr Nr Nr.
Nr.

Nr Nr Nr Nr Nr Nr Nr Nr To Collection ES/1 PROJECT: BEP II (ANTGUA) - ST. MARY'S SECONDARY SCHOOL DATE: 21-SEP-2016 DOC.

NO.

: 1207-2-GE-10-009-1 REVISION NO.

: A DOC.

TITLE: BILL OF MATERIALS - ELECTRICAL INSTALLATIONS Item Description Qty (MEASURED WORKS) Rate Unit Amount $ .

c Grounding A Grounding system including all fittings, 1-1/2"x1.8m copper bond ground rod PVC coated ground cable and and clampsas per Dwg.

1207-2-EL-GN-50.
1207-2-EL-GN-50.

1 Lot B SITC Lightning Protection 10M-70mm stranded copper cable (PVC coated) grounding cables, 1-Air Terminal Rod, 1-1/2"x1.8m copper bonded ground rod clamps clips etc.
1 Lot C CONDUITS, DUCTS, CABLE TRAYS AND ANCILLIARIES INCLUSIVE OF NECESSARY FITTINGS AND ACCESSORIES Medium Gauge PVC Conduit/Ducts C1 PVC conduit 20mm C2 PVC conduit 25mm C3 PVC conduit 32mm C4 PVC conduit 50mm C5 PVC conduit 100mm C6 PVC 90 deg long radius bends 20mm C7 PVC 90 deg long radius bends 25mm C8 PVC 90 deg long radius bends 32mm C9 PVC 90 deg long radius bends 50mm C10 PVC 90 deg long radius bends 100mm C11 LV/ELV pull box 900x900 D Ancilliaries D1 TVSS for LP1 Distribution Board; APC PMP1XR-B, SCCR: 25kA @ 240V.
Max.

Surge: 50kA 1 1 1 1 1 1 1 1 1 1 5 1 Lot Lot Lot Lot Lot Lot Lot Lot Lot Lot Nr Nr E Solar System with Lithium-Iron Battery Storage Provisional Sum 35,000.00 To Collection ES/2 PROJECT: BEP II (ANTGUA) - ST. MARY'S SECONDARY SCHOOL DATE: 21-SEP-2016 DOC.

NO.

: 1207-2-GE-10-009-1 REVISION NO.

: A DOC.

TITLE: BILL OF MATERIALS - ELECTRICAL INSTALLATIONS Item Description Qty (MEASURED WORKS) Rate Unit Amount $ .
c A Fire Services A1 Honeywell PEARL Fire Alarm Control Panel A2 Honeywell Notifier Short Circuit Isolator A3 Honeywell Notifier Photoelectric Smoke Detector A4 Honeywell Notifier Heat & Smoke Detector A5 Honeywell Notifier Ionization Smoke Detector A6 Honeywell Notifier Pull Station (Call Point) A7 Honeywell Notifier Wallmount Outdoor Speaker A8 Honeywell Notifier Relay Control Module A9 2-PR.
Fire resistant cable B Class F Wet Chemical Fire Extinguisher 6 litre BRITANNIA Model BFS6 Rating: 13A/75F C Smoke/Heat Detectors - self operating D Mains Cable All main cables are to have stainless steel tags at both ends of the termination and terminated with glands, 600V D1 4C-16mm sq Armoured, XLPE insulated copper D2 4C-35mm sq Armoured, XLPE insulated copper D4 4C-6mm sq Armoured, XLPE insulated copper Allow for termination kits, glands, tags and other accessories to complete the installation in price.
E LV CABLE AND WIRE Sub-Circuit wiring 1 4 32 5 5 10 3 1 1 3 2 100 35 60 Nr Nr Nr Nr Nr Nr Nr Nr Lot Nr Nr m m m E1 Single/single insulated copper conductor 2.5mm2 E2 ECC copper conductor 2.5mm2 E3 Single/single insulated copper conductor 4.0mm2 1 1 1 Lot Lot Lot To Collection $ ES/3 PROJECT: BEP II (ANTGUA) - ST. MARY'S SECONDARY SCHOOL DATE: 21-SEP-2016 DOC.

NO.

: 1207-2-GE-10-009-1 REVISION NO.

: A DOC.


TITLE: BILL OF MATERIALS - ELECTRICAL INSTALLATIONS Item Description Qty A STIC for LIGHTING All fixtures are to have LED equivalent lamps or as otherwise described.

See Lighting Schedule (MEASURED WORKS) Rate Unit Amount $ .

c Equivalent luminaries are to be used if those specified are not obtainable, but must first be approved by the Engineer.

Lighting Fixtures A1 G1.

LSI Industries LPASC24-LED-HO-CW A2 G2.


LSI Industries SDL-4-LED-VHO-CW A3 A4 A5 G3A.

Cooper FailSafe Vandal Resistant CFL_UCUW 15"- 2Lamp-32W-CT-277V G3B.

Wallmount Cooper FailSafe Vandal Resistant CFL_TR11 11"-2Lamp-57W-CT-120V G4.

Surface Cooper Corelite Class R2 Lensed 2x4-2Lamp- 28W-T5-UNV A6 G5.

Eaton's Cooper Lighting, NFFLD A7 G6.
Selux Corporation, SDS-1-F26-R3-xx-P1-xx-xx- B Public Address System; as per design Drawings and Specification; 1207-2-EL-PA-01/02 C CCTV Security System; cameras, NAS, Monitor Screes as per design drawing 1207-2-EL-SE-01/02 D Structured Data Cabling CAT6 c/w GB switches and system racks to satisfy the requirements for a local data network E Extinguishant System to serve three hoods in Home Management class room and one Hood in the Kitchen See drawing 1207-2-EL-FA-20/50 F Provide Power to the following Mechanical Equipment Air Handlers F CONTINGENCY SUM 22 20 34 63 250 7 18 1 1 1 2 Nr Nr Nr Nr Nr Nr Nr Lot Lot Lot Nr Include the provisional sum to be expended as instructed by the engineer 30,000.00 To Collection $ ES/4 PROJECT: BEP II (ANTGUA) - ST. MARY'S SECONDARY SCHOOL DATE: 21-SEP-2016 DOC.
NO.

: 1207-2-GE-10-009-1 REVISION NO.

: A DOC.

TITLE: BILL OF MATERIALS - ELECTRICAL INSTALLATIONS Item Description Qty COlLLECTION Page Nr ES/1 Page Nr ES/2 Page Nr ES/3 Page Nr ES/4 (MEASURED WORKS) Rate Unit Amount $ .

c ELECTRICAL INSALLATIONS - MEASURED WORK To Summary ES/5 PLUMBING INSTALLATIONS - MEASURED WORKS PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.

NO.

: 1207-2-GE-10-009-1 DOC.


TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .


c RAINWATER INSTALLATIONS PVC-U Class B pipe and fittings to BS 3505:1986 with solvent cement joints A Rainwater downpipe 80mm diameter and fix to blockwork with holderbats (measured separately) B Extra for bend on pipe 80mm diameter 60 3 m Nr Pipe Supports C Purpose-made galvanised mild steel holderbat 50mm x 6mm thick for pipe 80mm diameter with spacing 2.5m tail 150mm long built into concrete 30 Nr To Collection $ MPM/1 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.
NO.

: 1207-2-GE-10-009-1 DOC.

TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .

c RAINWATER INSTALLATIONS (Cont'd) Drains A Side wall Roof Drain B Rain water Flush Diverter Protection 3 3 Nr Nr D Protect all work in this Section Item To Collection $ MPM/2 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.

NO.

: 1207-2-GE-10-009-1 DOC.


TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .
c SANITARY INSTALLATIONS (SUPPLY AND Sanitary Appliances as "Zurn" or other equal and approved A White vitreous china washbasin "Wentworth" Ref 120114E size 590mm x with 1Nr tap hole, Zurn mechanical Water (70197Q4) 1 1/4" metal bottle trap with 75mm seal, one chromium plated slotted waste 50mm diameter, chromium plated water supply connector and control valve 12mm diameter and fix to blockwork B Water Closet White vitreous china, Zurn high efficiency, dual flush 1 .6 gpf [6 Lpf] - 1 .0 gpf [3 .78 Lpf], pressure-assisted tank, high performance EcoFlush technology, easy touch handle actuation, ultra quiet flush, siphon jet flush action, ADA height, 2-1/8" fully glazed trapway, operating pressure range 20-125 psi, elongated front rim, chrome-plated handle, large water surface area, bolt caps, floor-mounted toilet .
C Water Closet with Conceal Flush Valve White vitreous china, Zurn 1 .6 gpf high efficiency, ADA floor-mounted, model Z5667- BWL bottom outlet toilet with siphon jet flushing action, elongated front rim, 2-1/8" fully glazed trapway, and 1-1/2" back spud with Concealed, quiet dia- phragm-type, rough brass flushometer valve with Zurn AquaVantage® TPE, chlo-ramine resistant, dual seal diaphragm with a clog resis- tant, triple filtered by-pass .
Model Z6140AV- Urinal D White vitreous china wall-hung urinal "Sanura" comprising top inlet spreader, 1 1/2" plastic domed waste, 1 1/2" plastic bottle trap with 75mm seal, concealed hangers, MURA 9L exposed V/C cistern complete with auto fittings, petcock and support and stainless steel flush pipe MPM/3 14 Nr 6 Nr 8 Nr 2 Nr To Collection $ PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.

NO.

: 1207-2-GE-10-009-1 DOC.


TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .

c Sanitary Installations (Cont'd) Sanitary Appliances as "Zurn" or other equal and approved (Cont'd) Urinal A Washware Essentials Ltd Floor recessed slab manufactured from 1.2mm thick stainless steel satin finsh, 2100mm L x 340 W. Polished flat end panels suitable for wall fixing and is design to be recessed into floor.
Waste Outlet left 38mm BSP dome grateed waste fitting.

Vandal resistant square horizontal sparge pipe system.

End panels suitable for butting to side Back entry connection with a concealed cistern downpipe.

Janitor Sink B White firecaly cleaner's sink "Belfast" Ref 3500868 size 610mm x 455mm x 225mm Ref 7931 VEO aluminium alloy build-in Ref 7930FVE le MW and bearers, 2Nr Ref 6610400 Nimbus 12mm inclined bib tap, Ref 70668 MB 38mm slotted waste, chain and plug, screw stay and fix to concrete or blockwork.
C "Bobrick" satin finished stainless steel surface mounted vandal proof liquid soap dispenser with concealed wall fastener and fix D White vitreous china semi-recessed toilet roll holder "Mayfair" Ref 2053100 size 150mm x 150mm and fix in blockwork Kitchen Sink E Stainless steel kitchen sink 550mm x 825mm with double bowl and double drainer with 2Nr 2Nr chromium plated pillar taps 12mm diameter, overflow, stopper chain and stay, waste outlet 38mm diameter and fix in worktop chain and stay, waste outlet 38mm MPM/4 1 Nr 2 Nr 12 Nr 14 Nr 4 Nr To Collection $ PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.
NO.

: 1207-2-GE-10-009-1 DOC.

TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .
c Sanitary Installations (Cont'd) Ancillaries A Floor drain with 50mm diameter outlet similar to ANCON or other equal and approved with square satin nickel strainer and fix in reinforced concrete bed and make good PVC-U Class B pipe and fittings to BS 3505:1986 with solvent cement joints B Overflow pipe 12mm diameter and fix to blockwork or concrete with fixing clips C Waste and vent pipe 38mm diameter and fix to to concrete or blockwork with fixing clips D Ditto 50mm diameter E Ditto 110mm diameter and fix to concrete or blockwork with holderbats (measured separately) F Connection of PVC overflow 12mm diameter to fitting including union nut, back nut and washer G Form joint to WC outlet with PVC pipe 110mm diameter including rubber adaptor 7 Nr 1 1 1 lot lot lot 1 lot 6 6 Nr Nr To Collection $ MPM/5 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.
NO.

: 1207-2-GE-10-009-1 DOC.

TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .
c Sanitary Installations (Cont'd) Extra over PVC Class B pipe for:- A Splay cut end to overflow pipe 12mm diameter B Bend 12mm diameter C Bend 38mm diameter D Bend 50mm diameter E Bend 110mm diameter F Sanitary tee 38mm diameter G Sanitary tee 50mm diameter H Ditto 110mm diameter I Ditto 150mm diameter J Wye 38mm diameter K Ditto 50mm diameter L Ditto 110mm diameter M Cleanout plug and adaptor 38mm diameter N Cleanout plug and adaptor 50 mm diameter O Cleanout plug and adaptor 110 mm diameter 1 1 1 1 1 1 1 1 1 1 1 1 1 1 1 lot lot lot lot lot lot lot lot lot lot lot lot lot lot lot To Collection $ MPM/6 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.
NO.

: 1207-2-GE-10-009-1 DOC.

TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .

c Sanitary Installations (Cont'd) PVC trap to BS 3943 with and including PVC iron adaptor with one screwed joint to iron and two solvent welded joints A PVC "P" trap 38mm diameter with 75mm seal and cleanout plug.
B Ditto 50mm diameter (floor drain) Pipe Supports C Purpose-made galvanised mild steel holderbat 50mm x 6mm thick for pipe 110mm diameter with tail 150mm long built into blockwork 14 7 Nr Nr 1 Lot To Collection $ MPM/7 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.

NO.

: 1207-2-GE-10-009-1 DOC.

TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .


c School Lab Installation A Laboratory grade single sinks B Airone 1000R filtration fume cabinet C Bench Top 2-way Gas cocks set at 90 degree.

D Vacuum Break Faucets E pHpro Chemical Drainage System Neutralizing Tank Model:T6 with Lightweight PE Resin, Inground Gasketted & Bolted Cover & wide range of Monitoring Accessories.

22 1 21 22 Nr Nr Nr 1 Nr To Collection $ MPM/8 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.

NO.

: 1207-2-GE-10-009-1 DOC.


TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .
c Gas piping Installation Black pipe sch40 grade B ASTM A53 or A106 with mallrable butt-well fitting A Service pipe 12mm diameter and fix to blockwork or concrete with fixing clips B Ditto 20mm diameter Extra over Black pipe for:- C Bend 12mm diameter D Bend 20mm diameter E Reducer 12mm diameter F Reducer 20mm diameter G tee 12mm diameter H Ditto 20mm diameter 1 1 1 1 1 1 1 1 lot lot lot lot lot lot lot lot lot To Collection $ MPM/9 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.

NO.
NO.

: 1207-2-GE-10-009-1 DOC.

TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .


c Gas piping Installation (Cont'd) , 20mm NPT California Seismic Product, Model 300 Twin Cylinder Automatic Changeover Regulator with 2 x 500mm pigtails with non return valve 2 2 Nr Nr A B C Copper Pigtail with pol end fitting, silver Soldered to 5mm diameter copper tube and 7/16" unf male flare or as required for Appliance 4 Nr To Collection $ MPM/10 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.

NO.

: 1207-2-GE-10-009-1 DOC.


TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .


c Pump Systems - Supply and Install A Inline Vertical Close Coupled Pump 1HP, 60gpm @ 40 psi 1 Lot B Simplex Elevator Sump Pump; submersible with ss construction, 1/3HP, 3/8" spherical solids handling, built in overload protection, integral float switch, 2" discharge, Min 10' head and control panel 1 Lot To Collection $ MPM/11 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.

NO.

: 1207-2-GE-10-009-1 DOC.


TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .
c Cold Water Installation PVC-U Class D pipe and fittings to BS 3505:1986 with solvent cement joints A Service pipe 12mm diameter and fix to blockwork or concrete with fixing clips B Ditto 20mm diameter C Ditto 25mm diameter D Ditto 40mm diameter E Ditto 50mm diameter Extra over PVC pipe Class D for:- F Bend 12mm diameter G Bend 20mm diameter H Bend 25mm diameter I Bend 40mm diameter J Bend 50mm diameter K Reducer 12mm diameter L Reducer 25mm diameter M tee 15mm diameter N Ditto 20mm diameter O Ditto 25mm diameter P Ditto 40mm diameter N Ditto 50mm diameter 1 1 1 1 1 1 1 1 1 1 1 1 1 1 1 1 1 lot lot lot lot lot lot lot lot lot lot lot lot lot lot lot lot lot lot To Collection $ MPM/12 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.
NO.

: 1207-2-GE-10-009-1 DOC.

TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .
c Cold Water Installation (Cont'd) The following in CRANE or other equal and approved valves and the like with screwed ends connected to PVC with iron to PVC adaptors with screwed unions with 2Nr screwed joints and 2Nr solvent welded joints A Angle valves 12mm diameter B Metal ball valve 12mm diameter C Metal ball valve 20mm diameter D Metal ball valve 25mm diameter E Check valve 25mm diameter F Metal ball valve 40 mm diameter G Float valve 40mm diameter 51 5 5 2 2 1 2 Nr Nr Nr Nr Nr Nr Nr To Collection $ MPM/13 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.
NO.

: 1207-2-GE-10-009-1 DOC.

TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .
c Hot Water Installation A Fix only Solar Water Water - Solaris 60 Gallon integral Tank and two solar collector 2 Nr CPVC pipe and fittings to BS3505:1986 with solvent cement joints B Service pipe 12mm diameter and fix to blockwork or concrete with fixing clips C Ditto 20mm diameter Extra over CPVC pipe Class D for:- D Bend 12mm diameter E Ditto 20mm diameter F tee 12mm diameter G Ditto 20mm diameter Grease Interceptor H ZURN Z1172 Large capacity Acid Resistant Coated interior and exterior fabricated steel grease interceptor, rated at 250 GPM and 500 Lbs.
Grease capacity, with internal air relief by-pass, bronze cleanout plug and visible double wall trap seal with removable pressure equalizing/flow diffusing baffle.

Gasketed non-skid secured cover with removable lift handles, complete with flow control fitting.

1 1 1 1 1 1 Lot lot lot lot lot lot 2 Nr To Collection $ MPM/14 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.

NO.

: 1207-2-GE-10-009-1 DOC.


TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .
c Marking Positions A Allow for marking the position of chases and the like in the structure for the plumbing and engineering installations 1 lot Testing the Installations B Allow for testing and flushing the sanitary, cold water installation to the satisfaction of the Architect and the relevant Statutory Authority 1 lot BUILDER'S WORK C Septic Tank Construction: 6230mm x 2080mm X 1650 deep (internal dimension) two part compartment tank, 153MM thick bace, 3 concrete access cover with plug and 2 vent 1 Nr D Excavate trench for pipe 50mm and 100 mm starting at pump room level for an average depth of 750mm including grading and compacting bottom, planking and strutting, backfilling and disposal of surplus spoil from site E Cut or form hole for small pipe through reinforced concrete slab 150mm thick and make good F Cut or form mortice 75mm deep in reinforced concrete slab for floor drain with outlet 50mm diameter and make good G CONTINGENCY SUM Include the Provisional Sum to be expended as instructed by the Engineer 1 1 6 lot lot Nr To Collection $ $ 20,000.00 MPM/15 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.
NO.

: 1207-2-GE-10-009-1 DOC.

TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .

c MEASURED WORK COLLECTION Page Nr.

MPM/1 Page Nr.

MPM/2 Page Nr.

MPM/3 Page Nr.

MPM/4 Page Nr.

MPM/5 Page Nr.

MPM/6 Page Nr.

MPM/7 Page Nr.

MPM/8 Page Nr.

MPM/9 Page Nr.

MPM/10 Page Nr.

MPM/11 Page Nr.

MPM/12 Page Nr.

MPM/13 Page Nr.

MPM/14 Page Nr.


MPM/15 TOTAL MEASURED WORK $ MPM/16 PROJECT: BEP II (ANTGUA) ST. MARY'S SECONDARY SCHOOL DOC.

NO.

: 1207-2-GE-10-009-1 DOC.

TITLE: BILL OF MATERIALS - PLUMBING INSTALLATIONS Item Description Qty DATE: 21-SEP-2016 REVISION NO.

: A Unit Rate Amount $ .

c SUMMARY Preliminaries brought forward Measured Work MPM/16 TOTAL - PLUMBING AND SUPPLY & INSTALLATION $ MPS/1 MEP INSTALLATIONS - SUMMARY PROJECT: BEP II (ANTGUA) - ST. MARY'S SECONDARY SCHOOL DOC.

NO.
NO.

: 1200-1-GE-10-009-1 DATE: 21-SEP-2016 REVISION NO.

: A DOC.

TITLE: BILL OF MATERIALS - MEP INSTALLATIONS SUMMARY Amount $ .

c SUMMARY Preliminaries Measured Work - Mechanical Measured Work - Electrical Measured Work - Plumbing Page Nr MPS/1 ES/5 MS/2 TOTAL - MEP INSTALLATIONS MEP/1 DAYWORKS DAYWORKS DAYWORKS A B Where work arising under a variation ordered by the Architect cannot properly be measured and valued, the Sub-contractor shall be paid on a daywork basis.
Such payments shall be the sum of the prime cost of such work calculated in accordance with the following 'Definitions of Prime Cost of Daywork' and in the percentage additions to each section of the prime cost of the rates set out hereunder by the Contractor.
DEFINITION OF PRIME COST OF DAYWORK This definition applies to daywork carried out under or incidental to this building contract but does not cover daywork ordered by the Architect to be carried out after the date of commencement of the Defects Liability Period, which may be the subject of a separate agreement.
SECTION (1) - LABOUR C 1.1 The standard wage rates, emoluments and expenses referred to below and the standard working hours referred to in 1.2 are those laid down for the time being in the rules or decisions of agreements of the Barbados Workers Union and the Sub-contractor, applicable to the works (or those of such other body as may be appropriate) and to the grade of operative concerned at the time when and the area where the daywork is executed.
D 1.2 Hourly base rates for labour are computed by dividing the annual prime cost of labour based upon the standard working hours and as defined in 1.4 by the number of standard working hours per annum.
E 1.3 The hourly rates computed in accordance with 1.2 shall be applied in respect of the time spent by operatives directly engaged on daywork, including those operating mechanical plant and transport and erecting and dismantling other plant (unless otherwise expressly provided in the contract) and handling and distributing the materials and goods used in the daywork.

F 1.4 The annual prime cost of labour comprises the following: (a) Standard weekly earnings (ie.
the standard working week as determined at the appropriate rate for the operative concerned).

(b) Any supplemental payments.

(c) Any guaranteed minimum payments (unless included in Section 3.1 (a) - (p)).

(d) Merit money.

(e) Differentials or extra payments in respect of skill, responsibility, discomfort, inconvenience or rish (excluding those in respect of supervisory responsibility - see 1.5).

(f) Payments in respect of public holidays.


(g) Any amounts which may become payable by the contractor to or in respect of operatives arising from the rules etc., referred to in 1.1 which are not provided for in 1.4 (a) - (f) nor in Section 3.1 (a) - (p).

(h) Employer's contributions to the Annual Holiday with Pay and Welfare Benefits Scheme or payments in lieu thereof.

(i) Employer's National Insurance contributions as applicable to 1.4 (h).
(j) Any contribution, levy or tax imposed by Statute, payable by the contractor in his capacity as an employer.

DW1 DAYWORKS (Cont'd) A 1.5 Differentials or extra payments in respect of supervisory responsibility are excluded from the annual prime cost.

The time of principals, staff, foremen, charge hands and the like when working manually is admissible under this Section at the rates for the appropriate grades.
SECTION (2) - MATERIALS B 2.1 The prime cost of materials and goods obtained specifically for the daywork is the invoice cost after deducting all trade discounts and any portion of cash discounts in excess of 5 per cent.

C D 2.2 The prime cost of all other materials and goods used in the daywork is based upon the current market prices plus any appropriate handling charges.

2.3 The prime cost referred to in 2.1 and 2.2 includes the cost of delivery to site.
SECTION (3) - PLANT E 3.1 Unless otherwise stated in the contract, the prime cost of plant comprises the cost of the following: (a) use or hire of mechanically operated plant and transport for the time employed on and/or provided or retained for the daywork; (b) use of non-mechanical plant (excluding non-mechanical hand tools) for the time employed on and/or provided or retained for the daywork: (c) transport to and from site and erection and dismantling where applicable.
F 3.2 The use of non-mechanical hand tools and of erected scaffolding, staging, trestles or the like is excluded (see Section 6), unless specifically retained for the daywork.

SECTION (4) - OVERHEADS G Overheads for the purpose of this contract shall mean the following: (1) (2) (3) (4) (5) Head Office charges Site supervision Overtime other than that allowed under Section (1)(4) Time lost due to inclement weather Bonuses and all other incentive payments.
DW2 DAYWORKS Cont'd) (6) Apprentices' study leave (7 (8) (9) Employer's contribution to National Insurance including graduated pensions Contributions for annual and public holidays Fares and time allowances for traveling (10) Subsistence and periodic leave allowances (11) Safety and welfare facilities (12) Third party and employer's liability insurances (13) Sick pay or insurance in respect thereof (14) Tool allowances.
(15) Use, repair and sharpening of small tools (16) All non mechanically operated plant, erected scaffolding and staging and trestles, protective clothing, artificial lighting, storage facilities and the like that may be in general use on the site (17) All other liabilities and obligations whatsoever.

A Overheads as defined above and profit shall be dealt with by means of percentage addition to the totals of Prime Cost in each of the aforementioned sections (1), (2) and (3) at the rates stated hereafter.
DW3 A B C D E F DAYWORKS (Cont'd) LABOUR Include the Provisional Sum of for Daywork labour Allow for percentage addition on Prime Cost of labour for Profit & Overheads % MATERIALS Include the Provisional Sum of for Daywork materials Allow for percentage addition on Prime Cost of materials for Profit & Overheads % $ 4,000.00 $ 2,000.00 PLANT Include the Provisional Sum of for Daywork plant Allow for percentage addition on Prime Cost of plant for Profit & Overheads $ 1,000.00 % TO TENDER SUMMARY $ ----------------- ----------------- DW/4 Daywork Schedule A B C D For works to be executed on a daywork basis and instructions, the Contractor shall insert a rate against the items mentioned below on which the tender is based on.
Rates for plant under “A” below shall include fuel, oil and all consumable items but shall exclude wages of operator, workmen, loaders or watching.

Payment shall be made for “working time” and “movement time” only.

“Standing time” shall not be paid for.

Breakdowns in “working time” periods shall not be paid for.

Rates for plant under “B” below are to be inclusive of drivers, loaders, banksman etc and all items necessary.
Plant “A” Caterpillar type tractor (D4 or equal) Caterpillar type tractor (D6 or equal) Caterpillar type tractor (D7 or equal) Caterpillar type tractor (D8 or equal) Ditto but equipped to operate a bull or angle dozer Rooter 3 type heavy pattern Motor blade grader - all up weight 8 tonne Motor blade grader - all up weight 19 tonne Scraper 0.6m3 capacity Scraper 1m3 capacity Portable compressor with 3 jack hammers (or other attachments) with 20m hoses and steel Roller 2/3 tonne Roller 5/8 tonne Roller 5/10 tonne DW/5 per hour “ “ “ “ “ “ “ “ “ “ “ “ “ “ per hour “ “ “ “ “ “ “ “ “ “ Roller 10/12 tonne Dumper-self driven 3m3 Ditto 4m3 Pumps petrol driven with hoses and fittings: 50mm 75mm 100mm 150mm 2 tonne truck 2 tonne tipping truck 3 tonne truck 4 tonne truck 6 Tonne truck 7/5 closed drum concrete mixer 10/7 closed drum concrete mixer 0.3m3 excavator with face shovel, skimmer dragline or back actor equipment 0.5m3 ditto 0.6m3 ditto 0.76m3 ditto 0.95m3 ditto Mobile specify crane, please DW/6 “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ Plant “A” (cont’d) Tower specify crane, please Pneumatic drills Arch welding equipment Concrete vibrator Hoist, please specify Plant “B” Truck for transport - per ton mile (measured as single journey - i.e.
rates to be quoted are for the round trip which would be twice the kilometer listed hereunder).
0 - 1km per m3 2 - 3km per m3 3 - 4km per m3 4 - 90km per m3 10 – km per m3 15 – km per m3 20 – km per m3 Hoist and operator 3 tonne lorry and driver DW/7 per hour “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ 5 tonne lorry and driver Mechanical pump and operator Arc-welder including equipment Pneumatic earth consolidator and operator Compressor, pneumatic drills or paving breakers and operator 10S - concrete mixer and operator Mobile crane and operator Concrete vibrator and operator Tower crane and operator A Dayworks Schedule (cont’d) Labour Excavator general labour Craftsmen Craftsmen labourer Reinforcement bender Reinforcement fixer Concretor Concretor’s labourer Fitter 3 tonne lorry driver 5 tonne lorry driver Mechanical pump operator DW/8 “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ per hour “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ Arc-welder including equipment Painter Pneumatic earth consolidator operator Compressor, pneumatic drills or paving breaker operator 10S - concrete mixer operator Mobile crane operator Concrete vibrator operator Tower crane operator Blocklayer Blocklayer’s labourer Roofer Roofer’s labourer Plumber DAYWORKS (Cont’d) Drain layer Carpenter Joiner Plasterer Hoist operator “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ “ DW/9 ST. MARY'S SECONDARY SCHOOL - PHASE 2 TENDER SUMMARY SUMMARY Amount of Preliminaries from Page No.
P/25 Amount of Block A from Page No.

SA/1 Amount of Block B from Page No.

SB/1 Amount of Block C from Page No.

SC/1 Amount of External Works from Page No.

EW/12 Amount of MEP Installation from Page No.

MEP/1 Amount of Dayworks from Page No.

DW/4 Fringe Benefits (as Preliminaries) Third Party Insurance Insurance Against Fire, etc.
Contingencies Profits & Overheads (if not previously included) US$ 100,000.00 TOTAL TO FORM OF TENDER US$ ST. MARY'S SECONDARY SCHOOL TENDER SUMMARY NOVEMBER 2016 TS/1 3-1 PART 3 – Conditions of Contract and Contract Forms Section VII.

General Conditions of Contract 3-3 These General Conditions of Contract (GCC), read in conjunction with the Particular Conditions of Contract (PCC) and other documents listed therein, should be a complete document expressing fairly the rights and obligations of both parties.
These General Conditions of Contract have been developed on the basis of considerable international experience in the drafting and management of contracts, bearing in mind a trend in the construction industry towards simpler, more straightforward language.

The GCC can be used for both smaller admeasurement contracts and lump sum contracts.

3-4 Section VII – General Conditions of Contract Table of Clauses A. General………………………………………………………………………………….6 1.

Definitions…………………………………………………………...………………6 2.


Interpretation………………...………………………………………………………8 3.

Language and Law…………………………………………………………………..9 4.

Project Manager’s Decisions……………………………………………………..…9 5.

Delegation…………………………………………………………………………...9 6.

Communications…………………………………………………………………….9 7.

Subcontracting………………………………………………………………………9 8.

Other Contractors……………………………………………………………………9 9.

Personnel and Equipment……………………………………………………...…..10 10.

Employer’s and Contractor’s Risks………………………………………………..10 11.
Employer’s Risks…………………………………………………………………..10 12.

Contractor’s Risks……………………………………………………………….....11 13.

Insurance…………………………………………………………………………...11 14.

Site Data……………………………………………………………………………11 15.

Contractor to Construct the Works………………………………………………...12 16.

The Works to be Completed by the Intended Completion Date……………..……12 17.

Approval by the Project Manager………………………………………………….12 18.

Safety………………………………………………………………………………12 19.

Discoveries…………………………………………………………………………12 20.


Possession of the Site………………………………………………………………12 21.

Access to the Site…………………………………………………………………..12 22.

Instructions, Inspections and Audits………………………………………………13 23.

Appointment of the Adjudicator…………………………………………………...13 24.

Procedure for Disputes……………………………………………………….…….13 B.

Time Control……………………………………………………………………...…..14 25.

Program…………………………………………………………………………….14 26.

Extension of the Intended Completion Date……………………………………….14 27.
Acceleration………………………………………………………………..………15 28.

Delays Ordered by the Project Manager………………………………………...…15 29.

Management Meetings……………………………………………………………..15 30.

Early Warnings…………………………………………………………………….15 C. Quality Control……………………………………………………………………….16 31.

Identifying Defects………………………………………………………………...16 32.

Tests………………………………………………..………………………………16 33.

Correction of Defects………………………………………………………………16 34.
Uncorrected Defects………………………………………………………………..16 Section VII – General Conditions of Contract 3-5 D. Cost Control……………………………………………………………………….…..16 35.

Contract Price……………………………………………………………………....16 36.

Changes in the Contract Price………………………………………………………17 37.

Variations,……..........................................................................................................17 38.

Cash Flow Forecasts………………………………………………………………..18 39.

Payment Certificates………………………………………………………………..18 40.
Payments……………………………………………………………………………19 41.

Compensation Events……………………………………………………………....19 42.

Tax………………………………………………………………………………….20 43.

Currencies…………………………………………………………………………..21 44.

Price Adjustment…………………………………………………………………...21 45.

Retention……………………………………………………………………………21 46.

Liquidated Damages………………………………………………………………..22 47.

Bonus……………………………………………………………………………….22 48.

Advance Payment…………………………………………………………………..22 49.

Securities……………………………………………………………………………23 50.


Dayworks…………………………………………………………………………...23 51.

Cost of Repairs……………………………………………………………………...23 E. Finishing the Contract…………………………………………………………………23 52.

Completion…………………………………………………………………………..23 53.

Taking Over………………………………………………………..………………...23 54.

Final Account………………………………………………………………………..24 55.

Operating and Maintenance Manuals………………………………………………..24 56.

Termination…………………………………………………………………………..24 57.

Fraud and Corruption………………………………………………………...………25 58.
Payment Upon Termination………………………………………………………….26 59.

Property………………………………………………………………………………26 60.

Release from Performance………………………………………………...…………26 61.

Suspension of Bank Loan or Grant…………………………………………...……...27 62.

Eligibility…………………………………………………………………...………..27 3-6 Section VII – General Conditions of Contract General Conditions of Contract A.

General 1.

Definitions 1.1 Boldface type is used to identify defined terms.
(a) (b) (c) (d) (e) (f) (g) (h) (i) (j) (k) The Accepted Contract Amount means the amount accepted in the Letter of Acceptance for the execution and completion of the Works and the remedying of any defects.

The Activity Schedule is a schedule of the activities comprising the construction, installation, testing, and commissioning of the Works in a lump sum contract.
It includes a lump sum price for each activity, which is used for valuations and for assessing the effects of Variations and Compensation Events.

The Adjudicator is the person appointed jointly by the Employer and the Contractor to resolve disputes in the first instance, as provided for in GCC 23.

Bank means the financing institution named in the PCC.

Bill of Quantities means the priced and completed Bill of Quantities forming part of the Bid.
Compensation Events are those defined in GCC Clause 41 hereunder.

The Completion Date is the date of completion of the in Works as certified by accordance with GCC Sub-Clause 52.1. the Project Manager, The Contract is the Contract between the Employer and the Contractor to execute, complete, and maintain the Works.

It consists of the documents listed in GCC Sub- Clause 2.3 below.

The Contractor is the party whose Bid to carry out the Works has been accepted by the Employer.
The Contractor’s Bid the completed bidding is document submitted by the Contractor to the Employer.

The Contract Price is the Accepted Contract Amount stated in the Letter of Acceptance and thereafter as adjusted in accordance with the Contract.

(l) Days are calendar days; months are calendar months.
Section VII – General Conditions of Contract 3-7 (m) Dayworks are varied work inputs subject to payment on a time basis for the Contractor’s employees and Equipment, in addition to payments for associated Materials and Plant.

(n) (o) (p) (q) (r) (s) (t) (u) (v) (w) A Defect is any part of the Works not completed in accordance with the Contract.

The Defects Liability Certificate is the certificate issued by the Project Manager upon correction of defects by the Contractor.
The Defects Liability Period is the period named in the PCC pursuant to Sub-Clause 33.1 and calculated from the Completion Date.

Adjudicator means the single person appointed under Clause 23.

Drawings means the drawings of the Works, as included in the Contract, and any additional and modified drawings issued by (or on behalf of) the Employer in accordance with the Contract, include calculations and other information provided or approved by the Project Manager for the execution of the Contract.
The Employer is the party who employs the Contractor to carry out the Works, as specified in the PCC.

Equipment is the Contractor’s machinery and vehicles brought temporarily to the Site to construct the Works.

“In writing” or “written” means hand-written, type- written, printed or electronically made, and resulting in a permanent record; The Initial Contract Price is the Contract Price listed in the Employer’s Letter of Acceptance.
The Intended Completion Date is the date on which it is intended that the Contractor shall complete the Works.

The Intended Completion Date is specified in the PCC.

The Intended Completion Date may be revised only by the Project Manager by issuing an extension of time or an acceleration order.

(x) Materials are all supplies, including consumables, used by the Contractor for incorporation in the Works.
(y) Plant is any integral part of the Works that shall have a mechanical, electrical, chemical, or biological function.

3-8 Section VII – General Conditions of Contract (z) The Project Manager is the person named in the PCC (or any other competent person appointed by the Employer and notified to the Contractor, to act in replacement of the Project Manager) who is responsible the Works and the execution of for supervising administering the Contract.
(aa) PCC means Particular Conditions of Contract (bb) The Site is the area defined as such in the PCC.

(cc) the bidding documents and are Site Investigation Reports are those that were included factual and in interpretative reports about the surface and subsurface conditions at the Site.

(dd) Specification means the Specification of the Works included in the Contract and any modification or addition made or approved by the Project Manager.

(ee) The Start Date is given in the PCC.


It is the latest date when the Contractor shall commence execution of the Works.

It does not necessarily coincide with any of the Site Possession Dates.

(ff) A Subcontractor is a person or corporate body who has a Contract with the Contractor to carry out a part of the work in the Contract, which includes work on the Site.
(gg) Temporary Works are works designed, constructed, installed, and removed by the Contractor that are needed for construction or installation of the Works.

(hh) A Variation is an instruction given by the Project Manager which varies the Works.

(ii) the The Works are what Contractor to construct, install, and turn over to the Employer, as defined in the PCC.

the Contract requires In interpreting these GCC, words indicating one gender include all genders.
Words indicating the singular also include the plural and words indicating the plural also include the singular.

Headings have no significance.

Words have their normal meaning under the language of the Contract unless specifically defined.

The Project Manager shall provide instructions clarifying queries about these GCC.

2.
2.

Interpretation 2.1 2.2 If sectional completion is specified in the PCC, references in the GCC to the Works, the Completion Date, and the Intended Completion Date apply to any Section of the Works (other than Section VII – General Conditions of Contract 3-9 references to the Completion Date and Intended Completion Date for the whole of the Works).
2.3 The documents forming the Contract shall be interpreted in the following order of priority: (a) (b) (c) (d) (e) (f) (g) (h) (i) Agreement, Letter of Acceptance, Contractor’s Bid, Particular Conditions of Contract, General Conditions of Contract, Specifications, Drawings, Bill of Quantities,5 and any other document listed in the PCC as forming part of the Contract.

3.

Language and 3.1 The language of the Contract and the law governing the Law Contract are stated in the PCC.

4.
4.

Project Manager’s Decisions 5.

Delegation 4.1 Except where otherwise specifically stated, the Project Manager shall decide contractual matters between the Employer and the Contractor in the role representing the Employer.

5.1 Otherwise specified in the PCC, the Project Manager may delegate any of his duties and responsibilities to other people, except to the Adjudicator, after notifying the Contractor, and may revoke any delegation after notifying the Contractor.

6.
6.

Communica- tions 6.1 Communications between parties that are referred to in the Conditions shall be effective only when in writing.

A notice shall be effective only when it is delivered.

7.

Subcontractin g 7.1 The Contractor may subcontract with the approval of the Project Manager, but may not assign the Contract without the approval of the Employer in writing.

Subcontracting shall not alter the Contractor’s obligations.

8.
8.

Other Contractors 8.1 The Contractor shall cooperate and share the Site with other contractors, public authorities, utilities, and the Employer between the dates given in the Schedule of Other Contractors, 5 In lump sum contracts, delete “Bill of Quantities” and replace with “Activity Schedule.” 3-10 Section VII – General Conditions of Contract 9.

Personnel and Equipment 10.

Employer’s and Contractor’s Risks 11.

Employer’s Risks as referred to in the PCC.


The Contractor shall also provide facilities and services for them as described in the Schedule.

The Employer may modify the Schedule of Other Contractors, and shall notify the Contractor of any such modification.

9.1 The Contractor shall employ the key personnel and use the equipment identified in its Bid, to carry out the Works or other personnel and equipment approved by the Project Manager.
The Project Manager shall approve any proposed replacement of key personnel and equipment only their relevant qualifications or characteristics are substantially equal to or better than those proposed in the Bid.

if 9.2 If the Project Manager asks the Contractor to remove a person who is a member of the Contractor’s staff or work force, stating the reasons, the Contractor shall ensure that the person leaves the Site within seven days and has no further connection with the work in the Contract.
10.1 The Employer carries the risks which this Contract states are Employer’s risks, and the Contractor carries the risks which this Contract states are Contractor’s risks.
11.1 From the Start Date until the Defects Liability Certificate has been issued, the following are Employer’s risks: (a) The risk of personal injury, death, or loss of or damage to property (excluding the Works, Plant, Materials, and Equipment), which are due to (i) use or occupation of the Site by the Works or for the purpose of the Works, which is the unavoidable result of the Works or (ii) negligence, breach of statutory duty, or interference with any legal right by the Employer or by any person employed by or contracted to him except the Contractor.
(b) The risk of damage to the Works, Plant, Materials, and Equipment to the extent that it is due to a fault of the Employer or in the Employer’s design, or due to war or radioactive contamination directly affecting the country where the Works are to be executed.
11.2 From the Completion Date until the Defects Liability Certificate has been issued, the risk of loss of or damage to the Works, Plant, and Materials is an Employer’s risk except loss or Section VII – General Conditions of Contract 3-11 damage due to (a) a Defect which existed on the Completion Date, (b) an event occurring before the Completion Date, which was not itself an Employer’s risk, or (c) the activities of the Contractor on the Site after the Completion Date.

12.
12.

Contractor’s 12.1 From the Starting Date until the Defects Liability Certificate Risks 13.

Insurance has been issued, the risks of personal injury, death, and loss of or damage to property (including, without limitation, the Works, Plant, Materials, and Equipment) which are not Employer’s risks are Contractor’s risks.
13.1 The Contractor shall provide, in the joint names of the Employer and the Contractor, insurance cover from the Start Date to the end of the Defects Liability Period, in the amounts and deductibles stated in the PCC for the following events which are due to the Contractor’s risks: (a) loss of or damage to the Works, Plant, and Materials; (b) loss of or damage to Equipment; (c) loss of or damage to property (except the Works, Plant, Materials, and Equipment) the Contract; and in connection with (d) personal injury or death.
13.2 Policies and certificates for insurance shall be delivered by the Contractor to the Project Manager for the Project Manager’s approval before the Start Date.

All such insurance shall provide for compensation to be payable in the types and proportions of currencies required to rectify the loss or damage incurred.
13.3 If the Contractor does not provide any of the policies and certificates required, the Employer may effect the insurance which the Contractor should have provided and recover the premiums the Employer has paid from payments otherwise due to the Contractor or, if no payment is due, the payment of the premiums shall be a debt due.

13.4 Alterations to the terms of an insurance shall not be made without the approval of the Project Manager.
13.5 Both parties shall comply with any conditions of the insurance 3-12 Section VII – General Conditions of Contract policies.

14.

Site Data 14.1 The Contractor shall be deemed to have examined any Site Data referred to in the PCC, supplemented by any information available to the Contractor.

15.

Contractor to Construct the Works 16.

The Works to Be Completed by the Intended Completion Date 15.1 The Contractor shall construct and install the Works in accordance with the Specifications and Drawings.
16.1 The Contractor may commence execution of the Works on the Start Date and shall carry out the Works in accordance with the Program submitted by the Contractor, as updated with the approval of the Project Manager, and complete them by the Intended Completion Date.

17.

Approval by the Project Manager 17.1 The Contractor shall submit Specifications and Drawings showing the proposed Temporary Works to the Project Manager, for his approval.
17.2 The Contractor shall be responsible for design of Temporary Works.

17.3 The Project Manager’s approval shall not alter the Contractor’s responsibility for design of the Temporary Works.

17.4 The Contractor shall obtain approval of third parties to the design of the Temporary Works, where required.

17.5 All Drawings prepared by the Contractor for the execution of the temporary or permanent Works, are subject to prior approval by the Project Manager before this use.

18.
18.

Safety 18.1 The Contractor shall be responsible for the safety of all activities on the Site.

19.

Discoveries 20.

Possession of the Site 19.1 Anything of historical or other interest or of significant value unexpectedly discovered on the Site shall be the property of the Employer.

The Contractor shall notify the Project Manager of such discoveries and carry out the Project Manager’s instructions for dealing with them.
20.1 The Employer shall give possession of all parts of the Site to the Contractor.

If possession of a part is not given by the date stated in the PCC, the Employer shall be deemed to have delayed the start of the relevant activities, and this shall be a Compensation Event.

21.
21.

Access to the 21.1 The Contractor shall allow the Project Manager and any person Section VII – General Conditions of Contract 3-13 Site authorized by the Project Manager access to the Site and to any place where work in connection with the Contract is being carried out or is intended to be carried out.

22.

Instructions, Inspections and Audits 22.1 The Contractor shall carry out all instructions of the Project Manager which comply with the applicable laws where the Site is located.

23.
23.

Appointment of the Adjudicator 24.

Procedure for Disputes 22.2 The Contractor shall permit the Bank to inspect the Contractor’s accounts, records and other documents relating the submission of bids and contract performance and to have them audited by auditors appointed by the Bank.

The Contractor shall maintain all documents and records related to the Contract for a period of three (3) years after completion of the Works.
The Contractor shall provide any documents necessary for the investigation of allegations of fraud, collusion, coercion, or corruption and require its employees or agents with knowledge of the Contract to respond to questions from the Bank.

to 23.1 The Adjudicator shall be appointed jointly by the Employer and the Contractor, at the time of the Employer’s issuance of the Letter of Acceptance.
If, in the Letter of Acceptance, the Employer does not agree on the appointment of the Adjudicator, the Employer will request the Appointing Authority designated in the PCC, to appoint the Adjudicator within 14 days of receipt of such request.

23.2 Should the Adjudicator resign or die, or should the Employer and the Contractor agree that the Adjudicator is not functioning in accordance with the provisions of the Contract, a new Adjudicator shall be jointly appointed by the Employer and the Contractor.
In case of disagreement between the Employer and the Contractor, within 30 days, the Adjudicator shall be designated by the Appointing Authority designated in the PCC at the request of either party, within 14 days of receipt of such request.
24.1 If the Contractor believes that a decision taken by the Project Manager was either outside the authority given to the Project Manager by the Contract or that the decision was wrongly taken, the decision shall be referred to the Adjudicator within 14 days of the notification of the Project Manager’s decision.

24.2 The Adjudicator shall give a decision in writing within 28 days of receipt of a notification of a dispute.
24.3 The Adjudicator shall be paid by the hour at the rate specified in the PCC, together with reimbursable expenses of the types 3-14 Section VII – General Conditions of Contract specified in the PCC, and the cost shall be divided equally between the Employer and the Contractor, whatever decision is reached by the Adjudicator.

Either party may refer a decision of the Adjudicator to an Arbitrator within 28 days of the Adjudicator’s written decision.
If neither party refers the dispute the Adjudicator’s decision shall be final and binding.

the above 28 days, to arbitration within 25.

Program 24.4 The arbitration shall be conducted in accordance with the arbitration procedures published by the institution named and in the place specified in the PCC.

B.
B.

Time Control 25.1 Within the time stated in the PCC, after the date of the Letter of Acceptance, the Contractor shall submit to the Project Manager for approval a Program showing the general methods, arrangements, order, and timing for all the activities in the Works.

In the case of a lump sum contract, the activities in the Program shall be consistent with those in the Activity Schedule.
25.2 An update of the Program shall be a program showing the actual progress achieved on each activity and the effect of the progress achieved on the timing of the remaining work, including any changes to the sequence of the activities.

25.3 The Contractor shall submit to the Project Manager for approval an updated Program at intervals no longer than the period stated in the PCC.
If the Contractor does not submit an updated Program within this period, the Project Manager may withhold the amount stated in the PCC from the next payment certificate and continue to withhold this amount until the next payment after the date on which the overdue Program has been submitted.

In the case of a lump sum contract, the Contractor shall provide an updated Activity Schedule within 14 days of being instructed to by the Project Manager.
25.4 The Project Manager’s approval of the Program shall not alter the Contractor’s obligations.

The Contractor may revise the Program and submit it to the Project Manager again at any time.

A revised Program shall show the effect of Variations and Compensation Events.

26.
26.

Extension of the Intended Completion Date 26.1 The Project Manager shall extend the Intended Completion Date if a Compensation Event occurs or a Variation is issued which makes it impossible for Completion to be achieved by the Intended Completion Date without the Contractor taking steps to accelerate the remaining work, which would cause the Section VII – General Conditions of Contract 3-15 27.

Acceleration Contractor to incur additional cost.


26.2 The Project Manager shall decide whether and by how much to extend the Intended Completion Date within 21 days of the Contractor asking the Project Manager for a decision upon the effect of a Compensation Event or Variation and submitting full supporting information.
If the Contractor has failed to give early warning of a delay or has failed to cooperate in dealing with a delay, the delay by this failure shall not be considered in assessing the new Intended Completion Date.

27.1 When the Employer wants the Contractor to finish before the Intended Completion Date, the Project Manager shall obtain priced proposals for achieving the necessary acceleration from the Contractor.
If the Employer accepts these proposals, the Intended Completion Date shall be adjusted accordingly and confirmed by both the Employer and the Contractor.

27.2 If the Contractor’s priced proposals for an acceleration are accepted by the Employer, they are incorporated in the Contract Price and treated as a Variation.

28.

Delays 28.1 The Project Manager may instruct the Contractor to delay the Ordered by the Project Manager 29.

Management Meetings 30.


Early Warning start or progress of any activity within the Works.

29.1 Either the Project Manager or the Contractor may require the other to attend a management meeting.

The business of a management meeting shall be to review the plans for remaining work and to deal with matters raised in accordance with the early warning procedure.
29.2 The Project Manager shall record the business of management meetings and provide copies of the record to those attending the meeting and to the Employer.

The responsibility of the parties for actions to be taken shall be decided by the Project Manager either at the management meeting or after the management meeting and stated in writing to all who attended the meeting.
30.1 The Contractor shall warn the Project Manager at the earliest opportunity of specific likely future events or circumstances that may adversely affect the quality of the work, increase the Contract Price, or delay the execution of the Works.

The Project Manager may require the Contractor to provide an estimate of the expected effect of the future event or circumstance on the Contract Price and Completion Date.
The estimate shall be provided by the Contractor as soon as 3-16 Section VII – General Conditions of Contract reasonably possible.

30.2 The Contractor shall cooperate with the Project Manager in making and considering proposals for how the effect of such an event or circumstance can be avoided or reduced by anyone involved in the work and in carrying out any resulting instruction of the Project Manager.
C. Quality Control 31.1 The Project Manager shall check the Contractor’s work and notify the Contractor of any Defects that are found.

Such checking shall not affect the Contractor’s responsibilities.

The Project Manager may instruct the Contractor to search for a Defect and to uncover and test any work that the Project Manager considers may have a Defect.
32.1 If the Project Manager instructs the Contractor to carry out a test not specified in the Specification to check whether any work has a Defect and the test shows that it does, the Contractor shall pay for the test and any samples.

If there is no Defect, the test shall be a Compensation Event.

33.1 The Project Manager shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion, and is defined in the PCC.
The Defects Liability Period shall be extended for as long as Defects remain to be corrected.

33.2 Every time notice of a Defect is given, the Contractor shall correct the notified Defect within the length of time specified by the Project Manager’s notice.

31.

Identifying Defects 32.

Tests 33.

Correction of Defects 34.


Uncorrected Defects 34.1 If the Contractor has not corrected a Defect within the time specified in the Project Manager’s notice, the Project Manager shall assess the cost of having the Defect corrected, and the Contractor shall pay this amount.

35.

Contract Price D. Cost Control 35.1 In the case of an admeasurement contract, the Bill of Quantities shall contain priced items for the Works to be performed by the Contractor.
The Bill of Quantities is used to calculate the Contract Price.

The Contractor will be paid for the quantity of the work accomplished at the rate in the Bill of Quantities for each item.

35.2 In the case of a lump sum contract, the Activity Schedule shall Section VII – General Conditions of Contract 3-17 contain the priced activities for the Works to be performed by the Contractor.
The Activity Schedule is used to monitor and control the performance of activities on which basis the Contractor will be paid.

If payment for Materials on Site shall be made se parately, the Contra ctor shall show delivery of Materials to the Site separately on the Activity Schedule.

36.
36.

Changes in 36.1 In the case of an admeasurement contract: the Contract Price (a) If the final quantity of the work done differs from the quantity in the Bill of Quantities for the particular item by more than 25 percent, provided the change exceeds 1 percent of the Initial Contract Price, the Project Manager shall adjust the rate to allow for the change.
(b) The Project Manager shall not adjust rates from changes in quantities if thereby the Initial Contract Price is exceeded by more than 15 percent, except with the prior approval of the Employer.

(c) If requested by the Project Manager, the Contractor shall provide the Project Manager with a detailed cost breakdown of any rate in the Bill of Quantities.
36.2 In the case of a lump sum contract, the Activity Schedule shall be amended by the Contractor to accommodate changes of Program or method of working made at the Contractor’s own discretion.

Prices in the Activity Schedule shall not be altered when the Contractor makes such changes to the Activity Schedule.

37.

Variations 37.1 All Variations shall be included in updated Programs, and, in the case of a lump sum contract, also in the Activity Schedule, produced by the Contractor.
37.2 The Contractor shall provide the Project Manager with a quotation for carrying out the Variation when requested to do so by the Project Manager.

The Project Manager shall assess the quotation, which shall be given within seven (7) days of the request or within any longer period stated by the Project Manager and before the Variation is ordered.
37.3 If the Contractor’s quotation is unreasonable, the Project Manager may order the Variation and make a change to the Contract Price, which shall be based on the Project Manager’s own forecast of the effects of the Variation on the Contractor’s costs.
37.4 If the Project Manager decides that the urgency of varying the 3-18 Section VII – General Conditions of Contract work would prevent a quotation being given and considered without delaying the work, no quotation shall be given and the Variation shall be treated as a Compensation Event.

37.5 The Contractor shall not be entitled to additional payment for costs that could have been avoided by giving early warning.
37.6 In the case of an admeasurement contract, if the work in the Variation corresponds to an item description in the Bill of Quantities and if, in the opinion of the Project Manager, the quantity of work above the limit stated in Sub-Clause 38.1 or the timing of its execution do not cause the cost per unit of quantity to change, the rate in the Bill of Quantities shall be used to calculate the value of the Variation.
If the cost per unit of quantity changes, or if the nature or timing of the work in the Variation does not correspond with items in the Bill of Quantities, the quotation by the Contractor shall be in the form of new rates for the relevant items of work.

38.1 When the Program, or, in the case of a lump sum contract, the Activity Schedule, is updated, the Contractor shall provide the Project Manager with an updated cash flow forecast.
The cash flow forecast shall include different currencies, as defined in the Contract, converted as necessary using the Contract exchange rates.

38.

Cash Flow Forecasts 39.

Payment Certificates 39.1 The Contractor shall submit to the Project Manager monthly statements of the estimated value of the work executed less the cumulative amount certified previously.
39.2 The Project Manager shall check the Contractor’s monthly statement and certify the amount to be paid to the Contractor within 10 working days.

39.3 The value of work executed shall be determined by the Project Manager.
39.4 The value of work executed shall comprise: (a) (b) In the case of an admeasurement contract, the value of the quantities of work in the Bill of Quantities that have been completed; or In the case of a lump sum contract, the value of work executed shall comprise the value of completed activities in the Activity Schedule.

Section VII – General Conditions of Contract 3-19 40.

Payments 41.
Payments 41.

Compensatio n Events 39.5 The value of work executed shall include the valuation of Variations and Compensation Events.

39.6 The Project Manager may exclude any item certified in a previous certificate or reduce the proportion of any item previously certified in any certificate in the light of later information.

40.1 Payments shall be adjusted for deductions for advance payments and retention.
The Employer shall pay the Contractor the amounts certified by the Project Manager within 28 days of the date of each certificate.

If the Employer makes a late payment, the Contractor shall be paid interest on the late payment in the next payment.

Interest shall be calculated from the date by which the payment should have been made up to the date when the late payment is made at the prevailing rate of interest for commercial borrowing for each of the currencies in which payments are made.
40.2 If an amount certified is increased in a later certificate or as a result of an award by the Adjudicator or an Arbitrator, the Contractor shall be paid interest upon the delayed payment as set out in this clause.

Interest shall be calculated from the date upon which the increased amount would have been certified in the absence of dispute.

40.3 Unless otherwise stated, all payments and deductions shall be paid or charged in the proportions of currencies comprising the Contract Price.
40.4 Items of the Works for which no rate or price has been entered shall not be paid for by the Employer and shall be deemed covered by other rates and prices in the Contract.

41.1 The following shall be Compensation Events: (a) The Employer does not give access to a part of the Site by the Site Possession Date pursuant to GCC Sub-Clause 20.1.

(b) The Employer modifies the Schedule of Other Contractors in a way that affects the work of the Contractor under the Contract.
(c) The Project Manager orders a delay or does not issue Drawings, Specifications, or instructions required for execution of the Works on time.

(d) The Project Manager instructs the Contractor to uncover 3-20 Section VII – General Conditions of Contract or to carry out additional tests upon work, which is then found to have no Defects.

(e) The Project Manager unreasonably does not approve a subcontract to be let.
(f) Ground conditions are substantially more adverse than could reasonably have been assumed before issuance of the Letter of Acceptance from the information issued to bidders (including the Site Investigation Reports), from information available publicly and from a visual inspection of the Site.

(g) The Project Manager gives an instruction for dealing with an unforeseen condition, caused by the Employer, or additional work required for safety or other reasons.
(h) Other contractors, public authorities, utilities, or the Employer does not work within the dates and other constraints stated in the Contract, and they cause delay or extra cost to the Contractor.

(i) The advance payment is delayed.

(j) The effects on the Contractor of any of the Employer’s Risks.

(k) The Project Manager unreasonably delays issuing a Certificate of Completion.
41.2 If a Compensation Event would cause additional cost or would prevent the Intended the work being completed before Completion Date, the Contract Price shall be increased and/or the Intended Completion Date shall be extended.

The Project Manager shall decide whether and by how much the Contract Price shall be increased and whether and by how much the Intended Completion Date shall be extended.
41.3 As soon as information demonstrating the effect of each Compensation Event upon the Contractor’s forecast cost has been provided by the Contractor, it shall be assessed by the Project Manager, and the Contract Price shall be adjusted is deemed accordingly.

unreasonable, the Project Manager shall adjust the Contract Price based on the Project Manager’s own forecast.

The Project react Manager shall assume competently and promptly to the event.
the Contractor shall the Contractor’s forecast that If Section VII – General Conditions of Contract 3-21 42.

Tax 43.

Currencies 44.

Price Adjustment 41.4 The Contractor shall not be entitled to compensation to the extent that the Employer’s interests are adversely affected by the Contractor’s not having given early warning or not having cooperated with the Project Manager.
42.1 The Project Manager shall adjust the Contract Price if taxes, duties, and other levies are changed between the date 28 days before the submission of bids for the Contract and the date of the last Completion certificate.

The adjustment shall be the change in the amount of tax payable by the Contractor, provided such changes are not already reflected in the Contract Price or are a result of GCC Clause 44.
43.1 Where payments are made in currencies other than the currency of the Employer’s country specified in the PCC, the exchange rates used for calculating the amounts to be paid shall be the exchange rates stated in the Contractor’s Bid.

44.1 Prices shall be adjusted for fluctuations in the cost of inputs only if provided for in the PCC.
If so provided, the amounts certified in each payment certificate, before deducting for Advance Payment, shall be adjusted by applying the respective price adjustment factor to the payment amounts due in each currency.
A separate formula of the type indicated below applies to each Contract currency: Pc = Ac + Bc Imc/Ioc where: Pc is the adjustment factor for the portion of the Contract Price payable in a specific currency “c.” Ac and Bc are coefficients6 specified in the PCC, representing the nonadjustable and adjustable portions, respectively, of the Contract Price payable in that specific currency “c;” and Imc is the index prevailing at the end of the month being invoiced and Ioc is the index prevailing 28 days before Bid opening for inputs payable; both in the specific currency “c.” 44.2 If the value of the index is changed after it has been used in a calculation, the calculation shall be corrected and an adjustment 6 The sum of the two coefficients Ac and Bc should be 1 (one) in the formula for each currency.
Normally, both coefficients shall be the same in th e formulae for all currencies, since coefficient A, for the nonadjustable portion of the payments, is a very approximate figure (usually 0.15) to take account of fixed cost elements or other nonadjustable components.

The sum of the adjustments for each currency are added to the Contract Price.

[To be transferred to the User Guide] 3-22 Section VII – General Conditions of Contract made in the next payment certificate.
The index value shall be deemed to take account of all changes in cost due to fluctuations in costs.

45.

Retention 45.1 The Employer shall retain from each payment due to the Contractor the proportion stated in the PCC until Completion of the whole of the Works.
45.2 Upon the issue of a Certificate of Completion of the Works by the Project Manager, in accordance with GCC 51.1, half the total amount retained shall be repaid to the Contractor and half when the Defects Liability Period has passed and the Project Manager has certified that all Defects notified by the Project Manager to the Contractor before the end of this period have been corrected.

The Contractor may substitute retention money with an “on demand” Bank guarantee.
46.1 The Contractor shall pay liquidated damages to the Employer at the rate per day stated in the PCC for each day that the Completion Date is later than the Intended Completion Date.

The total amount of liquidated damages shall not exceed the amount defined in the PCC.

The Employer may deduct liquidated damages from payments due to the Contractor.

Payment of liquidated damages shall not affect the Contractor’s liabilities.
46.2 If the Intended Completion Date is extended after liquidated damages have been paid, the Project Manager shall correct any overpayment of liquidated damages by the Contractor by adjusting the next payment certificate.

The Contractor shall be paid interest on the overpayment, calculated from the date of payment to the date of repayment, at the rates specified in GCC Sub-Clause 40.1.
47.1 The Contractor shall be paid a Bonus calculated at the rate per calendar day stated in the PCC for each day (less any days for which the Contractor is paid for acceleration) that the Completion is earlier than the Intended Completion Date.

The Project Manager shall certify that the Works are complete, although they may not be due to be complete.
48.1 The Employer shall make advance payment to the Contractor of the amounts stated in the PCC by the date stated in the PCC, against provision by the Contractor of an Unconditional Bank Guarantee in a form and by a bank acceptable to the Employer in amounts and currencies equal to the advance payment.

The Guarantee shall remain effective until the advance payment has been repaid, but the amount of the Guarantee shall be 46.

Liquidated Damages 47.

Bonus 48.


Advance Payment Section VII – General Conditions of Contract 3-23 progressively reduced by the amounts repaid by the Contractor.

Interest shall not be charged on the advance payment.

48.2 The Contractor is to use the advance payment only to pay for Equipment, Plant, Materials, and mobilization expenses required specifically for execution of the Contract.
The Contractor shall demonstrate that advance payment has been used in this way by supplying copies of invoices or other documents to the Project Manager.

48.3 The advance payment repaid by deducting shall be proportionate amounts from payments otherwise due to the Contractor, following the schedule of completed percentages of the Works on a payment basis.
No account shall be taken of the advance payment or its repayment in assessing valuations of work done, Variations, price adjustments, Compensation Events, Bonuses, or Liquidated Damages.
49.1 The Performance Security shall be provided to the Employer no later than the date specified in the Letter of Acceptance and shall be issued in an amount specified in the PCC, by a bank or surety acceptable to the Employer, and denominated in the types and proportions of the currencies in which the Contract Price is payable.
The Performance Security shall be valid until a date 28 days from the date of issue of the Certificate of Completion in the case of a Bank Guarantee, and until one year from the date of issue of the Completion Certificate in the case of a Performance Bond.

50.1 If applicable, the Dayworks rates in the Contractor’s Bid shall be used only when the Project Manager has given written instructions in advance for additional work to be paid for in that way.
50.2 All work to be paid for as Dayworks shall be recorded by the Contractor on forms approved by the Project Manager.

Each completed form shall be verified and signed by the Project Manager within two days of the work being done.

50.3 The Contractor shall be paid for Dayworks subject to obtaining signed Dayworks forms.
51.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor’s cost if the loss or damage arises from the Contractor’s acts or omissions.

49.

Securities 50.

Dayworks 51.

Cost of Repairs 3-24 Section VII – General Conditions of Contract E. Finishing the Contract 52.
Completion 52.1 The Contractor shall request the Project Manager to issue a Certificate of Completion of the Works, and the Project Manager shall do so upon deciding that the whole of the Works is completed.

53.

Taking Over 53.1 The Employer shall take over the Site and the Works within seven days of the Project Manager’s issuing a certificate of Completion.

54.
54.

Final Account 54.1 The Contractor shall supply the Project Manager with a detailed account of the total amount that the Contractor considers payable under the Contract before the end of the Defects Liability Period.

The Project Manager shall issue a Defects Liability Certificate and certify any final payment that is due to the Contractor within 56 days of receiving the Contractor’s account if it is correct and complete.
If it is not, the Project Manager shall issue within 56 days a schedule that states the scope of the corrections or additions that are necessary.

If the Final Account is still unsatisfactory after it has been resubmitted, the Project Manager shall decide on the amount payable to the Contractor and issue a payment certificate.

55.
55.

Operating and Maintenance Manuals 55.1 If “as built” Drawings and/or operating and maintenance manuals are required, the Contractor shall supply them by the dates stated in the PCC.

55.2 If the Contractor does not supply the Drawings and/or manuals by the dates stated in the PCC pursuant to GCC Sub-Clause 55.1, or they do not receive the Project Manager’s approval, the Project Manager shall withhold the amount stated in the PCC from payments due to the Contractor.

56.
56.

Termination 56.1 The Employer or the Contractor may terminate the Contract if the other party causes a fundamental breach of the Contract.
56.2 Fundamental breaches of Contract shall include, but shall not be limited to, the following: (a) (b) the Contractor stops work for 28 days when no stoppage of work is shown on the current Program and the stoppage has not been authorized by the Project Manager; the Project Manager instructs the Contractor to delay the progress of the Works, and the instruction is not withdrawn within 28 days; (c) the Employer or the Contractor is made bankrupt or goes into liquidation other than for a reconstruction or amalgamation; Section VII – General Conditions of Contract 3-25 (d) a payment certified by the Project Manager is not paid by the Employer to the Contractor within 84 days of the date of the Project Manager’s certificate; (e) the Project Manager gives Notice that failure to correct a particular Defect is a fundamental breach of Contract and the Contractor fails to correct it within a reasonable period of time determined by the Project Manager; (f) the Contractor does not maintain a Security, which is required; (g) (h) the Contractor has delayed the completion of the Works by the number of days for which the maximum amount of liquidated damages can be paid, as defined in the PCC; or if the Contractor, in the judgment of the Employer, has engaged in corrupt or fraudulent practices in competing for or in executing the Contract, pursuant to GCC Clause 57.1.
56.3 When either party to the Contract gives notice of a breach of Contract to the Project Manager for a cause other than those listed under GCC Sub-Clause 56.2 above, the Project Manager shall decide whether the breach is fundamental or not.

56.4 Notwithstanding the above, the Employer may terminate the Contract for convenience.

56.5 If the Contract is terminated, the Contractor shall stop work immediately, make the Site safe and secure, and leave the Site as soon as reasonably possible.

57.
57.

Fraud and Corruption loans), 57.1 The Bank requires that Recipients (including beneficiaries of Bank as Contractors, Subcontractors, manufacturers, and Consultants under Bank-financed contracts, observe the highest standard of ethics during the procurement and execution of such contracts.
In pursuit of this policy, the Bank: as well (a) defines, for the purposes of this provision, the terms set forth below as follows: (i) “corrupt practice” means the offering, giving, receiving, or soliciting, directly or indirectly, of anything of value to influence the action of a public official in the procurement process or in contract execution; (ii) “fraudulent practice” means a misrepresentation of facts in order to influence a procurement process or the execution of a contract; 3-26 Section VII – General Conditions of Contract (iii) “collusive practice” means a scheme or arrangement between two or more bidders, with or without the knowledge of the Recipient, designed to establish bid prices at artificial, noncompetitive levels; and (iv) “coercive practice” means harming or threatening to harm, directly or indirectly, persons or their property to influence their participation in the procurement process or affect the execution of a contract; (b) will cancel the portion of the loan allocated to a contract if it determines at any time that representatives of the Recipient or of a beneficiary of the loan engaged in corrupt, fraudulent, collusive or coercive practices during the procurement or the execution of that contract, without the Recipient having taken timely and appropriate action satisfactory to the Bank to remedy the situation; and (c) will sanction a firm or individual, including declaring them ineligible, either indefinitely or for a stated period of time, to be awarded a Bank-financed contract if it at any time determines that they have, directly or through an agent, engaged in corrupt, fraudulent, collusive or coercive practices in competing for, or in executing, a Bank-financed contract.
58.1 If the Contract is terminated because of a fundamental breach of Contract by the Contractor, the Project Manager shall issue a certificate for the value of the work done and Materials ordered less advance payments received up to the date of the issue of the certificate and less the percentage to apply to the value of the work not completed, as indicated in the PCC.

Additional Liquidated Damages shall not apply.


If the total amount due to the Employer exceeds any payment due to the Contractor, the difference shall be a debt payable to the Employer.
58.2 If the Contract is terminated for the Employer’s convenience or because of a fundamental breach of Contract by the Employer, the Project Manager shall issue a certificate for the value of the work done, Materials ordered, the reasonable cost of removal of Equipment, repatriation of the Contractor’s personnel employed solely on the Works, and the Contractor’s costs of protecting and securing the Works, and less advance payments received up to the date of the certificate.

58.
58.

Payment upon Termination 59.

Property 59.1 All Materials on the Site, Plant, Equipment, Temporary Works, and Works shall be deemed to be the property of the Employer if the Contract is terminated because of the Contractor’s default.

Section VII – General Conditions of Contract 3-27 60.
Release from Performance 60.1 If the Contract is frustrated by the outbreak of war or by any other event entirely outside the control of either the Employer or the Contractor, the Project Manager shall certify that the Contract has been frustrated.

The Contractor shall make the Site safe and stop work as quickly as possible after receiving this certificate and shall be paid for all work carried out before receiving it and for any work carried out afterwards to which a commitment was made.

61.
61.

Suspension of Bank Loan or Grant 61.1 In the event that the Bank suspends the Loan or Grant to the Employer, from which part of the payments to the Contractor are being made: 62.

Eligibility (a) The Employer is obligated to notify the Contractor of such suspension within 7 days of having received the Bank’s suspension notice.
(b) If the Contractor has not received sums due it within the 28 days for payment provided for in Sub-Clause 40.1, the Contractor may immediately issue a 14-day termination notice.

62.1 The Contractor shall have the nationality of an eligible country.

The Contractor shall be deemed to have the nationality of a country if the Contractor is a citizen or is constituted, or incorporated, and operates in conformity with the provisions of the laws of that country.
This criterion shall also apply to the determination of the nationality of proposed subcontractors or suppliers for any part of the Contract including related services.

62.2 The materials, equipment and services to be supplied under the Contract shall have their origin in eligible source countries and all expenditures under the Contract will be limited to such materials, At the Employer’s request, the equipment, and services.
Contractor may be required to provide evidence of the origin of materials, equipment and services.

62.3 For purposes of GCC 62.2, “origin” means the place where the materials and equipment are mined, grown, produced or the services are provided.
manufactured, and from which Materials and equipment are produced when, through manufacturing, processing, or substantial or major assembling of components, a commercially recognized product results that differs substantially in its basic characteristics or in purpose or utility from its components.

3‐28 Section VIII ‐ Particular Conditions of Contract SECTION VIII.

Particular Conditions of Contract - Contract Data 3-29 Section VIII.
Particular Conditions of Contract Except where otherwise indicated, all PCC should be filled in by the Employer prior to issuance of the Bidding Documents.

Schedules and reports to be provided by the Employer should be annexed.

A.

General GCC 1.1 (d) The financing institution is: Caribbean Development Bank.

GCC 1.1 (s) The Employer is Government of Antigua and Barbuda Ministry of Education.

GCC 1.1 (iv) The period of construction is 12 months.
GCC 1.1 (z) The Project Manager is Moulton Mayers Architects, McKies Hill, Kingstown, St. Vincent.

GCC 1.1 (aa) The Site is located at Bolans, St. Mary's, Antigua and is defined in drawings - refer to drawing schedule.

GCC 1.1 (ee) The Start Date shall be within 21 days of date of Letter of Acceptance.

GCC 1.1 (ii) The Works consist of the alterations and extension to the existing school.

GCC 2.2 Sectional Completions are: N/A.

GCC 2.3(i) The following documents also form part of the Contract: N/A.
GCC 3.1 The language of the contract is English.

The law that applies to the Contract is the law of Antigua and Barbuda.

GCC 5.1 The Project manager may not delegate any of his duties and responsibilities.

GCC 8.1 Schedule of other contractors: [insert Schedule of Other Contractors, if appropriate] GCC 13.1 The minimum insurance amounts and deductibles shall be: (a) for loss or damage to the Works, Plant and Materials: contract amount plus 10%.

(b) For loss or damage to Equipment: US$185,000.00.
(c) for loss or damage to property (except the Works, Plant, Materials, and Equipment) in connection with Contract US$370,000.00.

3-30 Section VIII – Particular Conditions of Contract (d) for personal injury or death: (i) of the Contractor’s employees: US$925,000.00.

(ii) of other people: US$925,000.00.

GCC 14.1 Site Data are: Soils Report GCC 20.1 The Site Possession Date(s) shall be: within 21 days of Letter of Acceptance.
GCC 23.1 & GCC 23.2 Appointing Authority for the Adjudicator: President of the Barbados Institute of Architects.

GCC 24.3 GCC 24.4 Hourly rate and types of reimbursable expenses to be paid to the Adjudicator: to be agreed.

Institution whose arbitration procedures shall be used: Arbitration Laws of Antigua and Barbuda.

The place of arbitration shall be: Antigua.

B.


Time Control GCC 25.1 The Contractor shall submit for approval a Program for the Works within 14 days from the date of the Letter of Acceptance.

GCC 25.3 The period between Program updates is 60 days.

The amount to be withheld for late submission of an updated Program is US$1,000.00.

GCC 33.1 The Defects Liability Period is: 365 days.

C. Quality Control D. Cost Control GCC 43.1 The currency of the Employer’s country is: EC dollars.
GCC 44.1 The Contract is not subject to price adjustment in accordance with GCC Clause 44, and the following information regarding coefficients does not apply.

The coefficients for adjustment of prices are: (a) For currency [insert name of currency]: (i) [insert percentage] percent non adjustable element (coefficient A).

Section VIII – Particular Conditions of Contract 3-31 (ii) [insert percentage] percent adjustable element (coefficient B).
(b) For currency [insert name of currency]: (i) [insert percentage] percent non adjustable element (coefficient A).

(ii) [insert percentage] percent adjustable element (coefficient B).

The Index I for local currency shall be [insert index].

The Index I for the specified international currency shall be [insert index].
[These proxy indices shall be proposed by the Contractor, subject to acceptance by the Employer] The Index I for currencies other than the local currency and the specified international currency shall be [insert index].

[These proxy indices shall be proposed by the Contractor, subject to acceptance by the Employer.]

GCC 45.1 The proportion of payments retained is: 5%.

GCC 46.1 GCC 47.1 GCC 48.1 GCC 49.1 The liquidated damages for the whole of the Works are US$1,000.00 per day.
The maximum amount of liquidated damages for the whole of the Works is 10% of the final Contract Price.

The Bonus for the whole of the Works is $0 (zero) per day.

The maximum amount of Bonus for the whole of the Works is [insert percentage] of the final Contract Price.

The Advance Payments shall be: 10% of accepted contract amount and shall be paid to the Contractor no later than 30 days after contract signing and approval of all bonds and insurances.
The Performance Security amount is 10% denominated in the types and proportions of the currencies in which the Contract Price is payable, or in a freely convertible currency acceptable to the Employer] (a) Bank Guarantee: 10% of accepted contract amount.

(b) Performance Bond: 30% of accepted contract amount.

[A Bank Guarantee shall be unconditional (on demand) (see Section X.

Security Forms).
Security Forms).

A Performance Bond is an undertaking by a bonding or insurance company (surety) to complete the construction in the event of default by the Contractor, or to pay the amount of the Bond to the Employer.

An amount of 30 percent of the Contract Price is commonly used internationally for this type of security (see Section X.

Security Forms).]
Security Forms).]

3-32 Section VIII – Particular Conditions of Contract E. Finishing the Contract GCC 55.1 The date by which operating and maintenance manuals are required is 14 days after Certificate of Completion.

The date by which “as built” drawings are required is 60 days after Certificate of Completion.

GCC 55.2 The amount to be withheld for failing to produce “as built” drawings and/or operating and maintenance manuals by the date required in GCC 55.1 is US$8,000.00.
GCC 56.2 (g) The maximum number of days is: 150 days.

GCC 58.1 The percentage to apply to the value of the work not completed, representing the Employer’s additional cost for completing the Works, is 15%.

3-33 Section IX - Contract Forms This Section contains forms which, once completed, will form part of the Contract.

The forms for Performance Security and Advance Payment Security, when required, shall only be completed by the successful Bidder after contract award.
Table of Forms Letter of Acceptance ............................................................................................................. 34 Contract Agreement ............................................................................................................. 36 Performance Security ........................................................................................................... 38 Advance Payment Security .................................................................................................. 40 3-34 Section IX - Contract Forms Letter of Acceptance [ on letterhead paper of the Employer] To: .
.

.

.

.

.

.

.

.

.

[ name and address of the Contractor] .

.

.

.

.

.

.

.

.

.

Subject: .

.

.

.

.

.

.

.

.

.

[Notification of Award Contract No].

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

[date].

.

.

.

.

.

.

This is to notify you that your Bid dated .

.

.

.

[insert date] .

.

.

.

for execution of the .

.

.

.

.

.

.

.

.

.

[insert name of the contract and identification number, as given in the Ap pendix to Bid] .

.

.

.

.

.

.

.

.

.


for the Accepted Contract Amount of the equivalent of .

.

.

.

.

.

.

.

.

[insert amount in numbers and words and name of currency], as corrected and modified in accordance with the Instructions to Bidders is hereby accepted by our Agency.
You are requested to furnish the Performance Security within 28 days in accordance with the Conditions of Contract, using for that purpose the of the Performance Security Form included in Section IX (Contract Forms) of the Bidding Document.

[Choose one of the following statements:] We accept that __________________________[insert the name of Adjudicator proposed by the Bidder] be appointed as the Adjudicator.
[or] We do not accept that _______________________[insert the name of the Adjudicator proposed by the Bidder] be appointed as the Adjudicator, and by sending a copy of this Letter of Acceptance to ________________________________________[insert name of the Appo inting Authority], the Appointing Authority, we are hereby requesting such Authority to appoint the Adjudicator in accordance with ITB 42.1 and GCC 23.1.
Authorized Signature: ................................................................................................................... Name and Title of Signatory: ........................................................................................................ Name of Agency: ..........................................................................................................................
Section IX - Contract Forms 3-35 Attachment: Contract Agreement 3-36 Section IX - Contract Forms Contract Agreement THIS AGREEMENT made the .

.

.

.

.

.day of .

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

., .

.

.

.

.

.

., between .

.

.

.

.

[name of the Employer].

.

.

.

.. .

.

.

.

(hereinafter “the Employer”), of the one part, and .

.

.

.

.

[name of the Contractor].

.

.

.

.


(hereinafter “the Contractor”), of the other part: WHEREAS the Employer desires that the Works known as .

.

.

.

.

[name of the C ontract].

.

.

.


.should be executed by the Contractor, and has accepted a Bid by the Contractor for the execution and completion of these Works and the remedying of any defects therein, The Employer and the Contractor agree as follows: In this Agreement words and expressions shall have the same meanings as are 1. respectively assigned to them in the Contract documents referred to.
The following documents shall be deemed to form and be read and construed as part 2. of this Agreement.

This Agreement shall prevail over all other Contract documents.

(a) the Letter of Acceptance (b) the Bid (c) the Addenda Nos .

.

.

.

.

[insert addenda numbers if any].

.

.

.

.

(d) the Particular Conditions (e) the General Conditions; (f) the Specification (g) the Drawings; and (h) the completed Schedules, 3.
In consideration of the payments to be made by the Employer to the Contractor as indicated in this Agreement, the Contractor hereby covenants with the Employer to execute the Works and to remedy defects therein in conformity in all respects with the provisions of the Contract.

4.
4.

The Employer hereby covenants to pay the Contractor in consideration of the execution and completion of the Works and the remedying of defects therein, the Contract Price or such other sum as may become payable under the provisions of the Contract at the times and in the manner prescribed by the Contract.

IN WITNESS whereof the parties hereto have caused this Agreement to be executed in accordance with the laws of .

.

.

.

.

[name of t he borrowing country] .

.

.

.


.on the day, month and year indicated above.
Section IX - Contract Forms 3-37 Signed by: Signed by: for and on behalf of the Employer for and on behalf the Contractor in the presence of: in the presence of: Witness, Name, Signature, Address, Date Witness, Name, Signature, Address, Date 3-38 Section IX - Contract Forms Performance Security [Bank’s Name, and Address of Issuing Branch or Office] Beneficiary: ...................................... [Name and Address of Employer] .........................................
Date: ............................................................................................................................................

Performance Guarantee No.

: ................................................................................................... We have been informed that .

.

.

.

.

[name of the Contr actor].

.

.

.

.

(hereinafter called “the Contractor”) has entered into Contract No.

.

.

.

.

.

[reference number of the Contract].

.

.

.

.

dated .

.

.

.

.


.

.

.with you, for the execution of .

.

.

.

.

.

[name of contract and brief description of Works].

.

.

.

.

(hereinafter called “the Contract”).

Furthermore, we understand that, according to the conditions of the Contract, a performance guarantee is required.

At the request of the Contractor, we .

.

.

.

.

[name of the Bank].

.

.

.

.

hereby irrevocably undertake to pay you any sum or sums not exceeding in total an amount of .

.

.

.

.

.

.

.

.


[name of the currency and amount in figures] 1. .

.

.

.

.

(.

.

.

.

.

[amount in words].

.

.

.

. )

such sum being payable in the types and proportions of currencies in which the Contract Price is payable, upon receipt by us of your first demand in writing accompanied by a written statement stating that the Contractor is in breach of its obligation(s) under the Contract, without your needing to prove or to show grounds for your demand or the sum specified therein.
This guarantee shall expire, no later than the .

.

.

.

.

Day of .

.

.

.

.

.

.

.

.

.

, .

.

.

.

.

.

2, and any demand for payment under it must be received by us at this office on or before that date.

This guarantee is subject to the Uniform Rules for Demand Guarantees, ICC Publication No.

458, except that subparagraph (ii) of Sub-article 20(a) is hereby excluded.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.

.


[Seal of Bank and Signature(s)] Note – All italicized text is for guidance on how to prepare this demand guarantee and shall be del eted from the final document.

1 The Guarantor shall insert an amount representing the percentage of the Contract Price sp ecified in the Contract and denominated either in the currency(ies) of the Contract or a freely convertible currency acceptable to the Employer.
2 Insert the date twenty-eight days after the expected completion date.

The Employer should note that in the event of an extension of the time for completion of the Contract, the Employer would need to request an extension of this guarantee from t he Guarantor.

Such request mu st be in writin g and must be made prior to th e expiration date Section IX - Contract Forms 3-39 established in the guarantee.
In preparing this guarantee, the Employer might consider adding the following text to the form, at the end of the penultimate paragraph: “The Guarantor agrees to a one-time extension of this guarantee for a period not to exceed [six months][one year], in response to the Employer’s written request for such extension, such request to be presented to the Guarantor before the expiry of the guarantee.” 3-40 Section IX - Contract Forms Advance Payment Security [Bank’s Name, and Address of Issuing Branch or Office] Beneficiary: ...................................... [Name and Address of Employer] .........................................
Date: ............................................................................................................................................ Advance Payment Guarantee No.

: .......................................................................................... We have been informed that .

.

.

.

.

[name of the Contr actor].

.

.

.

.

(hereinafter called “the Contractor”) has entered into Contract No.

.

.

.

.

.

[reference number of the Contract].

.

.

.

.

dated .

.

.

.

.

.

.


.with you, for the execution of .

.

.

.

.

.

[name of contract and brief description of Works].

.

.

.

.

(hereinafter called “the Contract”).

Furthermore, we understand that, according to the Conditions of the Contract, an advance payment in the sum .

.

.

.

.

[name of the currency and amount in figures] 1. .

.

.

.

.

(.

.

.

.

.

[amount in words].

.

.

.

. )

is to be made against an advance payment guarantee.
At the request of the Contractor, we .

.

.

.

.

[name of the Bank].

.

.

.

.

hereby irrevocably undertake to pay you any sum or sums not exceeding in total an amount of .

.

.

.

.

[name of the currency and amount in figures]*.

.

.

.

.

.

(.

.

.

.

.

[amount in words].

.

.

.

. )


upon receipt by us of your first demand in writing accompanied by a written statement stating that the Contractor is in breach of its obligation under the Contract because the Contractor used the advance payment for purposes other than the costs of mobilization in respect of the Works.
It is a condition for any claim and payment under this guarantee to be made that the advance payment referred to above must have been received by the Contractor on its account number .

.

.

.

.

[Contractor’s account number].

.

.

.

.

at .

.

.

.

.

[name and address of the Bank].

.

.

.

.

.


The maximum amount of this guarantee shall be progressively reduced by the amount of the advance payment repaid by the Contractor as indicated in copies of interim statements or payment certificates which shall be presented to us.

This guarantee shall expire, at the latest, upon our receipt of a copy of the interim payment certificate indicating that eighty (80) percent of the Contract Price has been certified for payment, or on the .

.

.

day of .

.

.


.

.

.

.

, .

.

.

.

.

2, whichever is earlier.

Consequently, any demand for payment under this guarantee must be received by us at this office on or before that date.

This guarantee is subject to the Uniform Rules for Demand Guarantees, ICC Publication No.

458. .

.

.

.

.

.

.

.

.

.

.

.

.

.

[Seal of Bank and Signature(s)].

.

.

.

.

.

.

.

.

.

.

.

.

.


NNoottee –– All italicized text is for guidance on how to prepare this demand guarantee and shall be del eted from the final document.

1 The Guarantor shall insert an amount representing the amount of the advance payment denominated either in the currency(ies) of the advance payment as specified in the Contract, or in a freely convertible currency acceptable to the Employer.
Section IX - Contract Forms 3-41 Insert the expected expiration date of the Time for Completion.

The E mployer should note that in t he event of 2 an extension of the time for completion of the Contract, the Employer would need to request an extension of this guarantee from t he Guarantor.

Such request mu st be in writin g and must be made prior to th e expiration date established in the guarantee.
In preparing this guarantee, the Employer might consider adding the following text to the form, at the end of the penultimate paragraph: “The Guarantor agrees to a one-time extension of this guarantee for a period not to exceed [six months][one year], in response to the Employer’s written request for such extension, such request to be presented to the Guarantor before the expiry of the guarantee.